Causes of delay and cost overruns in construction of groundwater projects in a developing countries; Ghana as a case study
|
|
- Brook Oliver
- 8 years ago
- Views:
Transcription
1 International Journal of Project Management 21 (2003) Causes of delay and cost overruns in construction of groundwater projects in a developing countries; Ghana as a case study Yaw Frimpong a, *, Jacob Oluwoye b, Lynn Crawford c a 1/9-11 Oxford Street, Merrylands, NSW 2160, Australia b University of Technology Sydney, PO Box 123, Broadway NSW, 2007 Sydney, Australia c Project Management Program, University of Technology Sydney, PO Box 123, Broadway NSW, 2007 Sydney, Australia Received 28 June 2001; received in revised form 19 September 2001; accepted 27 September 2002 Abstract Delay and cost overruns are common in construction projects and groundwater construction projects in Ghana are not an exception. The paper presents the results of a questionnaire survey conducted to identify and evaluate the relative importance of the significant factors contributing to delay and cost overruns in Ghana groundwater construction projects. Respondents of this survey included personnel from owners, consultants and contractors involved in groundwater projects in Ghana. The results of the study revealed the main causes of delay and cost overruns in construction of groundwater projects included: monthly payment difficulties from agencies; poor contractor management; material procurement; poor technical performances; and escalation of material prices. Hence, effective project planning, controlling and monitoring should be established to enhance project performance in order to minimise or avoid delay and cost problems in groundwater construction projects. # 2003 Elsevier Science Ltd and IPMA. All rights reserved. Keywords: Project management; Groundwater projects; Construction; Overruns; Ghana; Developing countries 1. Introduction Project success can be defined as meeting goals and objectives as prescribed in the project plan. A successful project means that the project has accomplished its technical performance, maintained its schedule, and remained within budgetary costs. Project management tools and techniques play an important role in the effective management of a project. Therefore, a good project management lies in the management tools and techniques used to manage the project. Project management involves managing the resources workers, machines, money, materials and methods used [1]. Some projects are effectively and efficiently managed while others are mismanaged, incurring much delay and cost overruns. A construction project such as groundwater comprises two distinct phases: the preconstruction phase, * Corresponding author. address: yawfrimpong@hotmail.com (Y. Frimpong). (the period between the initial conception of the project and signing of the contract; and the construction phase which is the period after award of the contract when the actual construction is going on) [1]. Delay and cost overruns occur in both phases however, major causes of project overruns usually take place in the construction phase. Therefore, this paper is limited to this phase. Previous studies show extensive information on project schedule delays and cost overruns [2 7]. This paper identifies and examines the causes of delay and cost overruns in the construction of groundwater projects. The study is based on data relating to groundwater construction projects in Ghana. There are many factors that can cause delay and cost overruns in groundwater drilling projects. These range from factors inherent in the technology and its management, to those resulting from the physical, social and financial environment. In a preliminary survey conducted in water drilling projects in Ghana, for the purpose of this research, it was found that 33 out of a total of 47 projects completed between 1970 and 1999 were delayed /03/$30.00 # 2003 Elsevier Science Ltd and IPMA. All rights reserved. doi: /s (02)
2 322 Y. Frimpong et al. / International Journal of Project Management 21 (2003) while 38 projects were overruns [8]. The data indicated that 75% of the projects exceeded the original project schedule and cost whereas only 25% were completed within the budget and on time. The survey revealed that delay and cost overruns occur frequently in construction of groundwater projects in Ghana and developing countries in general, especially in long-duration projects. It is therefore important that thorough analysis be carried out to help in efficient project management, to reduce delay, and cost overruns. 2. Nature of groundwater work Groundwater-drilling projects involve the following activities: Groundwater exploration (siting of boreholes) which involves geophysical surveys conducted at the ground surface using highly sophisticated equipment, borehole sampling, and geophysical logging of the borehole with highly sophisticated well-logging equipment. Borehole drilling and construction; which involves drilling, installing the casing, placing a well screen and filter pack, if required, grouting to provide sanitary protection, and developing the well to ensure sand-free operation at maximum yield. Pumping test and water quality analysis: which involves pumping a well at a certain rate, recording the drawdown in the pumping well, monitoring and recording the recovery of the water, and conducting water quality tests. Civil works and exploration: which involves construction of well base pads and installation of appropriate pump. The nature of work in groundwater projects and the environment within which they are built make such projects susceptible to delay and cost overruns. Some of the influential factors can be summarised as followings: Poor technical performance due to improper planning result number of wells abandoned and thereby causes project delay and cost overruns. Work in these projects depends mainly on equipment, plants and materials, project may be delayed without effective and efficient procurement procedures. Numerous series of activities are involved in the water drilling project and reluctant to use of scheduling techniques and update schedules on regular basis are needed. A great deal of coordination among these activities is required to avoid delay especially in public projects. Due to lack of skilful management less attention is paid to resources allocation i.e. human, financial and material resources. In an attempt to identify the reasons for such delays and overruns, an extensive survey was conducted in Ghana. 3. Research aim and objectives This paper identifies and examines the causes of delay and cost overruns in the construction of groundwater projects in Ghana. The objectives are: To study and evaluate the factors that contribute to delay and cost overruns in groundwater construction, To identify the main factors that influence the causes of delay and cost overruns in construction of groundwater projects and to examine their relative importance. 4. Methodology In order to evaluate and analyse the causes of delay and cost overrun in groundwater projects, a wide range of personnel involved in groundwater construction in project Ghana were targeted. Personnel were randomly selected from Ghanaian project managers, consultants, contractors, client s representatives and construction managers. A questionnaire of 26 factors was carefully designed from previous preliminary investigations conducted in groundwater drilling projects between 1970 and 1999 in Ghana. It was organised in the form of a priority scaling (1=very low, 2=low, 3=medium, 4=high, and 5=very high). The questionnaire was directed towards three groups in both public and private organisations: owners of the groundwater projects, consulting offices, and contractors working in the groundwater works. The questionnaire was distributed to a random sample of 55 owners, 40 contractors and 30 consultants. The sample selected for each of the three groups is described below as: Owners comprising the government agency (key decision-makers) responsible for the projects, private organisations (industries), and individual owners. Consultants working in the groundwater construction projects. Contractors who are involved in the groundwater drilling project.
3 Y. Frimpong et al. / International Journal of Project Management 21 (2003) Respondents were from public and private agencies that sponsor groundwater construction projects, and the contracting and consulting organisations that work for them. There were 125 in the group targeted, 72 (57%) questionnaires were returned completed of these: 28 were from owners; 19 from consultants; and 25 from contractors (see Table 1). 5. Data analysis The procedure used in analysing the results was aimed at establishing the relative importance of the various factors responsible for project delay and cost overruns. The score for each factor is calculated by summing up scores assigned to it by respondents. Therefore, the level of importance as indicated by the owners, contractors and consultants were used to measure the relative weight of each factor. The relative weight was computed using the following equation: Relative Importance Weight (RIW)= P 5 i¼1 P N a i n i 100 xj j¼1 where: x j =the sum of the jth factor; j=the factors 1, 2, 3, 4,...N; N=total number of factors (26); a i =constant expressing the weight given to the ith response: i=1, 2, 3, 4, 5 for a response of very high a 1= 5 for a response of high a 2 =4 for a response of medium a 3 =3 for a response of low a 4 =2 for a response of very low a 5 =1 n i =the variable expressing the frequency of the ith response n 1 =frequency of very high responsen 2 =frequency of high response n 3 =frequency of medium response Table 1 Per cent of questionnaire distribution and their response Description Questionnaire distributed Number of respondents Owners Contractors Consultants Total ð1þ Percentage of responses n 4= frequency of low response n 5 =frequency of very low response Eq. (1) was used to calculate the Relative Importance Weight for all delay and cost overruns factors. The Weights were ranked for Contractors, Owners and Consultants. To determine whether there is degree of agreement among the three groups with respect to their rankings of the factors, Kendall s Coefficient of Concordance was used. The Kendall s Coefficient of Concordance says that the degree of agreement on a zero to one scale is: W ¼ 12U 3m2 nn ð 1Þ 2 m 2 ð2þ nn ð 1Þ where: U ¼ Xn j¼1 ðsrþ 2 n=number of factors; m=number of the groups; j=the factors 1, 2, 3, 4,...N. The calculated Kendall s Coefficient of concordance W = In order to know whether there is disagreement or agreement between the three groups on ranking the factors, a test of hypothesis is needed. Null hypothesis: H 0 : Disagreement in rankings among the three groups. Alternative hypothesis: H 1 : Agreement in rankings among the three groups. Since n=26 is too large for the table of critical values of Kendall s, chi-square approximation of the sampling distribution of W is computed with Eq. (3). 2 ¼ kn ð 1ÞW ð3þ Therefore, w 2 =69.06 and using a w 2 critical table for n=26 and a=0.05, the w 2(n 1) a = 225 ð Þ :05 =7.65. Since computed value w 2 is greater than critical table 225 ð Þ :05 null hypothesis H 0 is rejected and alternative hypothesis H 1 is accepted. Therefore, concluded that there is a significant degree of agreement between the three groups with respect to how they rank the factors. 6. Surveyresults and analysis The questionnaire was analysed from contractors, owners and consultants perspective. In order to identify the most important factors that influence time and cost
4 324 Y. Frimpong et al. / International Journal of Project Management 21 (2003) overruns in groundwater projects, the items were ranked in the various groups. On the basis of ranking of the factors by the various groups it was possible to identify the most important factors that influenced project time and cost overruns. A summary of all the factors causing delays and cost overruns in groundwater projects in relative importance weights, ranking by the groups, and overall ranking as identified by all groups is shown in the Table 2. The results show that, there are several important factors underlying causes of delay and cost overruns in groundwater construction projects in developing countries such as Ghana. The five most important factors agreed by the owners, contractors and consultants, as the main causes were (see Table 2) monthly payment difficulties from agencies, poor contractor management, material procurement, poor technical performances, and escalation of material prices. Contractors and consultants ranked the monthly payment difficulties from agencies for completed works first whereas the owners ranked it tenth. This problem may be due to the existing culture in the construction industry. In Ghana, the biggest customer of the groundwater industry is the government and there is very little participation from private investors [8]. Like most developing countries, groundwater projects in Ghana are financed either through domestic savings or foreign funding. Groundwater construction projects funds may be from capital allocation from Ministry of Work and/or foreign assistance which have been budgeted. However, there is delay in payment for the completed work due to bureaucracy in governments departments. Regular monthly payment to contractors for work done removed constraints which otherwise may have impeded project progress to cause delay and cost overruns. Failure to provide adequate funding resources to contractors for the job done will make it difficult for the contractors to meet project objectives [14]. The second most important factor attributing to the cause of delay and cost overruns in groundwater projects is poor contract management. Poor contract management was ranked first by owners, second by consultants, while contractors ranked it sixth (see Table 2). This can be attributed to the way contracts are been awarded. Most cases, projects are awarded to the lowest bidder. Some of the lowest bidders may lack management skills and less attention is paid to contractor s plan, cost control, overall site management, and resource allocation, ie, human, financial and material resources. Evidence from Ogunlana and Olomolaiye [9] and Wahab [11] postulated that many contractors in developing countries are entrepreneurs who are in the business of making money Table 2 Rank of all the factors responsible for project delays and cost overruns according to contractors, consultants and owners Factors Owners Contractors Consultants Overall RIW% RANK RIW% RANK RIW% RANK RANK Planning and scheduling deficiencies Deficiencies in cost estimates prepared Inadequate control procedures Delays in work approval Waiting for information Mistakes during construction Delays in inspection and testing of work Cash flow during construction Frequent breakdowns of construction plant and equipment Shortages of technical personnel Labour shortages Monthly payment difficulties Poor contract management Shortage of materials, Plant/equipment parts Contractor s financial difficulties Low bid Material procurement Imported materials Late delivery of materials and equipment Escalation of material prices Slow decision-making Inflation Difficulties in obtaining construction materials at official current prices Ground problems Bad weather Unexpected geological conditions
5 Y. Frimpong et al. / International Journal of Project Management 21 (2003) at the expense of good management. They pay low wages, submit very low bids and have very little, if any, ability to plan and coordinate contracts. The third significant factor identified was material procurement (see Table 2). It demonstrates a complete absence of effective material procurement management on the part of the contractors. The established bureaucratic structures in material procurement processes in developing countries like Ghana seem to hinder the easy flow of construction materials. In Ghana, the processing of an order can take from a week to several months especially in public sector. Project procurement involves the development of contract strategy, the management of contracting activities from initiation such as project and contract definition, market study through tendering process, contract documentation to contract performance, management and administration after contract award. The project team of client, consultants and contractors should join to establish proper material procurement strategy and methods in order to remove all the obstacles in the material procurement. The fourth item in Table 2 which was given by respondents as a cause of delay and cost overruns in groundwater construction projects is poor technical performances. Well completion problems are emerging from problems faced during actual drilling activities and from technical failures, which are accounted for improper planning and management experience limitation. The escalation of material prices was ranked fifth, resulting principally from the high and unstable inflationary trend in Ghana and developing countries in general. The average rate of inflation in Ghana was 12.7% between 1970 and 1979; 48.6% between 1980 and 1989; 30.8% between 1990 and 1999 [11]. The trend of inflation is probably due to demand exceeding supply, which creates scarcity of goods and hence the prices of materials increase. These unpredictable inflationary trends are readily observed in many developing countries and may have aided inaccurate projection of construction costs in such areas [7]. Other factors that emerged clearly as not very important, but of interest, are bad weather and geological conditions. These are the natural factors. Bad weather is ranked eight by owners and consultants and 10 by contractors while all the three groups ranked it 10. The respondents ranked the geological condition factor low. The bad weather and geological condition are the most difficult and unknown factors because they cannot be controlled. In Ghana, the effect of these natural factors may not be very significant, but it is worthy of consideration. Ghana is located in a tropical zone with only two climates: wet and dry. Rain would definitely stop groundwater construction activities because of the works nature. In the dry season, the average temperature varies between 30 and 38 C while the humidity ranges from 25 to 80%. Temperature and humidity affect the productivity of workers. If the temperature and humidity are high, workers feel dullness of senses and poor coordination [12] and generate body heat and subsequent discomfort [13]. Therefore, productivity in hot climates is certainly low. In the drilling world, the most apparent representative problem is the nature of the work itself. It is a work that can not see what is happening deep in the subsurface. The number of abandoned well due to the unfavourable geological conditions causes project delay and cost overruns. 7. Summaryand conclusion The main survey of contractors, owners and consultants as discussed in this paper relates to the construction of groundwater projects in Ghana. The survey focused on identifying and ranking in order of importance, the main factors causing project delay and cost overruns. The main conclusions of the survey are as follows: According to the contractors and consultants, monthly payments difficulties from agencies was the most important delay and cost factor, while owners ranked poor contractor management as the most important factor. Despite some difference in viewpoint held by the three groups surveyed, there is a high degree of agreement among them with respect to their ranking of the factors. The overall ranking results indicates that the three groups felt that the major factors that can cause excessive groundwater project overruns in developing countries are poor contractor management, monthly payment difficulties from agencies, material procurement, poor technical performances, escalation of material prices according to their degree of influence. Other factors that emerged clearly as not very important, but of interest, are bad weather and unexpected natural events. These are the natural factors. Bad weather is ranked eight by owners and consultants and 10 by contractors while all the groups on average ranked it 10. The respondents ranked geological conditions low. The bad weather and unfavourable geological conditions are most difficult and unknown factors because they cannot be controlled. The result shows that many of the problems in the groundwater construction projects are originated from poor resources management (human, technical and material). In practice, this phe-
6 326 Y. Frimpong et al. / International Journal of Project Management 21 (2003) nomenon is expected to continue unless actions are taken to control these causes right away from the planning to the implementation and management stages. Therefore, good practice in planning, coordinating, controlling and monitoring procedures needs to be recognised. 8. Recommendations Based on this study, and with developing countries in mind, some recommendations are given as follows: Appropriate funding levels should always be determined at the planning stage of the project so that regular payment should be paid to contractors for work done. In order to improve contractors managerial skills there is need for continuous work-training programs for personnel in the industry to update their knowledge and be familiar with project management techniques and processes. have effective and efficient performances. Effective and efficient material procurement systems should be established within projects. Material procurement has the potential to cause major delays to construction projects. Therefore, material procurement process should be executed properly by improving procurement process in order to avoid supply delays. Developing effective and efficient technical performances in the groundwater industry through different types of training programs. The training should cover project planning, scheduling, time and cost control, and the information systems. There should be adequate contingency allowance in order to cover increase in material cost due to inflation. References [1] Giridhar P, Ramesh K. Effective management of Turnkey projects. Aace Transactions, PM7- PM [2] Dlakwa MM, Culpin MF. Reasons for overrun in public sector construction projects in Nigeria. International Journal of Project Management 1990;8(4): [3] Ogunlana SO, Promkuntong K, Vithool J. Construction delays in a fast-growing growing economy: comparing Thailand with other economies. International Journal of Project Management 1996; 14(1): [4] Khalil ALMI, AL-Ghafly MA. Delay in public Utility projects in Saudi Arabia. International Journal of Project Management 1999;17(2): [5] Mansfield NR, Ugwu OO, Doran T. Causes of delay and cost overruns in Nigeria construction projects. International Journal of Project Management 1994;12(4): [6] Okpala DC, Aniekwu AC. Causes of high costs of construction in Nigeria. Journal of Management in Engineering, ASCE 1988; 114: [7] Arditi D, Akan GT, Gurdamar S. Cost overruns in public projects. Project Management 1985;3(4): [8] Frimpong, Y. (2000, November). Project management in developing countries: causes of delay and cost overruns in construction of groundwater projects. Unpublished Masters Research Project, University of Technology, Sydney, Australia. [9] Ogunlana SO, Olomolaiye PO. A survey of site management practice on some selected sites in Nigeria. Building Environ 1989; 24(2): [11] Wahab KA. Improving efficiency in the building sector. West Africa Tech Rev 1997:81 9. [12] Okpala DC. Causes of delay and cost overrun in the construction industry. CENSER Seminar Series 1986;May. [13] Ministry of Finance. Government Budget Statement. Ghana: Accra; [14] Oglesby C, Parker H, Howell G. Productivity improvement in construction. New York: McGraw-Hill; 1989.
Effective Front-End Project Management A Key Element in Achieving Project Success in Developing Countries
Effective Front-End Project Management A Key Element in Achieving Project Success in Developing Countries O O FANIRAN School of Civil and Environmental Engineering The University of New South Wales Sydney
More informationFACTORS AFFECTING DELAYS ON PRIVATE CONSTRUCTION PROJECTS
International Journal of Civil Engineering and Technology (IJCIET) Volume 7, Issue 2, March-April 2016, pp. 22-33, Article ID: IJCIET_07_02_002 Available online at http://www.iaeme.com/ijciet/issues.asp?jtype=ijciet&vtype=7&itype=2
More informationPROBLEMS OF PROJECTS AND EFFECTS OF DELAYS IN THE CONSTRUCTION INDUSTRY OF PAKISTAN
PROBLEMS OF PROJECTS AND EFFECTS OF DELAYS IN THE CONSTRUCTION INDUSTRY OF PAKISTAN M. Haseeb College of Public Administration, Huazhong University of Science and Technology, Wuhan, P.R. China, 430074.
More informationCauses and Effects of Delays in Large Construction Projects of. Pakistan
Causes and Effects of Delays in Large Construction Projects of Pakistan M. Haseeb 1, a, Xinhai-Lu 1, Aneesa Bibi 1, Maloof-ud-Dyian 2, Wahab Rabbani 3 1 College of Public Administration, Huazhong University
More informationAnalysis of Non-Excusable Delay Factors Influencing Contractors' Performance in Lagos State, Nigeria
Journal of Construction in Developing Countries, 18(1), 53 72, 2013 Analysis of Non-Excusable Delay Factors Influencing Contractors' Performance in Lagos State, Nigeria Olajide Timothy Ibironke, Timo Olugbenga
More informationCauses, Effects and Minimization of Delays in Construction Projects
Causes, Effects and Minimization of Delays in Construction Projects Divya.R 1, S.Ramya 2 Assistant Professor Department of Civil Engineering Bharathiyar Institute of Engineering for Women, Deviyakurichi
More informationProcurement Systems and Project Organisation Model for Low Cost Housing
Procurement Systems and Project Organisation Model for Low Cost Housing Murtala A. OLADAPO, Nigeria Key words: Procurement systems, project organisation, sustainable, low-cost housing. ABSTRACT Procurement
More informationFatemeh Akbari* Master of Industrial Engineering Islamic Azad University, Zahedan Brench, Iran
To Design and to Present a Tool to Prevent Extra Expense Incurring in School Reconstruction Projects (A case study: Reconstruction Department affiliated to School Equipment and Development Unit in Sistan
More informationSTRATEGIC DATA FOR EMPLOYERS CONSTRUCTION CLAIMS
STRATEGIC DATA FOR EMPLOYERS CONSTRUCTION CLAIMS KONGKOON TOCHAIWAT and VISUTH CHOVICHIEN Department of Civil Engineering, Chulalongkorn University, 254 Phyathai Road, Patumwan, Bangkok 10330, Thailand.
More informationRelationship between Factors of Construction Resources Affecting Project Cost
Modern Applied Science; Vol. 7, No. 1; 2013 ISSN 1913-1844 E-ISSN 1913-1852 Published by Canadian Center of Science and Education Relationship between Factors of Construction Resources Affecting Project
More informationCauses and effects of delays in Malaysian construction industry
International Journal of Project Management 25 (2007) 517 526 INTERNATIONAL JOURNAL OF PROJECT MANAGEMENT www.elsevier.com/locate/ijproman Causes and effects of delays in Malaysian construction industry
More informationCOST ESCALATION, SCHEDULE OVERRUNS AND QUALITY SHORTFALLS ON CONSTRUCTION PROJECTS
COST ESCALATION, SCHEDULE OVERRUNS AND QUALITY SHORTFALLS ON CONSTRUCTION PROJECTS By Chabota Kaliba A dissertation submitted to the University of Zambia in fulfilment of the requirements for the Degree
More informationA FRAMEWORK FOR COST MANAGEMENT OF LOW COST HOUSING
A FRAMEWORK FOR COST MANAGEMENT OF LOW COST HOUSING Murtala A OLADAPO Key words: Low cost housing, project environment, project organisation, procurement systems, cost management. ABSTRACT Cost Management
More informationProject Risk Management in Oman: A Survey of Risk Practices in the Construction Industry
CIB World Building Congress 2007 549 CIB2007-370 Project Risk Management in Oman: A Survey of Risk Practices in the Construction Industry Dr Tabarak Ballal 1, Dr Taha Elhag 2 and Mr Salim Ambusaidy 3 1
More informationREQUEST FOR PROPOSAL SPECTATOR FACILITY FEASIBILITY STUDY ADDENDUM NO. 1
Financial Management Services Purchasing Division Request for Proposal Spectator Facility Feasibility Study REQUEST FOR PROPOSAL FOR A SPECTATOR FACILITY FEASIBILITY STUDY ADDENDUM NO. 1 This addendum
More informationHow To Help The World Coffee Sector
ICC 105 19 Rev. 1 16 October 2012 Original: English E International Coffee Council 109 th Session 24 28 September 2012 London, United Kingdom Strategic action plan for the International Coffee Organization
More informationUnderstanding and Monitoring the Cost-Determining Factors of Infrastructure Projects. A User's Guide
Understanding and Monitoring the Cost-Determining Factors of Infrastructure Projects A User's Guide Table of contents 1. Introduction 3 2. Understanding The Project Development Process 4 3. Initial Project
More informationCost Control Techniques Used On Building Construction Sites in Uganda
Cost Control Techniques Used On Building Construction Sites in Uganda George Otim 1, Fiona Nakacwa 2, Michael Kyakula 3 1 PhD Student, Faculty of Technology, Makerere University, P. O. Box 7062, Kampala,
More informationFactors Affecting the Accuracy of Pre-Tender Cost Estimates in the Gaza Strip
Journal of Construction in Developing Countries, 18(1), 73 94, 2013 Factors Affecting the Accuracy of Pre-Tender Cost Estimates in the Gaza Strip * Adnan Enshassi 1, Sherif Mohamed 2 and Munther Abdel-Hadi
More informationQUANTITATIVE ANALYSIS OF TIME OVERRUNS IN TRANSPORT INFRASTRUCTURE PROJECTS
QUANTITATIVE ANALYSIS OF TIME OVERRUNS IN TRANSPORT INFRASTRUCTURE PROJECTS João Guedes de Miranda Extended abstract Examination Committee Chairperson: Prof. Ana Paula Patrício Teixeira Ferreira Pinto
More informationAfDB New Procurement Policy: Training Program for the Bank s Procurement Staff. Risk Allocation in Construction Contracts
11 AfDB New Procurement Policy: Training Program for the Bank s Procurement Staff Risk Allocation in Construction Contracts Risks 2 In the absence of a contract, all risks are the owner's Contracting is
More informationCurrent Research in Agricultural Sciences ECONOMICS OF SHEEP PRODUCTION IN ZURU LOCAL GOVERNMENT AREA OF KEBBI STATE NIGERIA
Current Research in Agricultural Sciences journal homepage: http://www.pakinsight.com/?ic=journal&journal=68 ECONOMICS OF SHEEP PRODUCTION IN ZURU LOCAL GOVERNMENT AREA OF KEBBI STATE NIGERIA Baba M.D.
More informationRISK MANAGEMENT POLICY
RISK MANAGEMENT POLICY 1. INTRODUCTION 1.1 This Policy sets out Marindi Metals Ltd ( Marindi or the Company ) system of risk oversight, management of material business risks and internal control. 1.2 Marindi
More informationBOREHOLE SEALING IN A COAXIAL HEAT EXCHANGER BY BENTONITE TREATMENT
BOREHOLE SEALING IN A COAXIAL HEAT EXCHANGER BY BENTONITE TREATMENT Frank.B.Cruickshanks, Olof Andersson, James Bardsley Climate Change Division, Meteorological Service of Canada, 45 Alderney Drive, Dartmouth,
More informationRisk Management approach for Cultural Heritage Projects Based on Project Management Body of Knowledge
1 Extreme Heritage, 2007 Australia, 19-21 July 2007, James Cook University, Cairns, Australia Theme 6: Heritage disasters and risk preparedness approach for Cultural Heritage Projects Based on Project
More informationAvoiding Claims in Egyptian Construction Projects: A Quantitative Survey
Avoiding Claims in Egyptian Construction Projects: A Quantitative Survey Hesham A. Bassioni 1, Mohamed E. Abd El-Razek 2 and Wael A. Abd El-Salam 3 Abstract Construction claims are considered by many project
More informationUsing Risk Assessment to Improve Highway Construction Project Performance
Using Risk Assessment to Improve Highway Construction Project Performance Mohamed F. Diab, MBA, Ph.D. and Amiy Varma, Ph.D., PE North Dakota State University Fargo, ND Khaled Nassar, Ph.D. American University
More informationCOST AND TIME CONTROL OF CONSTRUCTION PROJECTS: INHIBITING FACTORS AND MITIGATING MEASURES IN PRACTICE
COST AND TIME CONTROL OF CONSTRUCTION PROJECTS: INHIBITING FACTORS AND MITIGATING MEASURES IN PRACTICE Yakubu Adisa Olawale, Ph.D., MCIOB and Ming Sun, Ph.D. (Professor) Abstract Despite the availability
More informationCharacteristics of the Participants
3 Financial Analysis for Replacement of Construction Equipment in Saudi Arabia Ali A. Shash (Center for Engineering Research, Research Institute, King Fahd University of Petroleum & Minerals, Saudi Arabia)
More informationManual on o Training Management
5 Project on Improvement of Local Administration in Cambodia Manual on o Training Management Introduction What is Training Management? How to Use the Manuals Table of Contents 1. Introduction...4 2. What
More informationEffects of Operational Factors on Organizational Performance in Kenyan Insurance Industry
Effects of Operational Factors on Organizational Performance in Kenyan Insurance Industry Abisay Lumosi Mudaki Department of Business Management Masinde Muliro University of Science and Technology Kakamega,
More informationAVOIDING COST OVERRUNS IN CONSTRUCTION PROJECTS IN THE UNITED KINGDOM
AVOIDING COST OVERRUNS IN CONSTRUCTION PROJECTS IN THE UNITED KINGDOM By Susana Gomez Arcila Supervisor: Mr Michael Newton Dissertation submitted in partial fulfilment for the of Degree of Master of Science
More informationPERCEPTION OF BARRIERS TO IMPLEMENTING RISK ASSESSMENT AND MANAGEMENT PRACTICES BY CONSTRUCTION PROFESSIONALS IN TANZANIA
PERCEPTION OF BARRIERS TO IMPLEMENTING RISK ASSESSMENT AND MANAGEMENT PRACTICES BY CONSTRUCTION PROFESSIONALS IN TANZANIA Nicholas Chileshe 1 and Geraldine John Kikwasi 2 1 School of Natural and Built
More informationDescription of Selected Services under the UN CPC system in which the EC made Market Access Commitments in the EPA
Description of Selected Services under the UN CPC system in which the EC made Market Access Commitments in the EPA 7471 Travel agency and tour operator services Services rendered for passenger travel by
More informationMonitoring capital projects and addressing signs of trouble
/01 / Leadership Series 6 PROJECT ADVISORY Monitoring capital projects and addressing signs of trouble Leadership Series 6 kpmg.com/nz About the Leadership Series KPMG s Leadership Series is targeted towards
More informationManaging construction procurement risks
CONSTRUCTION PROCUREMENT BEST PRACTICE GUIDELINE #A5 Construction Industry Development Board Pretoria - Head Office Tel: 012 482 7200 Fraudline: 0800 11 24 32 Call Centre: 0860 103 353 E-mail: cidb@cidb.org.za
More informationCHAPTER 5 FINANCIAL BENEFIT-COST ANALYSIS
CHAPTER 5 FINANCIAL BENEFIT-COST ANALYSIS 122 HANDBOOK FOR THE ECONOMIC ANALYSIS OF WATER SUPPLY PROJECTS CONTENTS 5.1 Introduction...123 5.2 Financial Revenues...124 5.3 Project Costs...126 5.3.1 Investments...127
More informationProject Cost Management
Project Cost Management Study Notes PMI, PMP, CAPM, PMBOK, PM Network and the PMI Registered Education Provider logo are registered marks of the Project Management Institute, Inc. Points To Note Please
More informationSTUDY ON THE COST OVERRUNS IN ROAD CONSTRUCTION PROJECTS IN SRI LANKA
STUDY O THE COST OVERRUS I ROAD COSTRUCTIO PROJECTS I SRI LAKA Eng. S.B. Wijekoon Faculty of Engineering, University of Peradeniya (email: sbw@pdn.ac.lk) Eng. A.M.C.T.K. Attanayake Anuradhapura Provincial
More informationHousehold Energy Expenditure: Measures es off Hardship & Changes in Income
: Measures es off Hardship & Changes in Income By Professor or Sue Richardson Associate Professor or Peter Travers The National Institute of Labour Studies February, 2004 4 Table of Contents HOUSEHOLD
More informationCOVER SHEET. Copyright 2006 School of Engineering and Technology, Asian Institute of Technology. Accessed from http://eprints.qut.edu.
COVER SHEET Veronika, Alin and Riantini, Leni S and Trigunarsyah, Bambang (2006) Corrective action recommendation for project cost variance in construction material management. In Kanok-Nukulchai, Worsak
More informationources of Drinking Water
The drop on water Sources of Drinking Water Did you know that 40 per cent of Nova Scotians get their water privately from a drilled well, a dug well, or a surface water source? The other 60 per cent rely
More informationPlanning and Scheduling Consideration and Constraints in Automated Construction Environment. Chotchai Charoenngam, Ph.D. ABSTRACT
Planning and Scheduling Consideration and Constraints in Automated Construction Environment Chotchai Charoenngam, Ph.D. Assisatant Professor, School of Civil Engineering, Asian Institute of Technology,
More informationA REVIEW ON FACTORS AFFECTING CONTRACTOR PERFORMANCE IN CONSTRUCTION WORK
A REVIEW ON FACTORS AFFECTING CONTRACTOR PERFORMANCE IN CONSTRUCTION WORK Mihirkumar B. Naik 1, Dr. Neerajkumar D. Sharma 2, Prof. Bhavin K. Kashiyani 3 PG. Student, S.N. Patel Institute of Technology
More informationProject Management Guide
Project Management Guide What is in this guide? All development workers, and community organisations may at times work with development projects. This may bring you into contact with consultants, project
More informationSchool Construction Projects
The process of educating young people seems to be continually developing. New insights regarding how students most effectively receive retain and gain understanding of information and principles affect
More informationA SURVEY OF PROJECT MANAGEMENT TOOLS, TECHNIQUES AND METHODOLOGIES USED IN MAURITIUS: THE CURRENT STATUS
A SURVEY OF PROJECT MANAGEMENT TOOLS, TECHNIQUES AND METHODOLOGIES USED IN MAURITIUS: THE CURRENT STATUS Sukhoo, A. 1, Barnard, A. 2, Eloff, M.M. 2 and Van der Poll, J.A. 2 1 Central Informatics Bureau
More informationImportant Factors for Success of Public Construction Projects
2011 2 nd International Conference on Construction and Project Management IPEDR vol.15 (2011) (2011) IACSIT Press, Singapore Important Factors for Success of Public Construction Projects S. Z. S. Tabish1,
More informationRISK ANALYSIS IN FEASIBILITY STUDY OF BUILDING CONSTRUCTION PROJECT: CASE STUDY - PT. PERUSAHAAN GAS NEGARA INDONESIA
The Tenth East Asia-Pacific Conference on Structural Engineering and Construction August 3-5, 2006, Bangkok, Thailand RISK ANALYSIS IN FEASIBILITY STUDY OF BUILDING CONSTRUCTION PROJECT: CASE STUDY - PT.
More informationA QUALITATIVE APPROACH IN PROBLEM SOLVING PROCESS TRACING OF CONSTRUCTION SITE ENGINEERS
A QUALITATIVE APPROACH IN PROBLEM SOLVING PROCESS TRACING OF CONSTRUCTION SITE ENGINEERS Chotchai Charoenngam and Tayyab Maqsood School of Civil Engineering, Asian Institute of Technology, Thailand The
More informationWater Supply and Wells
Re-issued under new categorization in August 2009 as Practice Note for Authorized Persons, Registered Structural Engineers and Registered Geotechnical Engineers APP-4 Buildings Department Practice Note
More informationDate: 7 February 2013
Item No. Report title: Classification: Open Ward(s) or groups affected: From: Date: 7 February 2013 Meeting Name: Deputy Leader and Cabinet Member for Housing Management GW2: Leasehold and Ancillary Properties
More informationProcurement Management Challenges in Gas Projects of Iran
Proceedings of the 2010 International Conference on Industrial Engineering and Operations Management Dhaa, Bangladesh, January 9 10, 2010 Procurement Management Challenges in Gas Projects of Iran Mohammad
More informationExecutive Director, Engineering & Construction Services Director, Purchasing & Materials Management Division
PW8.5 STAFF REPORT ACTION REQUIRED Contract Award Request for Proposal No. 9117-15-7122 Engineering Services for the Detailed Design, Services During Construction, and Post-Construction Services for an
More informationCHAPTER 9 PROJECT FINANCE AND CONTRACT PRICING
CHAPTER 9 PROJECT FINANCE AND CONTRACT PRICING In the previous chapters, techniques for project planning, scheduling, resources management, and timecost trade off have been introduced. This chapter will
More informationAn Assessment of Risk Identification in Large Construction Projects in Iran
Journal of Construction in Developing Countries, Supp. 1, 57 69, 2012 An Assessment of Risk Identification in Large Construction Projects in Iran Mehdi Tadayon 1, Mastura Jaafar 1 and Ehsan Nasri 2 Abstract:
More informationAssessment of Critical Success Factors for Construction Projects in Pakistan
First International Conference on Construction In Developing Countries (ICCIDC I) Advancing and Integrating Construction Education, Research & Practice August 4-5, 2008, Karachi,, Pakistan Assessment of
More informationProducing a programme under the NEC form of contract
Proceedings of the Institution of Civil Engineers Management, Procurement and Law 163 May 2010 Issue MP2 Pages 59 64 doi: 10.1680/mpal.2010.163.2.59 Paper 900033 Received 02/05/09 Accepted 19/08/09 Keywords:
More information2010 MTEF: Budgeting for infrastructure and capital expenditure guidelines
2010 MTEF: Budgeting for infrastructure and capital expenditure guidelines Introduction The guidelines below provide departments and entities with information to make budget submissions for capital projects
More informationP3 Value for Money Assessment and Project Report. Evan Thomas Water and Wastewater Treatment Facility Project
P3 Value for Money Assessment and Project Report Evan Thomas Water and Wastewater Treatment Facility Project July 2013 Table of Contents 1. Summary: Using a P3 for a Water Treatment Plant - did it work?
More informationHow to get value for money from service providers on major projects
How to get value for money from service providers on major projects Session Focus Contracting as a relationship Identifying win/win arrangements Procurement & Planning on major projects Understanding the
More informationBARRIERS AND BENEFITS OF TOTAL QUALITY MANAGEMENT IN THE CONSTRUCTION INDUSTRY: EVIDENCE FROM TURKISH CONTRACTORS
7 th Research/Expert Conference with International Participations QUALITY 2011, Neum, B&H, June 01 04, 2011 BARRIERS AND BENEFITS OF TOTAL QUALITY MANAGEMENT IN THE CONSTRUCTION INDUSTRY: EVIDENCE FROM
More informationProject Procurement Management
Project Procurement Management Study Notes PMI, PMP, CAPM, PMBOK, PM Network and the PMI Registered Education Provider logo are registered marks of the Project Management Institute, Inc. Points to Note
More informationStudy of Delay in Project Planning and Design Stage of Civil Engineering Projects
International Journal of Engineering and Advanced Technology (IJEAT) ISSN: 2249 8958, Volume-2, Issue-3, February 2013 Study of Delay in Project Planning and Design Stage of Civil Engineering Projects
More informationImpact of Project Management Software on the Project Failure Rates in Nigerian Construction Industry.
Impact of Project Management Software on the Project Failure Rates in Nigerian Construction Industry. Obodoh Dominic A. 1, Mbanusi E. C. 2, Obodoh Chikasi M. 3 Department of Building Nnamdi Azikiwe University,
More informationDELEGATED POWERS REPORT NO. All reports 1. Governance Service receive draft report Name of GSO Paul Frost
DELEGATED POWERS REPORT NO. 1987 SUBJECT: Electoral Registration and Elections Management Software Contract Control sheet All of the following actions MUST be completed at each stage of the process and
More informationC.A.S.H. WORKSHOP Planning for the Building Season: Exploring and Understanding Project Delivery Methods
C.A.S.H. WORKSHOP Planning for the Building Season: Exploring and Understanding Project Delivery Methods Friday, December 3, 2010 9:00 a.m. to 3:00 p.m. Ontario Airport Radisson 2200 East Holt Boulevard
More informationCapital Projects. Providing assurance over effective delivery of projects
Capital Projects Providing assurance over effective delivery of projects Governance and oversight Project Scope and change Reporting and communication Project risk and success factors Delivery Major projects
More informationAnnex A TERMS OF REFERENCE PROTECTED CULTURE TECHNOLOGY AND PROJECT MANAGEMENT SERVICES
Annex A TERMS OF REFERENCE Reducing Risk to Human and Natural Assets Resulting from Climate Change Project (RRACC) PROTECTED CULTURE TECHNOLOGY AND PROJECT MANAGEMENT SERVICES 1. Background The OECS Secretariat,
More informationUnderstanding internally generated risks in projects
International Journal of Project Management 23 (2005) 584 590 INTERNATIONAL JOURNAL OF PROJECT MANAGEMENT www.elsevier.com/locate/ijproman Understanding internally generated risks in projects Richard B.
More information2011 MAJOR PROJECTS UPDATE - EAST WELLFIELD EXPANDED HYDROGEOLOGICAL STUDY AND WASTEWATER TREATMENT PLANT ZERO IMPACT ANALYSIS
Council November 28, 2011 2011 MAJOR PROJECTS UPDATE - EAST WELLFIELD EXPANDED HYDROGEOLOGICAL STUDY AND WASTEWATER TREATMENT PLANT ZERO IMPACT ANALYSIS ISSUE As a component of the Town s 2011 Major Projects
More informationLessons Learned For Successful Project Delivery. Listening with Care. Designing with Purpose. Delivering beyond Expectation.
For Successful Project Delivery Listening with Care. Designing with Purpose. Delivering beyond Expectation. Listening with Care. Designing with Purpose. Delivering beyond Expectation. Disclaimer The content
More informationCash flow is the life line of a business. Many start-up
PM.02 ABC of Cash Flow Projections Mark T. Chen, PE CCE Cash flow is the life line of a business. Many start-up companies fail because of insufficient cash flow. From the perspectives of both owner and
More informationUNITED NATIONS INDUSTRIAL DEVELOPMENT ORGANIZATION INVESTMENT AND TECHNOLOGY PROMOTION BRANCH INDUSTRIAL INVESTMENT AND TECHNOLOGY PROJECT PROFILE
UNITED NATIONS INDUSTRIAL DEVELOPMENT ORGANIZATION Vienna International Center P.O. Box 300, A-1400 Vienna, AUSTRIA INVESTMENT AND TECHNOLOGY PROMOTION BRANCH Tel: (43-1) 26026-4788 Fax: (43-1) 26026-6870
More informationQualitative analysis: Analyzing the construction schedule. 2014 Baker Tilly Virchow Krause, LLP
Qualitative analysis: Analyzing the construction schedule 2014 Baker Tilly Virchow Krause, LLP About Baker Tilly > Established in 1931 > One of the top 20 largest accounting and advisory firms in the United
More informationPERCEPTION OF SENIOR CITIZEN RESPONDENTS AS TO REVERSE MORTGAGE SCHEME
CHAPTER- V PERCEPTION OF SENIOR CITIZEN RESPONDENTS AS TO REVERSE MORTGAGE SCHEME 5.1 Introduction The present study intended to investigate the senior citizen s retirement planning and their perception
More informationREPORT. Earthquake Commission. Christchurch Earthquake Recovery Geotechnical Factual Report Merivale
REPORT Earthquake Commission Christchurch Earthquake Recovery Geotechnical Factual Report Merivale REPORT Earthquake Commission Christchurch Earthquake Recovery Geotechnical Factual Report Merivale Report
More informationCHAPTER 11 THE GOVERNMENT OF THE HONG KONG SPECIAL ADMINISTRATIVE REGION GENERAL REVENUE ACCOUNT. Information Technology Services Department
CHAPTER 11 THE GOVERNMENT OF THE HONG KONG SPECIAL ADMINISTRATIVE REGION GENERAL REVENUE ACCOUNT GOVERNMENT DEPARTMENT Information Technology Services Department Management of information technology outsourcing
More informationPrioritising Project Scope Definition Elements in Public Building Projects
Prioritising Project Scope Definition Elements in Public Building Projects Mohammed K. Fageha, Ajibade A. Aibinu (University of Melbourne, Australia) Abstract A complete definition of the scope of a project
More informationCauses of Contractor's Business Failure in Developing Countries: The Case of Palestine
Journal of Construction in Developing Countries, Vol. 11, No. 2, 2006 Causes of Contractor's Business Failure in Developing Countries: The Case of Palestine *Adnan Enshassi 1, Khalid Al-Hallaq 1 and Sherif
More informationProject LINK Meeting New York, 20-22 October 2010. Country Report: Australia
Project LINK Meeting New York, - October 1 Country Report: Australia Prepared by Peter Brain: National Institute of Economic and Industry Research, and Duncan Ironmonger: Department of Economics, University
More informationEPS 625 INTERMEDIATE STATISTICS FRIEDMAN TEST
EPS 625 INTERMEDIATE STATISTICS The Friedman test is an extension of the Wilcoxon test. The Wilcoxon test can be applied to repeated-measures data if participants are assessed on two occasions or conditions
More informationJanuary 2004, 1st edition ISBN 0-9583605-6-1
January 2004, 1st edition ISBN 0-9583605-6-1 Version Produced by: The Association of Consulting Engineers NZ PO Box 10247 Wellington NZ www.acenz.org.nz The Institution of Professional Engineers NZ PO
More informationPROCEDURE FS 1 PROCUREMENT POLICY
PROCEDURE FS 1 PROCUREMENT POLICY CONTENTS Section 1 Section 2 Section 3 Section 4 Section 5 Section 6 Section 7 Section 8 Section 9 Section 10 Section 11 Section 12 Section 13 Appendix A Appendix B Appendix
More informationFire? Loss of Profits? 3. What company covers the machinery to be insured under a Machinery Breakdown Policy?
Questionnaire and Proposal for Loss of Profits following Machinery Breakdown Insurance Name Postal address Nature of business: 1. What works of your business are to be insured against Machinery Loss of
More informationRequest for Proposal
Request for Proposal Central Library Building Assessment Review Issued by: Regina Public Library P.O. Box 2311 2311 12 th Avenue Regina, Saskatchewan S4P 3Z5 Issue Date: May 22, 2014 Closing Date: June
More informationSeminar s Title: EPC (Engineering-Procurement-Construction) Project Management
Seminar s Title: EPC (Engineering-Procurement-Construction) Project Management Purpose and Background : EPC contracting, one of the most prominent forms of contracting agreement in the construction industry,
More informationLONG TERM FOREIGN CURRENCY EXCHANGE RATE PREDICTIONS
LONG TERM FOREIGN CURRENCY EXCHANGE RATE PREDICTIONS The motivation of this work is to predict foreign currency exchange rates between countries using the long term economic performance of the respective
More informationDETERMINANTS OF PROJECT MANAGEMENT SUCCESS
DETERMINANTS OF PROJECT MANAGEMENT SUCCESS Gary Walker, Dr Shamil Naoum and Professor Rod Howes South Bank University, School of Construction, London. SW8 2JZ One of the features of the construction industry
More informationFacility Services PROJECT MANAGEMENT METHODOLOGY FRAMEWORK
Facility Services PROJECT MANAGEMENT METHODOLOGY FRAMEWORK Facility Services Project Management Methodology Framework 1 - Executive Summary The purpose of this document is to introduce the University community
More informationFactors Affecting Time Overruns in Public Construction Projects: The Case of Jordan
International Journal of Business and Management; Vol. 8, No. 23; 2013 ISSN 1833-3850 E-ISSN 1833-8119 Published by Canadian Center of Science and Education Factors Affecting Time Overruns in Public Construction
More informationAvailable online at www.sciencedirect.com Available online at www.sciencedirect.com
Available online at www.sciencedirect.com Available online at www.sciencedirect.com Procedia Procedia Engineering Engineering 00 (0 9 (0 000 000 340 344 Procedia Engineering www.elsevier.com/locate/procedia
More informationPaper P1 Performance Operations Post Exam Guide March 2011 Exam. General Comments
General Comments Performance overall in March 2011 was comparable to the September 2010 diet. While the pass rate was acceptable, it could have been significantly improved if candidates had worked through
More informationijcrb.webs.com INTERDISCIPLINARY JOURNAL OF CONTEMPORARY RESEARCH IN BUSINESS OCTOBER 2013 VOL 5, NO 6 Abstract 1. Introduction:
Impact of Management Information Systems to Improve Performance in Municipalities in North of Jordan Fawzi Hasan Altaany Management Information Systems Department, Faculty of Administrative Sciences, Irbid
More informationProjections, Predictions, or Trends?
Projections, Predictions, or Trends? The challenges of projecting changes to fire regimes under climate change Bec Harris 9-11 th October, 2013 What are we looking for? Aims differ, and are more or less
More informationAn Evaluation of the National Teachers Institute s Manpower Training Program for Teaching Personnel in Mid-western Nigeria
International Education Journal Vol 5, No 3, 2004 http://iej.cjb.net 405 An Evaluation of the National Teachers Institute s Manpower Training Program for Teaching Personnel in Mid-western Nigeria A.U.
More informationSURVEY ON HOW COMMERCIAL BANKS DETERMINE LENDING INTEREST RATES IN ZAMBIA
BANK Of ZAMBIA SURVEY ON HOW COMMERCIAL BANKS DETERMINE LENDING INTEREST RATES IN ZAMBIA September 10 1 1.0 Introduction 1.1 As Government has indicated its intention to shift monetary policy away from
More informationELECTRICITY DEMAND DARWIN ( 1990-1994 )
ELECTRICITY DEMAND IN DARWIN ( 1990-1994 ) A dissertation submitted to the Graduate School of Business Northern Territory University by THANHTANG In partial fulfilment of the requirements for the Graduate
More informationEvaluating the effects of communication in construction project delivery in Nigeria
Global Journal of Environmental Science and Technology: ISSN-2360-7955, Vol. 2(5): pp 048-054, June, 2014. Copyright 2014 Spring Journals Full Length Research Paper Evaluating the effects of communication
More informationDeming s 14 Points for the Transformation of Management
Deming s 14 Points for the Transformation of Management It is not necessary to change. Survival is not mandatory W. Edwards Deming 2008 E: info @ marval.co.uk Profile W.Edwards Deming was a world famous
More information