Posting Date: February 26, 2014

Transcription

1 LEARNING SCHOOLS OF TEXAS d/b/a CARPE DIEM SAN ANTONIO Request for Proposals Internet Access, Telecommunications & Telecommunications Services, Internal Connections Other than Basic Maintenance, and Basic Maintenance of Internal Connections E-Rate Funding Year # Posting Date: February 26, 2014 Proposal Due Date: March 26, 2014 at 4:00 PM. Mail, deliver, or complete proposal to: Learning Schools of Texas d/b/a Carpe Diem Schools ATTN: Nick Fleege C/O Schulman, Lopez & Hoffer, LLP 517 Soledad St. San Antonio, TX

2 SPECIFIC TERMS, CONDITIONS AND INSTRUCTIONS The undersigned authorized representative of the proposing organization indicated below hereby acknowledges: 1. That he/she is authorized to enter into contractual relationships on behalf of the proposing organization indicated below, and 2. That he/she has carefully examined this RFP Invitation, the accompanying RFP Forms, and all Terms and Conditions associated with this RFP Invitation, and 3. That he/she proposes to supply any products or services submitted under this RFP Invitation in strict compliance with the all Terms and Conditions associated with this RFP Invitation, unless any exceptions are noted in writing with this Proposal response, and 4. That if any part of this RFP is accepted, he/she will furnish all products or services awarded under this Proposal in strict compliance with all Terms and Conditions associated with this RFP Invitation, unless any exceptions are noted in writing with this Proposal response, and 5. That the individual, firm and/or any principal of the firm on whose behalf this proposal is submitted is qualified to provide products and services and who are current participants in the Schools and Library Program of the Universal Service Fund ( E-Rate ), and 6. That the individual, firm and/or any principal of the firm on whose behalf this proposal is submitted is not listed on the Federal Government s List of Parties Excluded from Federal Procurement and Non-procurement Programs published by the U.S. General Services Administration (GSA) effective and compliance with the FCC Red Light Rule as of the date of opening of this proposal, and agrees to notify Learning Schools of Texas of any debarment inquiries or proceedings by any federal, state or local governmental entity that exist or may arise between the date of this submission and such time as an award has been made under this procurement action, and 7. That the proposing organization in compliance with all federal, state, and local environmental codes, laws, and statutes. Name of Proposing Organization Address City, State, Zip Date Signature of Authorized Representative Printed Name of Authorized Representative Telephone Number of Authorized Representative Position or Title of Authorized Representative Fax Number of Authorized Representative RETURN THIS PAGE IN SEALED BID/PROPOSAL PACKAGE FORM A

3 STANDARD TERMS AND CONDITIONS 1. RFP SUBMISSION: Proposal must be submitted utilizing this document only and must reach Learning Schools of Texas ( School ) Business Office on or before the hour on the date specified. Late submittals will be returned unopened. Faxed or ed proposals will not be accepted. 2. REJECTION/AWARD: School reserves the right to reject any and/or all submittals, to award contracts as may appear advantageous to School and to waive all formalities in the procurement process. Written notice of award mailed or otherwise furnished to the successful respondent results in a binding contract without further action by either party. 3. SUPPLEMENTAL INFORMATION: All supplemental information required by the proposal documents must be included with the response. Failure to provide complete and accurate information may disqualify vendor from consideration. 4. PROPOSAL ERRORS: Proposals will represent a true and correct statement and shall contain no cause for claim of omission or error. Request for withdrawal of proposal is allowed based on proof of mechanical error: however vendor may be removed from approved vendor list. 5. USE OF BRAND NAMES: The use of brand and manufacturer s names is for the purpose of brevity in establishing type and quality of merchandise and is not restrictive. Manufacturer, trade and/or brand name must be indicated for each article and when omitted, Center will consider bid to be as specified. Illustrations and complete description must be included with the bid if bidding other than specified. 6. UNDUE INFLUENCE: In order to ensure the integrity of the selection process, vendor s officers, employees, agents or other representatives shall not lobby or attempt to influence a vote or recommendation related to the vendor s response, directly or indirectly, through any contact with school board members or other Center officials from the date this solicitation is released until the award of a contract by School s Board of Directors. 7. PAYMENT TERMS: Unless a prompt payment discount with a payment term of at least 10 days is offered and accepted by School, payment terms shall be Net 30 days from date of acceptance or receipt of a properly prepared and submitted invoice, whichever is later. 8. CONTRACTUAL RELATIONSHIP: Nothing herein shall be construed as creating the relationship of employer or employee between School and the Contractor or between the Center and the Contractor s employees. The Center shall not be subject to any obligation or liabilities if the Contractor or his employees, incurred in the performance of the contract unless otherwise herein authorized. Neither the Contractor nor its employees shall be entitled to any of the benefits established for Center employees, nor be covered by School s Workers Compensation Program. 10. INDEMIFICATION: Contractor shall indemnify, defend and hold harmless School, its officers, agents and employees, from and against any and all loss, cost, damage, expense and claims, including attorney s fees and liability of any kind of any acts or omission of Contractor, its officers, agents or employees, in performance of contract, so long as the sole negligence of the Center is not the cause of the loss, claim, damage expense or cost. 11. GRATUITIES: School may, by written notice to the Contractor, cancel any agreement without liability to School if it is determined by School that gratuities, in the form of entertainment, gifts, or otherwise, were offered or given by the Contractor, or any agent or representative of the Contractor, to any officer or employee of the School with a view toward securing a contract or securing favorable treatment with respect to the awarding or amending, or the making of any determination with respect to the performing of such a contract. In the event this contract is cancelled by the Center pursuant to this provision, School shall be entitled, in addition to any other rights and remedies, to recover or withhold the amount of the cost incurred by the Contractor in providing such gratuities. 12. ASSIGNMENT-DELEGATION: No right or interest in this contract shall be assigned or delegation of any obligation made by the Contractor without the written permission of the Center. Any attempt assignment or delegation by the Contractor shall be wholly void and totally ineffective for all purposes unless made in conformity with this paragraph. 13. WAIVER: No claim or right arising out of a breach of any contract can be discharged in whole or in part a waiver or renunciation of the claim or right unless the waiver or renunciation is supported by consideration and is in writing signed by the aggrieved party. 14. MODIFICATIONS: The contract may only be modified by a written agreement signed by both of the parties or their duly authorized agents. 15. INTERPRETATION OF EVIDENCE: No course of prior dealings between the parties and no usage of the trade shall be relevant to supplement or explain any term used in a contract. Acceptance or acquiescence in a course of performance rendered under a contract shall not be relevant to determine the meaning of the contract even though the accepting or acquiescing party has knowledge of the performance and opportunity for objection. Whenever a term defined by the Uniform Commercial Code is used in the contract, the definition contained in the Code is to control. 16. APLLICABLE LAW: This contract shall be governed by the policies of the School School Board, laws of the State of Texas and the Uniform Commercial Code. Wherever the term Uniform Commercial Code is used, it shall be construed as meaning the Uniform Commercial Code as adopted in the State of Texas as effective and in force on the date of this contract. School Board Policies can be accessed by contacting School. 17. ADVERTISING: Contractor shall not advertise or publish, without School s prior consent, the fact that School has entered into any contract, except to the extent necessary to comply with proper request for information from an authorized representative of the federal, state or local government. 18. LEGAL VENUE: Both parties agree that venue for any litigation arising from the contract shall lie in San Antonio, Bexar County, Texas. 19. FUND AVAILABILITY: Any contract resulting from this solicitation is contingent upon the continued availability of appropriations and is subject to cancellation, without penalty, either in whole or in part, if funds are not appropriated by the School School Board or otherwise not made available to School. 20. TERMINATION: School reserves the right to terminate all or any part of the undelivered portion of any order resulting from this bid solicitation with thirty (30) days written notice; upon default by the vendor, for delay or nonperformance by the vendor or, if it is deemed in the best interest of School, for convenience.

4 E-RATE SERVICES RFP SPECIFIC TERMS, CONDITIONS AND INSTRUCTIONS 1. NOTICE: The School is requesting these Proposals to address statutory competitive requirements and to determine the most cost effective service(s) for the School. The School, however, may or may not enter into an Agreement resulting from this RFP. 2. SCOPE OF SERVICES REQUIRES: New installation, setup, and monthly delivery of internet service Location: a currently vacant lot at , Requirements: 100MBps for 330 users with the potential to increase to 200MBps for 650 users 3. WRITTEN INQUIRIES Respondents may make written inquiries concerning this RFP to obtain clarification of the requirements. Questions should be brought to the attention of: Nick Fleege at: nick.fleege@carpediemsanantonio.com Inquiries must be submitted to no later than the date and time specified by the Deadline for Questions listed in the Schedule of Events. Questions received by this deadline, and corresponding answers, will be posted on the School s web page located at for all Vendors to access and review by issuance of written FAQS. The FAQs will be updated weekly. Transmission and confirmation of receipt of questions is the responsibility of the Respondent(s). Requests for verbal or telephone clarification will be declined and will be nonbinding. Form 470 # RIGHTS OF THE SCHOOL The School reserves the right to require additional information from Respondents and to conduct necessary investigations to determine service or product reliability, Respondent performance and to determine the accuracy of Respondent information. Respondents may be required to provide Manufacturers Specification Sheets, General Descriptions, Operating Manuals, System Layout Drawings and/or other support documentation so as to insure a clear understanding of the project offered. The School reserves the right to cancel any contract due to non-appropriations and lack of E-Rate funding without penalty. The School reserves the right to award none, one, or multiple Vendors. The School reserves the right to terminate this solicitation and to reissue a subsequent solicitation, and/or remedy technical errors in the process

5 4.1 Period of Performance The period of performance shall begin no earlier than July 1, 2014 and end no later than June 30, RFP Information and Work Conditions All Respondents are expected to carefully examine the RFP documents. Any uncertainties or inconsistencies should be brought to the attention of the individual identified in Section 4.5 of this RFP. It is believed that all information necessary to complete a response is included in this RFP. It is the responsibility of the Respondent to obtain clarification of any information contained herein that is not fully understood The Respondent shall not interfere or disrupt the day-to-day operations of the School, its staff, its students, or other contractors and consultants working for the School The Respondent, by and through the submission of a Proposal, agrees to be held responsible for: Having examined the Request for Proposal and all referenced applicable decisions of authorities having jurisdiction over the work herein, statutory authority, and local policy; Having become familiar with the nature and Scope of Work required by the School; and Identifying any local conditions that may affect the labor availability, administrative rules and other factors that may impact the School s timeline for completion of services Nothing in the RFP shall relieve the Respondent of the Scope of Work and associated work described within. The Respondent shall, in all cases, be solely responsible for the performance of all Deliverables in accordance with and resulting contract milestones The Proposal MUST take prime contractor responsibility, including the management and performance of any and all subcontractors, products, and services provided. 4.3 Addenda Only substantive items, as determined by the School, will be addressed in the form of written addenda, which, if issued, will be posted on the School E-Rate web portal. Failure of any Respondent to review any such addendum or interpretation shall not relieve the Respondent from any obligations under their Proposal submitted. 4.4 Proposal Submission All Proposals are due by 4:00 P.M. on March 26, Any Proposal received after this time and date will be rejected. It is the sole responsibility of the Respondent to ensure his Proposal is received by this deadline. No excuses are acceptable and the determination of the Superintendent is final.

6 4.4.2 All information requested must be provided by Respondent for the Proposal to be responsive Exceptions, substitutions and clarifications to the RFP requirements must be clearly stated and described in detail in the Proposal. For all substitutions and clarifications, state the nature of the exception or clarification and any alternate recommendation that will meet the intent of the School in accordance with the instructions in Section 5, Proposal Contents for format requirements An authorized officer of the Respondent must sign the Proposal. Signature on the Proposal form will signify agreement and compliance with all requirements set forth in this solicitation except where specifically noted in the written response. In addition, the Respondent s signature on the form will indicate the following: All data presented in the Proposal is accurate and reliable; Information given by the Respondent will constitute good and sufficient cause for rejection of the Proposal; Agreement that all costs, including the costs of subcontractors, either direct or indirect, incurred in the preparation of the Proposal, are the sole responsibility of the Respondent; Guarantees that the prices quoted have been established without collusion with other eligible Respondent(s) and without effort to preclude the School from obtaining the lowest possible competitive price; and Guarantees that the Respondent has strictly adhered to the federal gifting policy regarding this potential sale Each Respondent in submitting a Proposal represents that: The Respondent has read and understands the RFP and its Proposal is made in accordance with the Scope of Work. Respondent is familiar with the local conditions under which work is to be performed; The Proposal is based upon the materials, labor, systems, and equipment required in the RFP; and The Respondent acknowledges a waiver of their right, if any, to recover its costs incurred in preparation or submission of a Proposal or in anticipation of a contract. 4.5 Proposal Requirements and Conditions In submitting its Proposal, Respondent understands and agrees to be bound by terms and conditions set forth by this RFP: Submit ONE (1) signed, original Proposal via delivery or regular mail to: Learning Schools of Texas ATTN: Nick Fleege C/O Schulman, Lopez & Hoffer, LLP 517 Soledad St. San Antonio, TX or via (with all signature pages signed and scanned clearly to show Respondent execution)

7 to no later than the Proposal Submission Deadline. The Proposal shall be identified on the face of its container or in the subject of its transmittal as follows: E-Rate FUNDING YEAR 17 Proposal 470# No Proposal will be accepted after 4:00 P.M. on March 26, LATE PROPOSALS WILL NOT BE ACCEPTED and will be AUTOMATICALLY REJECTED. 4.6 Withdrawing Proposals Proposals deposited with the School can be withdrawn prior to the time set for opening Proposals. Request for non-consideration of Proposals must be made in writing to the Carl Tanton and received by the School prior to the time set for opening Proposals. The Proposal may not be withdrawn after Proposals have been opened, and the Respondent, in submitting the same, warrants and guarantees that its Proposal has been carefully reviewed and checked and that it is in all things true and accurate and free of mistakes and that such Proposal will not and cannot be withdrawn because of any mistake committed by Respondent. 4.7 Consideration of Proposals After Proposals are opened, the Proposals will be evaluated on the criteria listed in section 6.2, Criteria. The School reserves the right to reject any and all Proposals, to re-issue the RFP, modify or change the form of the solicitation or any combination thereof, to waive technicalities, or proceed to contract for service otherwise in the best interest of the School. E-Rate Program rules will be strictly enforced and adhered to during all phases of the project by both the School and Respondent. 4.8 Rejection of Proposals The School reserves the right to reject any or all Proposals for any of the following specific reasons: Respondent does not have a SPIN from the SLD/USAC Proposals received after the Proposal Submission Deadline as reflected on the cover page and in Sections 4.3 and Proposal containing any irregularities as defined in Section 4.14, Irregular Proposals, above Respondent, any subcontractor or supplier, or the surety on any bond given, or to be given is in litigation with the School, or where such litigation is contemplated or imminent, in the sole opinion of the School.

8 4.8.5 Proposal is incomplete or missing forms described within the Proposal or this RFP, and/or the Respondent fails to respond to Request(s) for Information within the three (3) day time limit Proposal does not have documented ability to provide discounted billing as required by the SLD/USAC. Please see section on Terms of Payment. 4.9 Disqualification of Respondents Respondents may be disqualified and their Proposals not considered, among other reasons, for any of the following reasons: Respondent does not have a SPIN from the SLD/USAC Reason for believing collusion exists among Respondents Respondent does not include specific pricing for requested services/products identified in this RFP. These types of Proposals may be considered spam and disqualified as such Where the Respondent, any subcontractor or supplier, or the surety on any bond given, or to be given, is in litigation with the School, or where such litigation is contemplated or imminent, in the sole opinion of the School The Respondent being in arrears on any existing contract or having defaulted on a previous contract Insufficient resources, which in judgment of the School will prevent or hinder promptly providing of additional services, if awarded Respondent does not have documented ability to discount bills as required by the SLD/USAC. Please see section on Terms of Payment Respondent is currently red lighted by the federal government. All Respondents are to be in good standing with all federal regulations.

9 5. FORMAT & ORGANIZATION OF SUPPORT MATERIALS Please address each of the following sections in your RFP. Your submittal should be submitted with tabs dividing each section of the response. Responses shall contain the following information and be submitted in the order shown below. Proposal Section Section Contents 1. Cover Sheet The cover sheet should include: (1) Company Name; (2) Company Address/Phone Number/Fax Number; (3) SPIN and (4) School Form 470 #. 2. Contact Information Name, title, , and phone number(s) of agent(s) representing Vendor and who is the best direct contact for information requests, points of clarification, and negotiation. (Form A) 3. Proposal Specific and detailed description of firm qualifications and proposed methodology to perform required services. See also Scope of Work Section for additional requirements. 4. Cost Schedule Completed cost schedule on Company letterhead including alternate Proposal costs and/or multiple year contract pricing, breakdown of costs, detailed descriptions and purposes, proper category alignment (e.g. separating basic maintenance from internal connections), and clearly distinguishing the cost of E-Rate ineligible products/services from E-Rate eligible products/services, pursuant to the 2014 Eligible Services List available at 5. General Implementation 6. Insurance Requirements Detailed description of the implementation of the project including: (1) Timeline for project completion; (2) Resources required to achieve success; and (3) Warranty information for all components included in the Proposal, as applicable. School requires all Consultants to carry professional liability, general liability, auto liability and umbrella liability, and worker s compensation/employer s liability insurance coverage. Professional liability insurance should remain in force during the term of contract and for one year following substantial completion of a project. Please state the carrier, agent, amount, expiration date and length of time you have maintained coverage for professional liability, general liability, auto liability and umbrella liability, and worker s compensation/employer s liability insurance coverage. Provide a sample certificate of insurance. 7. References One complete form (see Attachment A). 8. Felony Conviction Complete all portions of this form and submit with your Proposal and Disclosure supporting documentation (see Attachment B). 9. Out of State Complete this form in its entirety (see Attachment C). Certification 10. Conflict of Interest Questionnaire Complete this form in its entirety (see Attachment D).

10 6. EVALUATION AND SELECTION PROCESS 6.1 Overview The School will consider all applicable factors in determining which Proposal is in the best interest of the School. The School reserves the right to reject any, all, or any part of the Proposal and to accept any advantage considered beneficial to the School. The School reserves the right to waive any information or minor technicalities or to accept a Proposal deemed to be the most cost-effective solution in the best interests of the School. 6.2 Criteria The following criteria will be used to evaluate each Proposal. A major deficiency in any one area may disqualify a Proposal submission. In assessing the relative value and quality of each Proposal, a Decision Matrix will be utilized in which point values will be assigned in a range from zero to the maximum point weighing for each classification. The maximum score is 100 points. EVALUATION MATRIX Criteria Price of the eligible products and services Price of the ineligible products, services, and fees, including long-term cost to the School Prior experience with Vendor Ability to meet School s needs as described herein and within the Form 470 Vendor s reputation and quality of services/products Flexible USAC invoicing: i.e. the ability to accommodate both Forms 472 and Opening of Proposal At 10:00 A.M. on March 28, 2014, all Proposals will be opened and listed aloud. Responses received after opening time will be rejected. The Proposals will be reviewed by the School evaluation team at a later date and time to ascertain which Proposals address all requirements for the Request for Proposal. The team may interview selected Vendors or submit Requests for Information to clarify information contained within a Proposal or to remedy minor omissions of or inconsistencies with the requirements contained herein. The evaluation team will then score each criteria contained in the Evaluation Matrix for each Proposal, rank Vendors pursuant thereto, and thereby make their recommendation to the Superintendent for the award of a contract. 6.4 Award of Contract Award of contract for each Scope of Work, if it is awarded, will be made by the School to the Respondent whose Proposal is determined to be the most cost-effective solution in the best interests of the School. No award will be made until after investigations are made as to the responsibilities of the Respondents. Further, awarding of the contract is conditional and dependent on E-Rate funding and School discretion. In any contract resulting from this RFP, the School retains the right to terminate the contract, in whole or in part, at any time, with a written 30-day notice to the Respondent for reasons enumerated in Section 6.5.8, Termination, below. The Award of contract may be to one, all, some, or none of the Respondents at the sole discretion of the School.

11 APPLICATION SIGNATURE Until a contract resulting from this process is executed, no employee, agent or representative of any professional services provider shall make available or discuss its proposal with the media in any form, electronic or printed, and elected or appointed official or officer of School, or any employee, agent or other representative of School, unless specifically allowed to do so by the Purchasing Department. The information contained herein is true and accurate to the best of my knowledge. By signing below, the firm agrees to allow School to check references given and that the information regarding the size and scope of each project is accurate. Further, the signature below certifies that this RFP has been completed with no consultation, collaboration or conversation with other firms competing on the same project. NAME (Please print or type) TITLE DATE SIGNATURE

12 ATTACHMENT A LISTING OF CLIENTS Company Name Address Contact Name Phone Company Name Address Contact Name Phone Company Name Address Contact Name Phone

13 Felony Conviction Disclosure Statement State of Texas Legislative Senate Bill No. 1, Section , Notification of Criminal History, Subsection (1), states a person or business entity that enters into a contract with a school district must give advance notice to School if the person or an owner or operator has been convicted of a felony. A notice must include a general description of the conduct resulting in the conviction of a felony. Subsection (b) states a school district may terminate a contract with a person or business entity if the district determines that the person or business entity failed to give notice as required by Subsection (a) or misrepresented the conduct resulting in the conviction. The district must compensate the person or business entity for services performed before the termination of the contract. I, the undersigned agent for the firm named below, certify that the information concerning notification of felony conviction has been reviewed by me and the following information furnished is true to the best of my knowledge. Vendor s Name Signature of Authorized Company Official Authorized Company Official s Name (Please Print) My firm is a publicly held corporation; therefore, this reporting requirement is not applicable. My firm is not owned or operated by anyone who has been convicted of a felony. My firm is owned or operated by the following individual(s) who has/have been convicted of a felony:

14 Out of State Certification As defined by Texas House Bill 602, a nonresident Proposer means a Proposer whose principal place of business is not in Texas, but excludes a contractor whose ultimate parent company or majority owner has its principal place of business in Texas. I certify that my company is a Resident Proposer : Company Name (Please Print) I certify that my company qualifies as a Nonresident Proposer (NOTE: You must furnish the following information :) Indicate the following information for your Resident State : (The state your principal place of business is located in) Company Name Address City State Zip Code A. Does your resident state require Proposers whose principal place of business is in Texas to give preference to Proposers whose resident state is the same as yours by a prescribed amount or percentage to receive a comparable contract? ( Resident State means the state in which the principal place of business is located.) Yes No B. What is the prescribed amount or percentage? $ or % Certification: I certify that the information provided above is correct. Signature of Authorized Representative Name (Please Print) Title RETURN THESE PAGES IN SEALED RFP PACKAGE

15

16 3. DISCLOSURE: CONFLICT OF INTEREST Questionnaire CONFLICT OF INTEREST QUESTIONNAIRE For vendor or other person doing business with local governmental entity FORM CIQ This questionnaire is being filed in accordance with chapter 176 of the Local Government Code by a person doing business with the governmental entity. By law this questionnaire must be filed with the records administrator of the local government not later than the 7th business day after the date the person becomes aware of facts that require the statement to be filed. See Section , Local Government Code. OFFICE USE ONLY Date Received A person commits an offense if the person violates Section , Local Government Code. An offense under this section is a Class C misdemeanor. Name of person doing business with local governmental entity. Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than September 1 of the year for which an activity described in Section (a), Local Government Code, is pending and not later than the 7th business day after the date the originally filed questionnaire becomes incomplete or inaccurate.) Name each employee or contractor of the local governmental entity who makes recommendations to a local government officer of the governmental entity with respect to expenditures of money AND describe the affiliation or business relationship. Name each local government officer who appoints or employs local government officers of the governmental entity for which this questionnaire is filed AND describe the affiliation or business relationship.

17 Name of local government officer with whom filer has affiliation or business relationship. (Complete this section only if the answer to A, B, or C is YES.) This section, item 5 including subparts A, B, C & D, must be completed for each officer with whom the filer has affiliation or other relationship. Attach additional pages to this Form CIQ as necessary. A. Is the local government officer named in this section receiving or likely to receive taxable income from the filer of the questionnaire? Yes No B. Is the filer of the questionnaire receiving or likely to receive taxable income from or at the direction of the local government officer named in this section AND the taxable income is not from the local governmental entity? Yes No C. Is the filer of this questionnaire affiliated with a corporation or other business entity that the local government officer serves as an officer or director, or holds an Ownership of 10 percent or more? Yes No D. Describe each affiliation or business relationship. Signature of person doing business with the governmental entity Date 4. NON COLLUSIVE PROPOSAL CERTIFICATE & ACKNOWLEDGMENT By submission of this proposal, the Vendor certifies that: (a) the proposal has been independently arrived at without collusion with any other vendor or with any competitor. (b) The proposal has not been knowingly disclosed and shall not be knowingly disclosed, prior to the opening of proposals for this project, to any other vendor, competitor or potential competitor. (c) No attempt has been or will be made to induce any other person, partnership or corporation to submit or not to submit a proposal. (d) The person signing this proposal certifies that he has fully informed himself regarding the accuracy of the statements contained in this certification and under the penalties being applicable to the Vendor as well as to the person signing in its behalf. I certify that the above information is true and correct. YES

18 5. CERTIFICATION REGARDING DEBARMENT SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION - LOWER TIER COVERED TRANSACTIONS This certificate is required by the regulations implementing Executive Order 12549, Debarment and Suspension, 7 CFR Part 3017, Section , Participants' responsibilities. The regulations were published as Part IV of the January 30, 1989, Federal Register (pages ). Copies of the regulations may be obtained by contacting the Department of Agriculture agency with which this transaction originated. 1) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by a Federal department or agency. 2) Where the prospective lower tier participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. PR/Award # or Project Name: I (We) certify that our company has not been debarred and is not participating in lobbying activities. See attached explanation and complete disclosure forms. Check applicable box 6. CLEAN AIR & WATER ACT CERTIFICATION (This is a Federal requirement) I certify that my company is in compliance with all applicable standards, orders or regulations issued pursuant to the Clean Air Act of 1970, as amended ( 42 U.S.C. 1857(h), Section 508 of the Clean Water Act, as amended (33 U.S.C. 1368), Executive Order and Environmental Protection Agency Regulation, 40 CFR Part 15 as required under OMB Circular A-102, Attachment O, Paragraph 14 (1) regarding reporting violations to the grantor agency and to the United States Environmental Protection Agency Assistant Administrator for the Enforcement.

19 7. CERTIFICATION REGARDING LOBBYING for FEDERAL FUNDS - Applicable to grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certifications a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that: (1) No Federal appropriated funds have been paid or will be paid by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of congress, or an employee of a Member of Congress in connection with the awarding of a Federal contract, the making of a Federal grant, the making of a Federal loan, the entering into a cooperative agreement, and the extension, continuation, renewal, amendment, or modification of a Federal contract, grant, loan, or cooperative agreement. (2) If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of congress, or an employee of a Member of Congress in connection with this Federal grant or cooperative agreement the undersigned shall complete and submit Standard Form-LLL, SF-LLL Disclosure of Lobbying Activities Form in accordance with its instructions (see following page). (3) The undersigned shall required that the language of this certification be included in the award documents for all covered subawards exceeding $100,000 in Federal funds at all appropriate tiers and that all subrecipients shall certify and disclose accordingly. Check applicable box I (We) certify that our company has not been debarred and is not participating in lobbying activities. See attached explanation and complete disclosure forms. I (We) the undersigned, agent for the firm, named below certify that all information in the above certifications 1 through 8 are true and correct to the best of my knowledge. Name/Title: Company Name: Original Signature: Date