Project Summary Artist s impression: General View to the West - Victorian Desalination Plant Novemer 2009 Prepared y Capital Projects Division (a division of the Department of Sustainaility and Environment) in conjunction with the Department of Treasury and Finance
Contents Part One: Project overview... 2 1.1...2 1.2 A pulic private partnership...6 1.3 Tender process...6 1.4 Value for money...8 1.5 Pulic interest considerations...10 1.6 Project milestones...11 Part Two: Key commercial features... 12 2.1 Parties to the contract...12 2.2 Contractual relationships...13 2.3 Risk transfer...13 2.4 General oligations of the contractor...16 2.5 General oligations of the State...16 2.6 Government service payments...17 2.7 State contriutions...17 2.8 Performance measures and aatement...18 2.9 Default and termination regime...19 2.10 Finance and security arrangements...19 2.11 State rights at expiry of contract...20 2.12 Process for Government modification of services / facility...21 2.13 Future Technology Improvement...21 Glossary... 22 Appendix 1: Useful References... 25 Appendix 2: Key Contact Details... 26 Appendix 3: Evaluation Criteria... 27 Appendix 4: Pulic Interest Test... 30 i
Foreword The Project Summary series provides information aout the procedural and contractual nature of Partnerships Victoria projects. The (the Project) represents the largest pulic sector investment in water infrastructure in Australia s history. The Project is eing delivered within the Partnerships Victoria framework. It represents a major non-rainfall dependant addition to Melourne s and regional Victoria s uran water supply. The Project is a key step in the implementation of the State s Water Plan: Our Water Our Future The Next Stage of the Government s Water Plan (Water Plan), announced in June 2007. Partnerships Victoria is part of the Victorian Government s strategy to provide etter services to all Victorians y expanding and improving Victoria s pulic infrastructure. Since 2000, 19 Partnerships Victoria projects have een contracted with a total value of $9.5 illion of capital investment, including $3.5 illion of capital investment for the Project. This project summary is divided into two parts. The first part provides a road overview of the Project, including the rationale for undertaking it under the Partnerships Victoria policy, a summary of the tender process, the value for money calculation, the pulic interest considerations for the project and the project timetale. The second part provides more detail on the key commercial features of the Project, including the main parties and their general oligations, the road allocation of risk etween the pulic and private sectors, the treatment of various key project issues including the payment mechanism and the finance and security arrangements. NB: This summary should not e relied on as a complete description of the rights and oligations of the parties to the project and is not intended for use as a sustitute for the contracts. 1
Part One: Project overview 1.1 The Project The Project is the largest seawater desalination plant currently eing developed in Australia. It will supply up to 150 gigalitres (GL) of water a year to Melourne, Geelong and, via other connections, South Gippsland and Western Port towns, with the capacity to upgrade to supply up to 200 GL in future. The Project s production capacity represents approximately one third of Melourne s annual water usage from a source that is entirely independent of rainfall. The Project will assist in providing water security for Melourne. The marine intake and outlet tunnels, transfer pipeline, and the power supply will all e uilt for 200 GL per annum capacity from the outset. This way, if the State requires the additional capacity, only the plant would e required to e upgraded. The Project is the world s largest Pulic Private Partnership (PPP) project undertaken in the last 12 months. It is a landmark transaction conducted in the most adverse financial markets since the Great Depression. The Project will e delivered y the AquaSure consortium, comprising Degrémont SA, Suez Environnement, Thiess Pty Ltd and Macquarie Group, in partnership with the Capital Projects Division of the Department of Sustainaility and Environment. The Project capital cost of $3.5 illion will e fully funded y the private sector. The ank group has committed to seven to ten year funding. The State Government has acted as lender of last resort for an initial ank syndication process run y AquaSure to seek additional long term investors for $1.7 illion of det funding. This syndication process has now een completed, within the first two months of a three year syndication support period. The State s syndication support liailities are now no longer required. The success story of this Project ears testament to the roustness of the Australian PPP market and the aility of the State and leading Australian anks to structure PPP transactions which continue to attract significant international investment and offer value for money to the tax payer. Project Ojectives In the context of the overarching ojectives of the Water Plan to provide water security for Victoria s growing population and economy in the face of drought and the challenge of climate change, the State s ojectives for the Project are: Time: to commence delivery of Desalinated Water from the Project to Victoria s water supply system y 19 Decemer 2011; Scope: to provide Victoria with a non-rainfall dependent supply of initially up to 150 GL per annum; to allow for the efficient future expansion of the Project to supply up to 200 GL per annum; 2
to ensure desalinated water delivered meets the State s water quality requirements; to retain flexiility to vary supplies over time to support optimisation of Victoria s water supply network; to deliver the Project in a manner consistent with the State s policy of retaining ownership and management of water resources in pulic hands; Value for money: to deliver innovative solutions and overall value for money to the State, water users and the general pulic, through a whole of life approach to service delivery, risk management and the design, construction, operation and maintenance of the Project; Environmental: to minimise the environmental impact of the Project through design and appropriate risk management and mitigation measures and in particular, to minimise adverse impacts on the coastal and marine environment from construction activity, visual intrusion, noise and waste discharge and disposal; to protect the eneficial uses of the coastal and marine environment, including the landscape and recreational values of the adjacent coastal reserve; to optimise energy efficiency and ensure that 100% of the electricity used in operating the Desalination Plant and associated infrastructure will e offset y the purchase of renewale energy credits; Social: to maximise enefits to the local community and wider economy within relevant State Government policy frameworks; to estalish and maintain the highest levels of health, safety and aesthetics throughout the delivery and operation of the Project; and to minimise disruption to the surrounding area during construction. Water Security The Transfer Pipeline will e supplying the water from the plant into the Melourne Water network near Soldiers Road in Berwick, and water will then flow to consumers directly, or to the Cardinia Reservoir. The 1.9m diameter Transfer Pipeline has also een designed to operate as a two way pipe, which means that when the plant is not running, water from Cardinia Reservoir can flow down the Transfer Pipeline to supply off-takes along the pipeline, including to supply the Wonthaggi area. This creates an 85km extension to the Melourne Water network, providing water security to regional towns in South Gippsland and WesternPort, which can e supplied with desalinated water when the plant is running and with water from the Melourne Water network at other times. A numer of water authorities have already requested connections along the Transfer Pipeline six connections in all. South East Water has requested three connections, South Gippsland Water two connections and WesternPort Water one connection. South Gippsland Water is also currently constructing a new pipeline from the Transfer Pipeline near the plant site, to supply Wonthaggi, Inverloch and Cape Paterson. 3
Water Quality Melourne s consumers currently receive some of the est water quality in the world. The quality of the water produced y the Project will continue to match the high expectations of Victorian water consumers. Flexile Water Supply Water will e ordered annually y the State Government. AquaSure will supply water to the State only when requested to do so. AquaSure is not entitled to sell water to third parties. The State has flexiility to order water etween 0 GL and 150 GL per annum, generally in 25 GL increments (0, 50, 75, 100, 125 and 150). Each year on 1st April, an order is placed for the water to e supplied in the following financial year i.e. etween 1 July of that year and 30 June of the following year. There is scope for the State to restrict supply during wet winter months or to increase supply (suject to plant capacity) during any year. Payment for water will e in two components a water security payment reflecting the security of having the Desalination Plant producing or ale to produce water and a water usage payment which reflects the variale costs of producing such water as is required. The water security payment is made on the condition that AquaSure is capale of delivering the water that is ordered, to the required quantity and quality. If no water is ordered, to receive the water security payment AquaSure must demonstrate that the Project could have responded to an order for the supply of water. The water usage payment is made only if water is ordered and delivered. Both the water security and the water usage payments are at risk if there is a failure to perform to the required standards. Desalination Technology The plant will use reverse osmosis technology the same as that eing used for all of the major plants in Australia and the predominant desalination technology used worldwide. It will e constructed in three 50 GL modules, which will provide significant flexiility for the supply needs of Melourne, Geelong and the surrounding regions. Degrémont, a memer of the successful consortium, delivered (on time and within udget) and is operating the Western Australian Desalination Plant using similar technology. Plant Architecture and Landscaping Visual amenity has always een an active concern of the community. With the assistance of the Office of the Victorian Government Architect and a range of state government architectural and landscape specialists, the Project ojective of ensuring the plant integrated into the coastal landscape was set. AquaSure s world class, state of the art design achieves this ojective and includes a novel expansive ecological restoration program of the plant site land. This will result in one of the largest ecological restoration programs, with millions of plants and around 150,000 trees planted on the site. The plant uilding will also include a green roof, composed of living native species, ensuring integration into the coastal landscape. Intake and Outlet Tunnels Long tunnels under the sand dunes, each and marine sensitive areas, will e constructed to protect the environment. These tunnels are around 1.1 kilometres long for the intake (4m diameter), and around 1.4 kilometres long for the outlet (4m diameter). The design and operation of the intake and outlet tunnels must meet the contractual Performance 4
Requirements of the State. These were set following the completion of the Environment Effects Statement (EES), commentary from the pulic, a range of government regulators and other stakeholders, the EES Inquiry Panel and the EES Independent expert. The Environment Protection Authority (EPA) has also set requirements as part of its Works Approval, granted for the Project on 3 March 2009. Ultimately, AquaSure must otain a Discharge License from the EPA efore the plant will e ale to operate. Power Supply The power supply will e an underground high voltage alternating current transmission line (HVAC Transmission Line), largely co-located (within the one easement) with the Transfer Pipeline except where it diverges towards the Cranourne terminal station (along an existing high voltage overhead power line easement at Pound Road, Clyde North). Where co-located, the Transfer Pipeline and Power Supply will e generally within a single 20 metre easement, which is within the width shown in the EES for the pipeline alone (15 to 20m). The design of the HVAC Transmission Line will require some power load compensator equipment, which will e co-located with the ooster pump station in Cardinia, and located separately at a point approximately mid-way along the length of the HVAC Transmission Line. Each of these installations will occupy a small area. The power supply is eing sized to suit the requirements of the plant at 200 GL capacity, and will e dedicated to supplying the plant only. The HVAC Transmission Line will e easier to construct than other underground solutions. There are multiple suppliers capale of delivering this technology, which was considered lower cost and ale to e constructed in a shorter timeframe than other solutions. HVAC technology has less energy loss than HVDC technology and does not require complex, supplier-specific converter stations. The HVAC Transmission Line is an innovative solution to the challenge of meeting community expectations for minimising visual amenity and disturance to landowners, while meeting the power supply requirements of the project in oth the short and long term. Energy and Renewale Energy A key feature of the Project is that all power usage during the operating phase of the Project will e fully offset y power generation y renewale energy sources commissioned after 1 July 2007. The State has agreed to a minimum level of renewale energy credits each year. The energy procurement arrangement contract is load following and fixed price for the full Project Term. This means for the life of the Project only energy which is consumed is paid for and at a pre-agreed price. Independent Reviewer and Environmental Auditor The State has required the appointment of an Independent Reviewer and Environmental Auditor (IR&EA). Davis Langdon has een appointed to this role, which is a joint appoint of the State and AquaSure. The role of the IR&EA is to review the design, construction and environmental management of the project as it progresses, to seek to ensure safety is maintained and to assist in ensuring compliance with the numerous technical, environmental and social requirements of the contract documents. The environmental auditor aspect of the IR&EA role will also continue during the operation and maintenance phase of the project through to the end of the 30 year term of the contract. 5
1.2 A pulic private partnership The decision to deliver the Project as a PPP was driven y a detailed assessment of the following four alternative delivery models: Traditional State funded procurement under a design and construct contract, with pulic sector operation and maintenance of the plant, or separate short term operating contracts with the private sector; State funded alliance alliance for design and construction with either pulic sector or a further alliance for the operation and maintenance of the plant; State funded procurement under the DBOM model with private sector design, uild, operation and maintenance of the plant; and Partnerships Victoria privately funded PPP with private sector design, finance, construction, operation and maintenance over an extended period of time. Following a detailed assessment, the PPP structure was considered likely to offer the optimal value for money result in delivery of and outcomes for the Project, through the following key enefits: effective risk transfer: the PPP model offered the optimum risk profile given the size and complexity of the Project, oth during the construction phase and eyond into operations and maintenance, with the most efficient and effective management of risks overall. The private sector proponent is committed to delivering water and related services, and maintaining the Desalination Plant and associated infrastructure, to the State s required standards throughout the term of the Project, including meeting changing technology, water quality and environmental requirements; whole of life efficiencies: the PPP model encouraged idders to take a whole of life approach to optimising the alance etween capital costs and ongoing maintenance / lifecycle costs; improved asset and service quality: the PPP model was considered to offer greater control over the quality of infrastructure and services due to the high degree of rigour and roust review and control (including additional layers of review through third party financiers) inherent in the PPP procurement process and, on an ongoing asis, y providing for performance standards, supported y an aatement regime to ensure those standards are met; design innovation: the PPP model provided a highly competitive structure within which there was significant scope and incentive for the private sector to deliver innovative solutions to achieve the est whole of life cost and management of risk, while still meeting the performance requirements; timely delivery: the PPP model was considered most likely to facilitate the required timeframe of commencement of delivery of water y late 2011 and to e effective in mitigating the risks of delay to commissioning compared to the other options considered; and operational flexiility: the PPP model permitted the level of operational flexiility sought y the State, from water production of 0 GL to production at full capacity. 1.3 Tender process The State is facilitating the delivery of the Project y having otained all key State and Commonwealth approvals, concurrently with the idding process. This included approvals or facilitation under the following Acts: 6
the Environment Protection Act 1970 (Vic); the Environment Effects Act 1978 (Vic); the Environment Protection and Biodiversity Conservation Act 1999 (Cth); the Planning and Environment Act 1987 (Vic); the Coastal Management Act 1995 (Vic); the Aoriginal Heritage Act 2006 (Vic); the Land Acquisition and Compensation Act 1986 (Vic); the Heritage Act 1995 (Vic); the Project Development and Construction Management Act 1994 (Vic); the Flora and Fauna Guarantee Act 1988 (Vic); and the Water Act 1989 (Vic). The State conducted a competitive tender process to determine the private sector party to deliver the Project. The tender process was implemented in accordance with Partnerships Victoria policy and principles seeking to ensure that the State received the est value for money outcome. The ase evaluation structure used throughout the tender process was: The State Inter-Departmental Reference Group Cainet Committee Proity Adviser Executive Group Evaluation Panel Department of Treasury & Finance Commercial Panel Technical Panel Architecture & Landscape Panel Specialist Commercial Adviser Su-Panel Figure 1 - Base evaluation structure Specialist Technical Adviser Su-Panel Specialist A&L Adviser Su-Panel Each of the Commercial, Technical and Architecture and Landscape (A&L) Panels were structured with specific su-panels to provide detailed advice in their areas of expertise. This structure was utilised to provide governance to the tender process, which comprised: Expressions of Interest: evaluation of the Expressions of Interest sumitted y consortia seeking to participate in the tender process; 7
Initial Proposals: evaluation of initial proposals sumitted March 2009 in response to the State s Request for Proposals (RFP); Amended Proposals: ased on consultation and community feedack, the government announced its decision to prefer an underground power supply solution in April 2009. Following that decision, the State sought and then evaluated amended proposals from shortlisted idders which encompassed and priced an underground power solution; and Final Proposals: due to the volatility in the financial markets over the tender period, the State sought final proposals from shortlisted idders in July 2009 with firm financing commitments, to optimise the risk allocation and det/equity solutions availale for the Project. The shortlisted idders were evaluated in accordance with the RFP and Appendix 3 sets out relevant evaluation criteria. The roustness of the tender process, and the decision to adopt a two-to-the-wire, fully documented approach, achieved significant value for money, certainty as to the transaction evaluation y the State and competitive risk allocation for the State. The tender process was conducted under strict proity guidelines, with a proity plan developed and approved y the Project s Proity Adviser. The proity plan identified proity principles for the Project and specific rules which were required to e followed y the Project Team in delivering the Project. The proity plan also required each shortlisted idder to appoint a Proity Auditor to report on the performance of that shortlisted idder in relation to specific oligations under the Proity and Process Deed. A review of these reports formed part of the evaluation. The Premier and the Minister for Water announced that the AquaSure consortium had een awarded the contract for the Project on 30 July 2009. The AquaSure proposal offered: state of the art proven technology and high energy efficiency memranes and equipment, producing high quality desalinated water matching Melourne s world class water, with a solution that provided certainty to the delivery of water y end of 2011; world class architecture and landscaping, integrating the plant into the coastal environment and incorporating a large network of recreational trails, wetlands and one of the largest ecological restoration programs with more than 150,000 tress and millions of plants; landmark financing secured in some of the toughest market conditions ever seen; high levels of goods and services supplied y Australian usinesses; a low cost, reliale underground power solution which could e constructed within the State s timeframe; and a long term, fixed price electricity and renewale energy solution, including a major announcement y AGL Energy Ltd committing to a new wind farm at Oakland Hills (63 MW), and with Macarthur wind farm (330 MW) in final commitment phase. 1.4 Value for money The Partnerships Victoria framework seeks to identify and implement efficient infrastructure delivery (value for money). The concept of value for money is not a simple selection of the cheapest solution. Value for money analysis requires consideration of the true value of each method of delivery whether y the State or the Private Sector. The analysis considered 8
quantifiale elements (i.e. items that can e quantified in dollar terms) as well as sujective or qualitative elements. Pulic Sector Comparator The Pulic Sector Comparator (PSC) is an estimate of the risk-adjusted, whole-of-life cost of the Project if delivered y the State. The PSC is developed according to the same output specifications included in the Project Brief and assumes the most likely and efficient form of conventional (i.e. non-ppp) delivery y the State. The PSC is expressed in terms of the net present cost to the State, calculated using discounted cash flow analysis and seeks to take full account of the costs and risks of that method of procurement. The PSC includes amounts to cover oth the design and construction costs and the maintenance, operation and facilities management costs during the Project Term. The net present cost of the service payments to e paid to AquaSure is compared with the PSC. If it is lower than the PSC, it indicates that the id represents value for money. Tale 1 Pulic Sector Comparator Components of the Pulic Sector Comparator (PSC) Hypothetical, risk-adjusted estimate of the most efficient, likely and achievale form of pulic sector delivery. Capital Costs Operating and Asset Replacement Costs (27 years) Raw PSC Transferred Risk Competitive Neutrality PSC Net Present Cost $m (150 GL output per annum) 3,272 2,602 5,874 782 0 6,656 Note the assumptions used to calculate the PSC include: all numers are expressed in net present values as at 30 June 2009. discount rate of 7.3% (Real) to reflect the nature of the Project discounting asis: annual, period end. the transferred risk calculation of $782 million refers only to the risks transferred to the private sector under the Partnerships Victoria arrangements (i.e. those risks that the State would otherwise assume) and excludes the State s estimates of its retained risks) the competitive neutrality adjustment removes any net competitive advantages that accrue to a government usiness y virtue of its pulic ownership Tale 2 - Quantitative value for money comparison etween pulic and private sector delivery as at Financial Close Pulic Sector Comparator (Net Present Cost) AquaSure s Winning Bid (Net Present Cost) Saving $6,656 million $5,720 million 14.1% 9
The $5,720million includes design and construction costs, asset replacement, all maintenance and operating costs such as power, 100% renewale energy credits and chemicals (over the 30 year and 1 month contract). This cost takes into account and provides for the fact that the Project is fully privately financed, and assumes annual output of 150 GL of desalinated water per annum during the operating period and covers all components of the project ie the Plant with marine intake and outlet tunnels, the 84km Transfer Pipeline and Booster Pump station, the 87km underground power supply and other works required under the contract. The $5,720million NPC represents a cost of $1.37 per kilolitre, in June 2009 dollars, on the assumption that the plant operates to produce its required capacity of 150 GL per annum for 27.75 years. The Project Deed requires the project assets to e handed ack to the State at the end of the 30 year and 1 month Project Term, for no additional payment y the State. In addition, on handover, the project assets are required to have a specified residual life in order to ensure that they are in good working condition. Many of the project assets are to have a design life longer than the Project Term, such as tunnels and pipelines which have a 100 year design life and the desalination plant uilding which has a 50 year design life. If the cost of running the plant and other project assets at 150 GL per annum for a 50 year period is considered (20 years after handover to the State) the real cost of water per kilolitre of $1.37 has een estimated to reduce y around 40%. Additional value for money enefits The net present cost of the successful AquaSure proposal is approximately 14% elow the PSC, which is a key indicator that the Project delivers value for money for the State. However, this comparison does not recognise a range of other significant value for money elements provided y AquaSure s Final Proposal including: the certainty of the long term energy and renewale energy offsets; the certainty of the use of almost identical technology to that successfully deployed in other desalination plants constructed and operated y memers of the AquaSure consortium; the design amenity delivered y the ground reaking design, with full integration of the plant into the local coastal environment including a living green roof on the process plant, recreational trails, wetlands and one of the largest ecological restoration programs with more than 150,000 tress and millions of plants; a high speed communications cale along the entire length of the Transfer Pipeline, which will facilitate roadand access to the region; and the enefit of the underground power solution delivering visual amenity to properties crossed y the power supply. 1.5 Pulic interest considerations The Partnerships Victoria guidelines require that the pulic interest e considered from the early stages of the options appraisal process. The Project usiness case (prepared in Septemer 2008), provided a detailed analysis of pulic interest issues, and the test was revisited in the context of the Final Proposals received from the shortlisted idders in July 2009. Based on the assessment of the pulic interest element and the procurement of the Project, it was concluded that the Project can adequately protect the pulic interest. Appendix 4 provides further detail on the final Pulic Interest Test. 10
1.6 Project milestones The following tale outlines the major milestones for the Project. Tale 3 - Key date summary Key Event Date Contract Close 30 July 2009 Financial Close 02 Septemer 2009 Commercial Acceptance (water delivery) 19 Decemer 2011 Reliaility Testing January June 2012 Contract expiry date 30 Septemer 2039 11
Part Two: Key commercial features Part Two of the project summary outlines the contractual relationships etween the parties involved in the Project, including the allocation of risk and the oligations of oth AquaSure and the State. In some areas, it provides more detail on the issues and topics that have een discussed more generally in Part One. 2.1 Parties to the contract On 30 July 2009, the Premier and the Minister for Water announced that the AquaSure consortium had een awarded the contract for the Project. AquaSure Pty Ltd and related entities were specifically incorporated for the Project and entered into Project Documents with the State for the Project. AquaSure has sucontracted its design and construction oligations to its D&C Contractor and its operation and maintenance oligations to its O&M Contractor. The key parties to the contracts are summarised elow: The State - The State is the contracting entity for the Project and is a signatory to the Project Deed and other ancillary documents. The Minister for Water is the person empowered that executed these contracts on ehalf of the State. The Department of Sustainaility and Environment (DSE) - The DSE Secretary is the facilitating agency under the Nomination Order made under section 6 the Project Development and Construction Management Act 1994 (Vic) and pulished in the Victorian Government Gazette, and in that capacity has acquired the Desalination Plant site and certain other land, and using powers delegated y Melourne Water under the Water Act, has acquired the pipeline and power easements, for the purposes of the Project and will grant rights to AquaSure in relation to that land and for other purposes. The Capital Projects Division of DSE is managing and facilitating the Project on ehalf of the Secretary. AquaSure - AquaSure is the entity contracted to deliver the Project and is a signatory to the Project Deed and other ancillary documents with the State. Equity providers - Equity for the Project has een sourced from oth domestic and international equity providers. Financiers - AquaSure has arranged for commercial det to e provided y a large group of anks. D&C Contractor - AquaSure has engaged a Thiess Degrémont joint venture to design and construct the Desalination Plant and associated infrastructure. O&M Contractor - AquaSure has engaged a Degrémont Thiess Services joint venture to operate and maintain the Desalination Plant and associated infrastructure. Transmission Line Operator - The State proposes to engage a third party to operate and maintain the HVAC Transmission Line during the O&M Phase of the Project. Electricity and REC provider - AquaSure has engaged AGL to supply the electricity and renewale energy requirements of the Desalination Plant and associated infrastructure during the O&M Phase of the Project. 12
2.2 Contractual relationships The State has contracted with a single entity, AquaSure, to deliver all aspects of the Project. The relationship etween the State, AquaSure and other related parties is detailed in the Project Deed and associated documentation. The following diagram sets out the structure and principal agreements required for the delivery of the Project: Figure 2 - Contractual Structure Direct Deeds The State Direct Deeds Project Deed Leases and Licenses State Security Thiess Degremont JV (D&C Contractor) D&C Contract AquaSure (Project Co) O&M Contract Degremont Thiess JV (O&M Contractor) Det Financiers Equity Providers Financing Documents HVAC Operation Agreement Transmission Line Operator REC Contract Electricity Supply Contract AGL (REC provider) AGL (electricity provider) 2.3 Risk transfer The following risk summary outlines the risk allocation under the Project Documents. Tale 4 - Risk Summary Type of Risk Description State AquaSure Site Risks Land acquisition Key Approvals Risks associated with acquiring interests in land required for Project Co s design accepted y the State (as identified at Contractual Close). The risk of delay in otaining, or delay to the Project resulting from legal action, revocation or amendment of, specified Key Approvals for the Project. Other approvals Site conditions All risks of otaining any other necessary approvals, consents, permits, licences, etc for the Project, including any additional cost or delay to the Project in otaining those approvals, or if those approvals are suject to unanticipated and onerous conditions, or are challenged. Risks of geotechnical, marine and other site conditions. 13
Type of Risk Description State AquaSure Environmental contamination Risk of contamination on Project sites. Native Title claims and artefacts Scope Risks Output specification / Project Requirements Risk of cost and delay if native title claims are made or native title is found to exist, or if work must e suspended due to the discovery of artefacts on the site. Risk that the State s output specification (as set out in the Project Requirements) does not meet the State s requirements, including if the capacity of the Project is not adequate to meet Victoria s needs. Design, Construction and Commissioning Risks Design and construction risk Risk that the design, construction and commissioning of the Project cannot e completed on time or to udget (other than as specified elow), or that the Project (as uilt) does not meet the State s output specification resulting in delayed or reduced service to the State. Force Majeure Events and Extension Events Risk of delay to completion and increased construction costs caused y force majeure events or specified extension events (State risk items) such as State reach, court decisions preventing the Project and change in law. Power supply infrastructure Risk that sufficient power supply infrastructure is availale to supply electricity during the construction phase. Water supply system connection risk Risk that there is a delay to completion of the Project and commencement of delivery of water attriutale to a delay in Melourne Water completing the preparatory works at the main delivery point near Cardinia Reservoir. Operational Risks Operation, maintenance and repair Risk that the requirements for operation, maintenance and repair to meet the State s specification are different or cost more than anticipated (suject to the risks identified elow). Design risks Risk that the design and technology are incapale of delivering Project services at required service levels. Input seawater characteristics Risk associated with the characteristics of input seawater. Output volume and quality risk Risk that the quantity and quality of desalinated water supplied to the Delivery Points does not meet the State s requirements. Discharge risk Risk associated with EPA or any other requirements existing at Contractual Close 14
Type of Risk Description State AquaSure concerning the quality and rate of environmental discharge, including diffusion of concentrate or sludge discharge. Power supply risk Risk that sufficient power supply is availale to supply electricity during the operation phase. Electricity and renewale energy credits consumption and costs Risk that the cost and consumption of electricity and renewale energy credits required for the Project differs to that anticipated. Water supply system Risk that the State s water supply system is unavailale for a prolonged or unanticipated period of time to receive desalinated water from the Project. Water supply system damage Risks of damage to the State s water supply system caused y the Project. Force majeure Risk that force majeure events affect the Project during the operating phase. Industrial Relations Industrial action Risks of all strikes or industrial action, except as identified elow. Risks of strikes or industrial action directed at the Project during the construction or operating phase, if it can e reasonaly demonstrated that the action results from a wrongful act or omission of the State directly in connection with the Project. Asset Risk Asset ownership, maintenance and life span Upgrades due to technological innovation Handover risk Change in Law Specified changes in law Risks associated with the maintenance and ownership of assets including the requirement to maintain assets in order to deliver the Project services, and that Project assets do not have the required asset lives. Risks associated with implementing Project upgrades consistent with market practice. Risks associated with satisfying the State s requirements regarding asset condition and residual design life at the end of the Project Term. Specified changes in law, including changes to Part IVAA of the Wrongs Act 1958 (Vic), changes to reference documents set out in the State s Project Requirements, implementation of the caron pollution reduction scheme, enactment of the draft Environmental Protection Regulations for Industrial or Prescried Waste or the Fair Work Bill 2008, changes in tax law, or other changes 15
Type of Risk Description State AquaSure reasonaly foreseeale when the contracts were entered into. Other changes in law Risk of other changes in law. Sponsor and Finance risk Interest rate and foreign exchange risk prior to Financial Close Risk of movements in interest or foreign exchange rates etween id sumission and Financial Close. Interest rate and foreign exchange risk after Financial Close Risk of movements in interest or foreign exchange rates after Financial Close. Cost movements prior to Financial Close Risk of movements in the cost etween id sumission and Financial Close. Construction phase insurances Operations phase insurances Risk of changes to pricing of construction phase insurance. Risk of changes to pricing of operations phase insurance. 2.4 General oligations of the contractor In summary, AquaSure s oligations under the Project Documents are to finance, design, construct, commission, operate, maintain and handover the Desalination Plant over the Project Term. The major oligations of AquaSure under the Project Documents include: to finance and/or procure financing for the Project; to design, construct and commission the Desalination Plant, Transfer Pipeline and HVAC Transmission Line; to operate, maintain and repair the Desalination Plant and Transfer Pipeline for the Project Term, and handover that infrastructure to the State at the end of the Project Term; to handover the HVAC Transmission Line to the State upon completion of reliaility testing; and to offset 100% of the Project s energy usage during the O&M Phase with renewale energy. 2.5 General oligations of the State The State s oligations under the Project Deed include oligations to: deliver the land required for the Project; estalish and facilitate a community liaison group to seek to ensure stakeholder and community involvement in the Project; 16
notify AquaSure of the volume of desalinated water to e delivered in the following year; make payments to AquaSure in accordance with the Project Deed (suject to any applicale aatements); procure that Melourne Water construct the preparatory works at the main Delivery Point and that Melourne Water and other Water Authorities whose systems are connected to the Project comply with operational protocols agreed etween the State, AquaSure and those Water Authorities regarding the delivery of water at Delivery Points; and to repay the HVAC Supported Facility. The HVAC Transmission Line will e handed over to the State (or its nominee if the State elects to sell the HVAC Transmission Line to a third party operator) and the State will provide consideration for the asset y repaying the facility drawn down to fund construction costs. 2.6 Government service payments The Project Deed sets out the asis on which the State is required to make payments to AquaSure. The State only pays for water it receives, up to the amount of water ordered y the State. Service payments from the State commence once Preliminary Commercial Acceptance (PCA) is reached, and then step up as Commercial Acceptance is reached, and reliaility testing of the Desalination Plant is completed. Payments then continue on a monthly asis throughout the Project Term. Monthly service payments are made up of two key elements: a security element that is paid to the extent the Project delivers water that is ordered, or is capale of delivering 150 GL per annum of desalinated water at the required quality; and a usage payment that relates specifically to the volume of desalinated water delivered to the State each month. The State does not pay any usage payment for any volume of desalinated water delivered that exceeds the amount ordered, nor for any desalinated water that is ordered ut not received. If performance does not meet the State s requirements, either in terms of quality of service or quantity of water delivered, the payment mechanism contains an aatement regime (discussed elow) which aates the payments proportionately (including proportionate to volume produced as a percentage of volume ordered) and provides an incentive for AquaSure to remedy any poor performance as quickly as possile. 2.7 State contriutions Land The State has granted, or procured the grant of, leases and licences over the various parts of the Project area (as appropriate given the nature of the various parcels of land), including a lease over the Desalination Plant site for the Project Term and licenses for the pipeline and power easements. The Desalination Plant site was acquired in the name of the DSE Secretary, while Melourne Water s powers under the Water Act were utilised to acquire rights over the parcels of land for the Transfer Pipeline and power easements. The State has otained all Key Approvals and will manage all land acquisition and compensation matters for the Project under the Land Acquisition and Compensation Act 1986 (Vic). 17
Finance The gloal financial crisis has made it very difficult for project financing in Australia and all around the world. Despite this, the Project team (in collaoration with Treasury officials and Treasury Corporation of Victoria) has developed ground reaking funding structures resulting in high volumes of committed equity and det eing secured for the Project at the time of the Final Proposals in July 2009. Det and equity was sourced oth domestically and internationally. The Project is the largest PPP financing of the last twelve months, during the gloal financial crisis (GFC). Other major PPP projects which have closed since the GFC commenced, such as Greater Manchester Waste, M25 widening, A2 Poland, and Liefkenshoek Rail Tunnel, have all contained a mixture of State co-funding, guarantees and other forms of government liquidity support. The funding solution for this Project included State support for syndication in the form of a guarantee, under which the State would effectively act as a lender of last resort if the det which was to e syndicated (slightly under half the senior det) was not completely sold down (State Syndication Guarantee Facility). The syndication process is now complete and that det was successfully sold down, so the State Syndication Guarantee Facility was not called upon and there is no residual risk for the State in respect of syndication of the det or under that guarantee. Given the HVAC Transmission Line will e financed, designed and constructed y AquaSure, and then handed ack to the State on completion of construction and reliaility testing, the State provided a repayment guarantee for the dedicated det facility for construction of the HVAC Transmission Line. This can only e drawn down as that infrastructure is actually constructed, suject to a cost-to-complete test (HVAC Supported Facility). It is intended that the HVAC Supported Facility will e paid out y the proceeds of the sale y the State of the HVAC assets, which may e accomplished through a separate tender process y the State, to e completed efore 2011. 2.8 Performance measures and aatement If the Project does not meet the State s requirements for water quality, availaility of desalinated water and a numer of other defined key performance indicators (including nonwater related performance indicators, such as noise levels), the service payments otherwise payale to Project Co will e aated. The aatements proportionately increase with the severity or repetition (or oth) of failures to meet the key performance indicators. Non Availaility or Partial Availaility The availaility of the Project to deliver desalinated water will e judged on: its actual performance in delivering the volume of desalinated water ordered y the State; and direct testing of the potential future aility of the Project to deliver the guaranteed supply capacity (150 GL) if requested y the State. An aatement will e made if AquaSure fails to deliver the ordered amount of desalinated water for a supply period (in which case the quantum of the aatement will e proportional to the amount of the shortfall) or if the Project is not capale of producing 150 GL per annum (in which case an aatement fixed at a predetermined (indexed) amount will e applied). 18
Poor Performance Aatements will also e made to the monthly service payments payale to AquaSure (comprising oth the water security payment and water usage payments discussed aove) for failing to meet the State s required performance standards in relation to water quality, environmental management, general operation, social and community requirements and other Project Deed oligations. Aatements for failure to meet the specified performance standards will e calculated as a monetary amount per incidence of failure with increases in the quantum of the deduction depending on the frequency and size of the failure. In the case of failures in water quality, additional parameters have een defined on which the State may refuse to accept and pay for desalinated water. In this situation, no variale (usage) payment will e made y the State and water will not count towards the volume of water ordered. 2.9 Default and termination regime The State has rights to terminate the Project Deed, suject to certain conditions and notice requirements: for default y AquaSure, if an event of default is not remedied within applicale cure periods, if AquaSure is not diligently pursuing a cure of an event of default, or if completion is not achieved y the applicale date specified in the Project Deed (in each case, suject to det and equity cure periods, as provided for in the Finance Direct Deed); if there is a susisting force majeure event; or at any time, on 60 Business Days notice to AquaSure (regardless of whether or not there has een any default or reach of a Project Document y AquaSure). AquaSure may terminate the Project Deed, suject to certain conditions and notice requirements, if there is a susisting force majeure event (ut not in any other circumstances). Upon termination, the State will pay AquaSure a termination amount. The asis for calculation of the amount varies depending on the cause of the termination. For example, if the Project is terminated for AquaSure default, the State will only pay the market value of the Project at that time as reduced in value y AquaSure s default. In addition, if AquaSure reaches an oligation under the State Project Documents, the State may exercise its step-in rights to remedy the reach. 2.10 Finance and security arrangements Funding package The funding package for the Project included: senior commercial det in the form of nominal ank det; mezzanine det in the form of nominal ank det; State supported det in the form of the State Syndication Guarantee Facility [(now no longer provided)] and the HVAC Supported Facility; and 19
a mix of sponsor and third party equity investment. The State has security over all of AquaSure s rights and interests in the Project, in order to secure AquaSure s oligations to the State under the contract, including the right to step in. The security enales the State to appoint a receiver over all or part of the secured assets. The Project s financiers hold, via a Security Trustee, a suite of securities in relation to the Project including a fixed and floating charge over the assets of AquaSure. The rights and priorities as etween the State and the Security Trustee are reconciled in the Financier Direct Deed Gloal Financial Crisis The State has provided limited and specific support for the Project to address the prospect of there eing significant adverse developments in the financial markets in the future which affect the det funding of the Project. This support takes three forms: the State will share the risk of refinancing losses equally with AquaSure. However, the State will also share to a significant extent in refinancing gains; the State will share the risk of the funding costs due to market disruption of more than a specified percentage of the senior det increasing aove market rates, with the State having the right to recover extra costs through future refinancing gains; if the financial markets will not support a refinancing of the initial det at the time that det is scheduled to expire, ecause of significant market dislocation, then the State will provide support through adopting one of a numer of options, including: procuring alternative funding; procuring a State-supported guarantee for the det funding; termination of the Project Deed and payment of the relevant termination payment; pay out of the alance of any unrefinanced det; and any other agreed arrangement. 2.11 State rights at expiry of contract At end of the Project term, AquaSure is required to hand over the Desalination Plant and associated infrastructure to the State, at no cost. The State may require AquaSure to carry out joint inspections with the State up to three years prior to the end of the Project Term (and at 6 monthly intervals until the end of the term). The State and AquaSure will agree (or seek independent determination of), a schedule of maintenance and repairs (if any) needed to ensure the Desalination Plant and associated infrastructure meets the required handover conditions (including residual design lives for particular assets), the cost of any such maintenance and repairs, and a program for carrying out any works required. To provide the State with certainty that it will receive a properly maintained Desalination Plant and associated infrastructure at handover (or the funds to ring the Project up to the required standard if there are any deficiencies), AquaSure must either deposit funds into an escrow account or provide the State with a ond, to the value of the estimated cost of maintenance and repairs. 20
2.12 Process for Government modification of services / facility The Project Deed provides for modifications, which may e initiated at any time y either the State or AquaSure. If the State proposes a modification, AquaSure must provide a notice setting out details of the effect of implementing the modification, including the cost of the modification, any approvals required and the effect on timing of completion or delivery of water. A full list of the matters that must e detailed in such a notice is set out in the Project Deed. The State will then elect whether or not to proceed with implementation of the modification. The State will pay for the modification (unless otherwise agreed with AquaSure) either y way of a lump sum or adjustment to the payments to e made under schedule 1. The State will receive 100% of the enefit of any costs savings resulting from the modification. If AquaSure proposes a modification, the modification can only e implemented with the State s approval. Any savings resulting from the modification are shared equally etween AquaSure and the State. This provides an incentive to AquaSure to identify and propose variations which reduce the overall cost of the Project. 2.13 Future Technology Improvement The Project has adopted leading edge technology and practices for memrane efficiency and energy efficiency. Over time, there will e advances in the technology used in desalination plants (for example, new, more efficient memrane models). Significant enefits may e achieved y upgrading the Desalination Plant and associated infrastructure to utilise new technology (oth in terms of cost savings and efficiency or environmental enefits), however there will also e an associated cost of implementing that technology. The Project Deed alances these considerations to achieve the est value for money outcome, while retaining flexiility for Project Co and the State to weigh the costs and enefits of new technology on a case-ycase asis. AquaSure must maintain a level of technology in the Desalination Plant and associated infrastructure that is consistent with O&M est practice and ensures the system is ale to operate effectively and efficiently with the Victorian water and electricity networks. If AquaSure implements new technology, AquaSure and the State will share any resulting cost savings. Alternatively, the State may at any time direct AquaSure to implement new technology, in which case the State will retain the whole of the enefit of any resulting cost savings. 21
Glossary Term AquaSure Commercial Acceptance Desalination Plant D&C Contractor EPA Final Proposals GL HVAC Supported Facility HVAC Transmission Line Intake and Outlet Structures Key Approvals Melourne Water O&M Contractor O&M Phase Partnerships Victoria Preliminary Commercial Acceptance Proity Auditor Definition The AquaSure consortium consisting of Macquarie Group, Degrémont SA, Suez Environnement and Thiess Pty Ltd. The date on which the Desalination Plant and associated infrastructure satisfies the required commissioning tests and commences delivery of water at a rate of 150 GL per annum. The Process Plant together with the Intake and Outlet Structures. The design and construction contractor, eing Thiess Pty Ltd and Degrémont Pty Ltd (jointly and severally). The Environment Protection Authority Victoria. Proposals received on 20 July 2009 in response to the RFP Gigalitre. One thousand megalitres or one illion litres. HVAC supported facility provided for the construction of the HVAC transmission line. The underground high voltage, alternating current (HVAC) electricity transmission line connecting the Desalination Plant to the National electricity grid at Cranourne terminal station. The seawater intake and concentrate outlet pipes which extend underground from the Process Plant (and associated onshore works); and the risers and other associated marine structures that connect to the seawater intake and concentrate outlet pipes. Certain approvals or facilitation under the Environment Protection Act 1970 (Vic), the Environment Effects Act 1978 (Vic), the Environment Protection and Biodiversity Conservation Act 1999 (Cth), the Planning and Environment Act 1987 (Vic), the Coastal Management Act 1995 (Vic) and the Aoriginal Heritage Act 2006 (Vic). Melourne Water Corporation, an entity owned y the government and responsile for managing Melourne s water resources in a sustainale manner and secure supplies for a range of uses. Operations and maintenance contractor, eing Thiess Services Pty Ltd and Degrémont Pty Ltd (jointly and severally). Refers to the period from completion of reliaility testing of the Desalination Plant (RT Finalisation) until the end of the Project Term (whether y expiry or early termination). The State s Partnerships Victoria policy. Further information can e otained on the wesite www.partnerships.vic.gov.au. The date on which the Desalination Plant and associated infrastructure satisfies the required commissioning tests to demonstrate an output capacity of 50 GL per annum. Upon achievement of this milestone, AquaSure can commence delivering water to the State and receive payment for that water. An auditor appointed to audit and report on the fairness of the tender process. 22
Term Definition Proity Adviser Proity Plan Process Plant Project Pitcher Partners, engaged to advise the DSE project team on, and monitor, the procedural integrity and fairness of the tender process. A plan identifying the proity principles for the Project and specific rules which were required to e followed y the Project Team in delivering the Project. The pre-treatment, reverse osmosis treatment and posttreatment processes which comine to produce desalinated water suitale for drinking. The, comprising: financing, design, construction, commissioning, operation, maintenance and handover of the Desalination Plant and associated infrastructure; and financing, design, construction, commissioning and handover of the HVAC Transmission Line, in accordance with the State Project Documents. Project Deed The agreement etween the State and Project Co dated 30 July 2009 (as amended from time to time) which estalishes the rights and oligations of the Project Co to finance, design, construct, commission, operate, repair, maintain and handover the Project. Project Documents The Project Deed; Project Term Pulic Interest Test the lease over the Process Plant site; the licences for construction works and operation over the Transfer Pipeline land and land for the associated ooster pump station; the licences over Crown land where the Intake and Outlet structures are located; the Independent Reviewer & Environmental Auditor Deed of Appointment; the State Security Deed (under which AquaSure grants the State security over its assets) and the Finance Direct Deed (governing the interface etween the State and the Financiers for the Project, who also hold security over AquaSure s assets); each Direct Deed (eing tripartite arrangements etween the State, AquaSure and key sucontractors of AquaSure); the Financial Close Adjustment Protocol, which identifies the process for updating the documents at Financial Close; and any other document the State and Project Co agree is a State Project Document. The period commencing on the date of Financial Close and concluding on expiry (after 30 years and one month) or early termination of the Project Deed. The Project is required under Partnerships Victoria policy to have considered the elements of the pulic interest test and satisfy the pulic interest assessment. 23
Term Pulic Sector Comparator PPP RFP South Gippsland Water State State Syndication Facility Transmission Line Operator Transfer Pipeline Victorian Government Purchasing Board Proity Policy Water Act Water Plan Westernport Water WorkSafe Victoria Definition The PSC is the estimated, hypothetical, risk-adjusted cost if the Project were to e financed and implemented y the State. The PSC is consistent with the requirements of the output specifications, project requirements and the proposed risk allocation contained in the State Project Documents. Pulic Private Partnership. The request for proposals issued y the State in Septemer 2008, as updated from time to time. Water provider that provides water services in Eastern Victoria for towns and coastal resorts. The State Government of Victoria. A syndication facility supported through a government guarantee to allow for the syndication of state det to commercial parties. The contractor which will e appointed to operate the HVAC Transmission Line. The transfer pipeline to connect the Process Plant to the existing Melourne Water supply system near Cardinia Reservoir. Policy from the Victorian Government Purchasing Board which provides guidance to Victorian government employees to help them estalish and maintain high standards of proity in tendering activities. Water Act 1989 (Vic) The Our Water Our Future The Next Stage of the Government s Water Plan, which is the next stage of the Government's Our Water Our Future water plan, the government s long term water plan which alances traditional water sources with new rainfall-independent sources of water such as desalination. Water authority which provides water services to the Westernport district. The manager of Victoria's workplace safety system. 24
Appendix 1: Useful References Project documentation, including the Project Deed, is availale at www.contracts.vic.gov.au Partnerships Victoria policy guidance and project information is availale at www.partnerships.vic.gov.au Details in relation to the Our Water Our Future -The Next Stage of the Government s Water Plan can e found at http://www.ourwater.vic.gov.au 25
Appendix 2: Key Contact Details Department of Sustainaility and Environment Wesite: Address: Email: www.dse.vic.gov.au Level 15, 55 Collins Street Melourne VIC 3000 desalination.project@dse.vic.gov.au AquaSure Pty Ltd Wesite: Address: Email: www.aquasure.com.au Level 7, 492 St Kilda Road Melourne VIC 3004 contactus@aquasure.com.au Partnerships Victoria Wesite: Address: www.partnerships.vic.gov.au Department of Treasury and Finance Commercial Division, 1 Treasury Place Melourne VIC 3002 26
Appendix 3: Evaluation Criteria The following matters were advised to the shortlisted idders as potentially eing relevant to evaluation. A. Technical The State may evaluate: The technical solution including fitness for purpose. The design and construction methodology including the extent to which the Proposal: provides certainty of delivery of the Desalination Plant, the Transfer Pipeline and the power supply in terms of time, cost and quality. addresses safety and industrial relations. The operation and maintenance methodology. The response in respect of the Proof Engineer, Design Reviewer and Rehailitation Consultant (eing the specialist consultants who will verify compliance with the key aspects of the Project Requirements). The response in respect of the Independent Reviewer & Environmental Auditor. B. Industrial Relations and Occupational Health and Safety The State may evaluate the shortlisted idders proposed approach to workplace and occupational health and safety issues (including occupational health and safety) throughout the design, construction and operation and maintenance phases. Shortlisted idders are to demonstrate what steps they would take to support all workplaces in connection to the Project to e fair, cooperative and innovative workplaces, including information on opportunities which will e availale for the promotion of training and skills formation in relation to the Project. Shortlisted idders are required to set out the provision and skills for estalishing and maintaining the highest levels of health and safety throughout the delivery and operation of the Project; in particular, the steps which the shortlisted idder will take to ensure that any occupational health and safety issue that arises in connection with the Project is resolved fairly and efficiently. A shortlisted idder should also identify how it will ensure that any employee working in connection with the Project who suffers illness or injury as a result has access to effective rehailitation, including mechanisms to ensure employee consultation and representation in occupation health and safety throughout the Project. Shortlisted idders are required to set out specifically the experience and capacity of shortlisted idders to manage industrial relations and occupational health and safety. Shortlisted idders are also required to explain in detail how they plan to identify and manage industrial relations. 27
C. Community involvement and stakeholder management The State may evaluate the shortlisted idder s proposed community involvement and stakeholder management methodologies including the extent to which the Proposal addresses community and stakeholder issues throughout the design, construction and operation and maintenance phases. Shortlisted idders are required to provide the outline Community Involvement Plan. Shortlisted idders are required to provide a list of stakeholders identifying the key issues and propose strategies to deal with those issues. Shortlisted idders are required to provide detailed information in relation to the approach of a shortlisted idder to engaging with local and regional industries and services and to providing opportunities to engage suitaly trained local and regional human services. D. Environmental management The State may evaluate: the proposed environmental management methodology including the extent to which the Proposal addresses environmental requirements throughout the design, construction and operation and maintenance phases; and the proposed design in terms of the extent to which the Proposal addresses the environmental requirements throughout the design, construction, operational and maintenance phases. E. Commercial The State may evaluate: the commercial solution including the nature of the legal and commercial relationships etween the: Project sponsors, equity and det providers; and Project Co, the D&C Contractor, the O&M Contractor and any other contractors, such as the provider(s) of technology, power supply and RECs (as appropriate); and the nature and extent of the proposed commercial departures from the State s preferred position as set out in the draft State Project Documents including the extent to which these departures impact the aility to achieve Contract Close and Financial Close within the State s preferred timeframes. F. Financial The State may evaluate: the appropriateness, competitiveness and flexiility of the funding structure; the certainty of the funding structure as evidenced y the level of commitment demonstrated, the approvals otained y all providers of det, equity and other forms of finance and the asence of circumstances in which funding may e repriced or commitments may lapse, whether for Project specific or financial market reasons, and regardless of financial market practice in relation to such matters; the financial strength of the party(s) that would contract with the State (or party(s) providing financial support for the party that would contract with the State) for the Project; and 28
the roustness of the financial projections for the Project. This will include, ut not e limited to, a review of the assumptions relating to construction costs, ongoing life cycle maintenance, operational costs, working capital, accounting treatment, taxation and availaility of capital allowances. G. Risk adjusted cost The State proposes to evaluate the whole of life, risk-adjusted cost of a Proposal taking into account the financial and risk consequences for the State. H. Conformity with the RFP The State will consider the extent to which the proposal schedules have een adequately completed, and the extent to which each proposal complies with the RFP. I. Compliance with the Victorian Industry Participation Policy The Victorian Industry Participation Policy (VIPP) Statement completed y each shortlisted idder will e assessed and used in accordance with the guidelines issued under the prevailing policy. J. Proity investigations The State may take into account any matters revealed as a result of its proity and security investigations in evaluating proposals. K. Conflicts of interest The State proposes to evaluate the nature of any actual or perceived conflicts of interest and how effectively the shortlisted idder has managed any such conflicts. 29
Appendix 4: Pulic Interest Test Pulic Interest Issues Protecting the pulic interest entails an assessment of the impact of the Project on the following eight elements of pulic interest: Effectiveness Accountaility and transparency Affected individuals and communities Equity Consumer rights Pulic access Security Privacy Summary of the Pulic Interest Test The determination of whether the pulic interest can e adequately protected under either or all of the procurement options requires a judgement of: whether the failure to adequately protect any individual pulic interest element is a significant concern; and whether it outweighs, on its own or together with other failures, the enefits to the pulic interest arising from the potential project eing delivered under the recommended procurement option. Assessment Set out elow are some aspects of the detailed pulic interest test assessment. Pulic interest element Standard Assessment Effectiveness Is the project effective in meeting government ojectives? Relevant policies and strategies include: Our Water Our Future -The Next Stage of the Government s Water Plan. Key Element: Development of a nonrainfall dependent source of water to meet Victoria s future water requirements. Other relevant policies: Melourne 2030; and The Project is consistent with the overarching ojective of the Our Water Our Future -The Next Stage of the Government s Water Plan to provide water security for Victoria s growing population and economy in the face of drought and the challenge of climate change. The Project is a key element of the water plan which includes: Diversifying and oosting water supplies in Melourne, including 30
Pulic interest element Standard Accountaility and transparency Do the proposed procurement arrangements ensure that: The community can e well-informed aout the oligations of Government and the private sector partner; and These can e overseen y the Auditor-General. Growing Victoria Together. Note that the overarching Project Ojectives have, where relevant, een informed y roader government ojectives. Policies and responsiilities relevant to accountaility and transparency include: Partnerships Victoria; Victorian Government Purchasing Board Proity Policy; Freedom of Information Act 1982; Financial Management (Financial Responsiility) Act 2000; and Auditor General Victoria. Assessment through desalination; Networking the State s water resources in a Victorian Water Grid; and Enaling a rapid and flexile response to changing future water needs. The State s tender evaluation process has had regard to the overarching Project ojectives. Pitcher Partners has een engaged as an independent proity auditor to oversee the procurement of the Project. The FOI Act will apply. Participants in the Project recognise the disclosure requirements under the FOI Act. The procurement processes for the Project were designed to e fair and transparent providing equal opportunities to private sector contractors whilst ensuring the est outcome for the Project and the State. A Project Summary document required under the Partnerships Victoria Pulic Disclosure Policy has een released within 3 months of Financial Close. Affected individuals and communities Have those affected een ale to contriute effectively at the planning stages, and are their rights protected through fair appeals processes and other conflict resolution mechanisms? The Victorian Government is committed to open and effective community engagement. Engagement strategies have een estalished at many levels, including with local councils. The Project has also undergone assessment under the Environment Effects Act and approval under the EPBC Act. These processes have enaled affected individuals and communities to contriute effectively. The following are key stakeholders in the Project (note that this is not an exhaustive list): Victorian water users Local residents, community groups and organisations Affected land owners Government departments (Department of Sustainaility and Environment, Department of Premier and Cainet and Department of Treasury and Finance); Memers of parliament, oth state and federal. 31
Pulic interest element Standard Assessment Equity Are there adequate arrangements to ensure that disadvantaged groups can effectively use the infrastructure or access the related service? Pulic access Are there safeguards that ensure ongoing pulic access to essential infrastructure? The Project ojectives are focused on creating a nonrainfall independent source of water to assist in meeting Victoria s water requirements. Project does not impact on access to essential infrastructure. The Project Team consulted directly with landowners whose properties are within the Project Site and Transfer Pipeline and electricity grid connection route alignments to arrange land acquisition and compensation in accordance with State Government laws. The State has followed the requirements of the Land Acquisition and Compensation Act 1986. This Act was estalished to ensure landowners are fairly compensated for expenses associated with the acquisition or access to land. Under the Act, the State is required to pay reasonale costs to an affected landowner for valuation and legal representation, and compensation for any loss incurred as a result of any Project construction on their land. The State has completed extensive pulic consultations as part of the environmental approvals processes. Given that water produced y the Project will e pumped in to Melourne s existing water supply system to Cardinia Reservoir (which services users in Melourne) and towns in the Westernport and South Gippsland region, access or use restrictions meet the pulic interest. Pulic access to the Project site at Wonthaggi during construction and operations will e restricted to ensure the facility remains secure. Access to the adjacent coastal reserve will e unaffected y the Project during oth construction and operations. 32
Pulic interest element Standard Consumer rights Does the project provide sufficient safeguards for service recipients, particularly those for whom Government has a high level of duty of care, and/or the most vulnerale? This Project is different to an accommodation ased project where Government may have a duty of care in the delivery of certain core services. Assessment The Project s service recipients are the general pulic and commercial water users. Monitoring processes and quality reviews will e in place to ensure that water quality is safeguarded at all Delivery Points along the transfer pipeline. Security Does the project provide assurance that community health and safety will e secured? Privacy Does the project provide adequate protection of users rights to privacy? Relevant standards and policies in relation to the Project include: Occupational Health and Safety Act 2004 (Vic) Numerous environmental standards Environmental Management Plan World Health Organisation Water Quality Standards Water Act 1989 (Vic) Water Industry Act 1994 (Vic) Safe Drinking Water Act 2003 (Vic) State s duty of care to the pulic Minimum performance requirements consistent with output specification oligations and contracts will e required of the service provider. Freedom of Information Act 1982 (Vic) Information Privacy Act 2000 (Vic) Health Records Act 2002 Federal Privacy Act 1982 The Project will e required to comply with health and safety and water quality specific legislation. The contract includes performance standards required of the Project Co. The FOI Act gives people a right of access to information held y the State Government. 33
Conclusion The conclusions reached from the assessment of the pulic interest test are: the Project implements a numer of State ojectives and policies, including those specifically related to the government s Water Plan and the identified need to develop a non-rainfall dependant source of water for Victoria; the contractual arrangements are transparent and ensure that the community will e well informed aout the responsiilities of the parties. In particular, Victorian Government Purchasing Board Proity Policy and Best Practice Proity Advice guidelines have een applied, including the appointment of a Proity Auditor and a Proity Advisor during the procurement process. The Project documents to which the State is a party have een pulished in accordance with Partnerships Victoria policy, suject to confidentiality provisions of the Freedom of Information Act 1982 (Vic). The Auditor-General will have access to information relating to the Project; key stakeholders (including affected land owners and occupiers) have een sought to e consulted throughout the procurement process, and a communications strategy is in place for the implementation phase; all parties to the Project will e required to comply with the relevant equity laws; the Project does not affect access to essential infrastructure nor does it impact on consumer rights; AquaSure must comply with Victorian legislation, aspects of which will e enforced y WorkSafe Victoria and the EPA, to seek to ensure that community health and safety are secured; users rights to privacy (including commercially sensitive information) are protected; and the value for money and pulic interest disclosure requirements under the Partnerships Victoria Disclosure Policy (released in March 2007) and Partnerships Victoria Requirements (Feruary 2009) are met. 34
Wesite: www.partnerships.vic.gov.au Copyright State of Victoria 2009 This pulication is copyright. No part may e reproduced y any process except in accordance with the provisions of the Copyright Act 1968. Pulished: Novemer 2009