Software Forensics Centre Technical Report TR
|
|
|
- Dominic Sparks
- 9 years ago
- Views:
Transcription
1 Software Forensics Centre TR Software Forensics Centre Technical Report TR A Case Narrative of the Project Problems with the Denver Airport Baggage Handling System (DABHS) by A.J.M. Donaldson Middlesex University, School of Computing Science [email protected] Source Material: Applegate, L. M., Montealegre R., Knoop C. I., Nelson H. J., BAE Automated Systems (A): Denver International Airport Baggage-Handling System, Harvard Business School Case , in Glass R.L., Software Runaways: Lessons learned from massive software project failures, Prentice Hall, ISBN X, 1998 Applegate, L. M., Montealegre R., Knoop C. I., Nelson H. J., BAE Automated Systems (B): Implementing the Denver International Airport Baggage-Handling System, Harvard Business School Case , in Glass R.L., Software Runaways: Lessons learned from massive software project failures, Prentice Hall, ISBN X, 1998 Stearns D., Functionality Of Original BAE Design: Saviour Of Modern Flying, Denver International Airport was scheduled to open on October 31, 1993 with all three of its concourses fully running on the BAE automated baggage handling system that. On February 28, 1995, the new airport finally opened. Its opening came sixteen months late. The automated baggage system for the Denver International Airport is now running and is regarded as an important introduction in modern airport design. The baggage handling system was designed by BAE Automated Systems and allows airport planners to design airports of larger size, using narrow corridors and tunnels for baggage where no tug and cart system can run. Labour costs in using the system are minimal and the system moves luggage simply and has an equally simple method for pinpointing items as they are transferred between the concourses and terminal buildings. The baggage handling system is completely automatic and runs faster and more reliably than those using traditional technology.
2 Software Forensics Centre TR c B A Concourses Terminal West Terminal East The Jeppesen Terminal Figure 1. The Airport Terminal and Concourses at Denver International Airport This document was prepared with the purpose of being able to model the Case Study using UML. It is presented here in order to show a simple and yet comprehensive narrative of the case study Target Objectives of the DABHS Improve ground efficiency. Reduce close-out time for hub operations. Decrease time-consuming manual sorting/handling. Risks recognised early in the DABHS Project Very large scale of the project. Enormous complexity. Newness of the technology. Large number of entities to be served by the system. The high degree of technical and project definition uncertainty.
3 Software Forensics Centre TR Chronology September 1989 November 1989 November 1989 February 1990 June 1991 U.S. Federal officials authorised $60 million to construct a new highly technologically advanced airport for Denver, CO, to be called the Denver International Airport (DIA). Airport started A new Mayor was elected in Denver, CO. They had inherited the project with a target of October 1993 completion, but with no commitment to it by the major airlines. a commitment was received from 'Continental' United Airways signed on in with DIA planned to be its second largest hub. December 1991 a commitment was received from 'United Airlines' April 1992 April 1992 May 1992 May 1992 August 1992 August 1992 BAE was awarded the $175.6 million contract top build the entire airport system.. Company officials hammered out a deal in three intense working sessions BAE systems presented the City of Denver with a proposal to develop the most complex and automated [and integrated] baggage system ever built. 15 May 1992 Design of the UA baggage handling system was frozen when PMT assumed responsibility for the integrated baggage system. shortly after the baggage system negotiations began, the head of the DIA project resigned. August 1992 (as an example) UA altered plans for a transfr system for bags changing planes, requesting that BAE eliminate an entire loopof track from Concourse B. (they would operate with one loop rather than two). This saved approximately $20 million, but required a system redesign. additional ski-claim devices and odd-size baggage elevators added in four of the six sections of the terminal, added $1.6 million to the cost of the system. September 1992 Continental requested that automated baggage sorting systems be added to its west basement at a cost of $4.67 million. The ski claim area length was first changed from 94 feet to 127 feet.
4 Software Forensics Centre TR area length was first changed from 94 feet to 127 feet. October 1992 January 1993 January 1993, February 1993 June 1993 September 1993 Chief Airport Engineer Walter Slinger died. He had been a strong proponent of the baggage system and was a key player in the negotiations. this ski claim length was shortened to 112 feet! The first change added $295,800 The second change subtracted $125,000 maintenance tracks were added to permit the Telecars to be serviced without having to lift them off the main tracks. This cost an additional $912,000. Mayor Webb delayed the scheduled October 1993 opening to December 19, Later this was put back to March 9, This became the panic drop-dead date. Cars were running in concourse B all summer. However all of the programming was not done and BAE had full control of all the programming. BAE s contract negotiations wih the City of Denver over maintenance of the system, occasioned a 2-day strike of 300 millwrights that was joined by ~ 200 electricians. BAE lost the maintenance contract because they intended to pay $12 per hour for jobs that union wanted $20 per hour. September 1993 The opening was again delayed until May 15, October October 1993 January 1994 March 1994 April 1994 April 1994 Original target opening date for the airport was (delayed seven times over the next three months). October 29, 1993 was the original scheduled completion date for the project. UA requested alterations to its odd-size baggage inputs. This cost an additional; $432,000 The motors and circuitry was extremely sensitive to power surges and fluctuations. Feedback continually tripped circuit breakers and filters to remedy this took months to arrive. City of Denver invited reporters to observe the first test of the baggage system without notifying BAE. This was a public disaster! Reporters saw piles of disgorged clothes and other personal items lying beneath the Telecar s tracks. After the test, Mayor Webb deleayed the test yet gain this time indefinitely.
5 Software Forensics Centre TR indefinitely. May 1994 May 1994 July 1994 August 1994 August 1994 August 1994 September 1994 January 1995 February 1995 February 1995 the Mayor of Denver hired the German firm 'Logplan' The German Logplan was commissioned to asses the state of the baggage handling system. Logplan isolated a loop of track that contained every featur of the automated baggage system and intended to run it for an extended period to test the reliability of the Telecars. Announcement of construction of a back-up system. August 22, 1994, Mayor Webb notified BAE that they would have to pay $12,000-per-day penalty for not implementing the baggage system by DIA s original completion date. 31 st August 1994 in an effort to avoid the City of Denver had proposed a stand still agreement whereby major parties (the City, UA., and BAE) would waive certain previous rights until the new airport was opened and operational. (this merely pout legal issues on the back-burner for a while). September 7, 1994, BAE went public with a $40 million claim against the City of Denver in which they blamed delays on: Following autumn and winter testing of the system, a full-scale threehour 10,000-bag practice run of the substitute baggage` system. the airport finally opened February 28, 1995 the DIA opened with a real flourish including jet flypasts, current/former Mayors and a large crowd including 1725 journalists.
6 Software Forensics Centre TR Part A Narrative from Harvard case study Part 1 - Troubled times Target Objectives Improve ground efficiency. Reduce close-out time for hub operations. Decrease time-consuming manual sorting/handling. Risks were recognised Very large scale of the project. Enormous complexity. Newness of the technology. Large number of entities to be served by the system. The high degree of technical and project definition uncertainty. Initial Start November 1989 Airport started Original contract for a baggage handling system raised by United Airlines, but this was subsequently expanded to cover the entire airport. Original target opening date for the airport was October Delayed seven times over the next three months. May 1994 the Mayor of Denver hired the German firm 'Logplan' following pressure from: Denver residents Federal Aviation Administration (FAA) Commissioners Tenant Airlines November 1989 A new Mayor was elected in Denver, CO. They had inherited the project with a target of October 1993 completion, but with no commitment to it by the major airlines. this was a key requirement! (the main players were 'United Airlines' and 'Continental', accounting for 70% of the air traffic). February 1990 December 1991 a commitment was received from 'Continental' a commitment was received from 'United Airlines' With respect to the whole airport project, the Mayor of Denver put a very high emphasis on jobs and trade for the city Amongst the legal requirements for funding were the requirements that 30% minority-owned firms were used, and that 6% of women-owned firms were used. Five out of sixty contracts awarded for the design of DIA went to Denver companies.
7 Software Forensics Centre TR The 60 contracts generated 110 construction contracts and 88 professional service contracts. Between 200 and 300 (max. 400) companies were involved There was a huge local commitment with a workforce which peaked at 10,000 in mid At one stage there were 4,000 daily deliveries to the site. Communication was a problem from the beginning channels between: (a) The City, (b) The Project Management Team and (c) Consultants, were never well defined The tracking system was a disaster. They tried to merge the different systems into one central database `structure. Everybody had their own and it took 3 years to get working. Project Management DIA was financed by a lot of different sources The City if Denver staff and the Consultant team shared leadership of the project and coordinated initial facets of the design.. T his led to duplication, and so they identified responsibilities. Elements not delegated to consultants included: Ultimate policy and facility decisions Approval of payments Negotiation and execution of contracts Facilitation of FAA approvals Affirmative action Settlement of contractor claims and disputes Utility agreements The city did however delegate elements such as: Value engineering Construction Market analysis Claim management On-site staff and organisation State-of-the-Art project control (computerised management of budget and schedule) The Project Management Team (PMT)became responsible fo0r overseeing planning and development. Headed by associate director of aviation Partly staffed by City career civil servants! Consultants supplied other members of the team to added experience and capability. The project structure had 5 different areas 1. Site development 2. Roadways and parking 3. Airfield paving 4. Building design
8 Software Forensics Centre TR Utility systems United Airlines Baggage System The friendliness of an airport is measured in time and baggage handling is a key aspect of this. The larger the airport, the more critical the timing aspects of baggage handling because the underground movement of the baggage becomes problematic In most airports, airlines build their own baggage handling systems. N Denver, Concourse housed Continental 400m from the Terminal and Concourse B was to host United at 1000m from the terminal. Concourse C housed American, Delta, Northwest America West and TWA at 1600m from the terminal.. United signed on in June 1991 with DIA planned to be its second largest hub. UA needed an automated baggage handling system as they wanted to turn aircraft round in 30 minutes. UA commissioned BAE Automated Systems Inc., to develop0e a system for Concourse A A $20million contract was to be completed in 2.5 years. (BAE had independently contracted with UA. They knew that the overall DIA schedule was out of control and fixed their contract with UA prior to DIA going for competitive bidding) BAE had grown out of Boeing Airport Equipment into a company owned by he UK's BTR plc. They7 accounted for 90% of US baggage sorting systems. Implementing and Integrated Baggage Handling System BAE had commenced work on UA s baggage system when PMT recognised benefits of an airport-wide solution. (also other airlines were not moving on the subject at on their own) BAE did not bid for the larger project BAE had installed Telecar (laser barcode readers and conveyor belt system) but never on the size envisaged in the tender offer. DIA was going to need something much bigger. BAE told UA that it would take at least a year to get the system up and running, but noone wanted to hear that. City of Denver got the same story from technical advisers to the Franz Joseph Strauss airport in Munich (that less complicated system had taken 2 years testing and was running 24 hours a day for 6 months before the airport opened. Formulating Intentions BAE had a world-wide reputation as a superior baggage system builder. Denver approached the company and asked them to study how the United concept that could serve other carriers in the various concourses. BAE came up with a proposal (most ambitious ever biggest, most complex automated system ever)). It was to be effective in delivering bags to and from passengers.and efficient in terms of reliability, maintainability and future flexibility. The system was to be capable of delivering bags (including suitcases of all sizes, skis, and golf clubs) from the main terminal through a tunnel into a remote concourse and directly to a gate. Such efficient delivery would save precious ground time, reduce close-out time for hub operations, and cut time-consuming manual baggage sorting and handling.
9 Software Forensics Centre TR Although an automated system was more expensive initially than simple tugs and baggage carts, it was expected that it would reduce the manpower need ton distribute the baggage as required. Bags unloaded from an arriving aircraft at a particular concourse would be barely touched by human hands. Moved through the airport at speeds of up on 20 mph, they would be waiting when passengers arrived at the terminal., To prove the capability, BAE proposed to build a prototype automated baggage handling system in a 50,000 sq. ft. warehouse near its manufacturing plant in Texas. The prototype system convinced Chief Airport Engineer (Walter Slinger) that the automated system would work. A dilemma was approaching: The City wanted a fully integrated airport-wide system and they had no acceptable proposal.; but UA intended to proceed with their own system and let the rest of the airport be equipped with something else. BA arrived at the scene with fully designed specs which obviously in the long run proved to be a major planning error. The City had fallen into a trap, which historically architects and engineers tend to fall into as they severely underplay he importance and significance of some of the requirements of the baggage handling system, that is: arranging for the space into which it must fit, accommodating the weight that it may impose on the building structure the power that is required to run it the ventilation and air conditioning that may be necessary to dissipate the heat that it generates. In April 1992, BAE was awarded the $175.6 million contract top build the entire airport system.. Company officials hammered out a deal in three intense working sessions: Denver officials accepted these requirements (conditions?) They also committed to unrestricted access for BAE equipment. Owing to the tight deadlines, BAE would have priority in any area where it needed to install the system. According to BAE s chairman, at creation of the contract.: Concourse A Continental Airlines was under bankruptcy law protection. The City was worried that they would be unable to pay for their concourse. They only accounted for about 40%of the equipment. Concourse C had no signatory airlines as leaseholders at the time. The City therefore wanted the simplest, most elementary baggage system possible for Concourse C. The outputs and inputs were very crude because to keep the costs down, the City has no assurance of a revenue stream at that point in time. The City did not get airlines together to ask them what they wanted or needed to operate.
10 Software Forensics Centre TR Project Management No major organisational changes were deemed necessary on the DIA project to accommodate the new baggage handling system. Some management adjustments were made on the project Design of the UA baggage handling system was frozen on 15 May 1992 when PMT assumed responsibility for the integrated baggage system. Direct relationship with BAE was delegated to WA4. The area manager for this had no experience in airport construction, baggage systems, or the introduction of new technologies or the introduction of new technologies; but possessed vast experience in construction project control management. BAE had to change its working structure to conform to DIA s project management team structure. According to BAE s president: There was a senior manager for each concourse and a manager for the main terminal. The baggage system traversed all of these and BAE had to negotiate with each in the course of normal work. As changes were happening rapidly at each of these sites there was no time to have an information that showed what decisions were going on at each location. This discreet management led to pandemonium. For the first 2 years of the project the BAE chairman was the project manager. Then the project was divided into three general areas of expertise: mechanical engineering: mechanical components and their installation. industrial control: industrial control design, logic controller planning and motor control panels. software design: writing real-time process control software to manage the system. The major adjustments were operational At the time that the BAE contract was signed, construction had already begun on the terminal on concourses. Substantial changes had to be made to the overall design of the terminal and some construction already completed had to be taken out and reinstalled to accommodate the expanded system. Installation of the expanded system was initially estimated to require more than $100 million in construction work (remove walls, install new floors etc. etc.) In May 1992, shortly after the baggage system negotiations began, the head of t he DIA project resigned. In October 1992, Chief Airport Engineer Walter Slinger died. He had been a strong proponent of the baggage system and was a key player in the negotiations. His co-operation had been essential because of the crossover with heavy machinery and track moving/installation and general construction work still needed. His replacement was Gail Edmond. She had worked with him and new all the key players well. Her managerial style however was completely different. A UA manager summarised: - Slinger was a problem, solver controversial but never afraid to address a problem He had lots of autonomy and used it. She knew the people but little about
11 Software Forensics Centre TR the actual construction and had nowhere near the same autonomy.(th city council really tied her hands). - The PMT staff echoed this and pointed out that Edmond also retained her previous responsibilities as Chief of Construction and Acting Director of Aviation. (she was regarded as be an excellent and very capable manager who was completely overstretched). Emergent problem areas System Authority BAE felt restricted with the breaking over their agreement on unrestricted access which occurred everywhere. Other contractors work was impeding BAE progress. (key point in original negotiation). Complications 1. Airlines began requesting changes to the system s design even though the mechanical and software designs were supposed to be frozen. This meant that six months prior to opening the airport they were still moving equipment around, changing controls and changing software design. In August 1992 (as an example) UA altered plans for a transfer system for bags changing planes, requesting that BAE eliminate an entire loop of track from Concourse B. (they would operate with one loop rather than two). This saved approximately $20 million, but required a system redesign. Still in August 1992, additional ski-claim devices and odd-size baggage elevators added in four of the six sections of the terminal, added $1.6 million to the cost of the system. In September 1992, Continental requested that automated baggage sorting systems be added to its west basement at a cost of $4.67 million. The ski claim area length was first changed from 94 feet to 127 feet. In January 1993, this ski claim length was shortened to 112 feet! The first change added $295,800 The second change subtracted $125,000 Also in January 1993, maintenance tracks were added to permit the Telecars to be serviced without having to lift them off the main tracks. This cost an additional $912,000. In January 1994, UA requested alterations to its odd-size baggage inputs. This cost an additional; $432,000 (AJMD ideas note the effects of requirements changes and also he impact of non-software matters on projects. Also look up the current glib thinking that changing requirements is a good thing. Of course it is, but evolving requirements have to be kept within reason. It is all very well making cost savings, but the wider implications have to be taken into account) Use dollars as bullets.) 2. The City of Denver was unable to supply clean electricity to the baggage system.
12 Software Forensics Centre TR The motors and circuitry was extremely sensitive to power surges and fluctuations. Feedback continually tripped circuit breakers and filters to remedy this took months to arrive. (March 1994). 3. Denver s city laws required that a certain percentage of jobs be contracted to minority owned companies. BAE s original contract had been denied because they did not meet this requirement and BAE engaged outside contractors to address this requirement. BAE estimate that this increased costs by $6 million (a claim rejected by the Mayor s Office of Contract Compliance). In September 1993, BAE s contract negotiations wih the City of Denver over maintenance of the system, occasioned a 2-day strike of 300 millwrights that was joined by ~ 200 electricians. BAE lost the maintenance contract because they intended to pay $12 per hour for jobs that union wanted $20 per hour. Project Relations Much of the effort of implementing the baggage system was directed within one of the four working areas. The management team had no experience of baggage handling systems and treated it as being similar to pouring in concrete or fitting air-conditioning ducts. This inexperience meant that they continually underestimated their task, insisting that access and mechanical issues were not the problem. June 1993: Cars were running in concourse B all summer. However all of the programming was not done and BAE had full control of all the programming. Lawsuits February 1993: Mayor Webb delayed the scheduled October 1993 opening to December 19, Later this was put back to March 9, This became the panic drop-dead date. September 1993: The opening was again delayed until May 15, April 1994 City of Denver invited reporters to observe the first test of the baggage system without notifying BAE. This was a public disaster! Reporters saw piles of disgorged clothes and other personal items lying beneath the Telecar s tracks. (AJMD I have seen this phenomenon of forcing through a public test when the system is not ready) Most of the problems related to software errors, but mechanical problems also played a part. The software that controlled delivery of empty cars to the terminal building often sent cars back to the waiting pool. The jam logic software, designed to shut down a section of track behind a jammed car, shut down the whole loop instead. Optical sensors designed to detect and monitor cars were dirty, and caused the system to believe that a section of track was empty when in fact it held a stopped car. Collisions between cars dumped baggage on the tracks and on the floor. Jammed cars jumped the track and bent the rails.
13 Software Forensics Centre TR Faulty switches caused Telecars to dump luggage onto the tracks opr against the walls of the tunnels April 1994: After the test, Mayor Webb deleayed the test yet gain this time indefinitely. The City set the costs of the delay at $330,000 per month. May 1994: The German Logplan was commissioned to asses the state of the baggage handling system. July 1994: Logplan isolated a loop of track that contained every featur of the automated baggage system and intended to run it for an extended period to test the reliability of the Telecars. Jams on the conveyor belts caused he test to be halted. The system did no run long enough to determine if there was a fundamental design fault or to analyse where the problems actually were. Logplan recommended construction of a baggage back-up system, using Rapistam Demmag August 1994: Announcement of construction of a back-up system. The back-up system cost $10.5 million, but electrical upgrades and major building modifications pushed the project cost up top $50 million. The City of Denver and many other airlines hired legal firms to assist with negotiations and future litigation. The City also had to communicate with such parties as: the United States federal grand jury; the Securities Exchange Commission (SEC) ; and the General Accounting Office (GAO). The federal grand jury was conducting an investigation into the DIA The SEC was investigating the sale of $3.2 billion in bonds to finance DIA s construction. The GAO was investigating the use of Congressional funds. Mayor Webb s letter requesting a $12,000-a-day penaly for missing DIA s original opening date, plus the costs for building the conventional tug-and-cart back-up system.
14 Software Forensics Centre TR Part B Narrative from Harvard case study - part 2 - the solution Some chronological facts: In September 1989, U.S. Federal officials authorised $60 million to construct a new highlky technologically advanced airport for Denver, CO, to be called the Denver International Airport (DIA). In April 1992, BAE systems presented the City of Denver with a proposal to develop the most complex and automated [and integrated] baggage system ever built. October 29, 1993 was the original scheduled completion date for the project. On August 22, 1994, Mayor Webb notified BAE that they would have to pay $12,000- per-day penalty for not implementing the baggage system by DIA s original completion date. The mayor had also ordered a back-up conventional tug-and-cart baggage system for which he expected BAE to pay $50 million! The City of Denver insisted on holding BAE respoonsible for failing to finnish the original system. September 7, 1994, BAE went public with a $40 million claim against the City of Denver in which they blamed delays on: BAE s claimed was counterclaim was that the entire airport was behind schedule and that constant design changes had prevented BAE from installing its system. This included: Lack of site access due to City of Denver actions. Permit delays due to City of Denver actions. The city s alleged inability to meet agreed-upon deadlines to build the space that would house different elements of the baggage handling system. The claim also accused the City of breaking contractual promises to make BAE s system the toip priority by allowing other contractors jobs to take precedence. February 1995 the airport finally opened 16 months behind schedule Close to $2 billio0n over budget The first flight to land, nearly 3 years after BAE was retained, encountered not one state-of-the-art integrate baggage handling system, but three. Back to square one 31 st August 1994 in an effort to avoid the City of Denver had proposed a stand still agreement whereby major parties (the City, UA., and BAE) would waive certain previous rights until the new airport was opened and operational. (this merely pout legal issues on the back-burner for a while). The moratorium did however break the deadlock. Problems had arisen between City of Denver and UA over the baggage handling system.
15 Software Forensics Centre TR UA objected to the manual system because it wouldn t fit their tight time schedules. UA offered to modify the automated system to deliver bags on to the planes and rely on tugs and carts to deliver most of the baggage for arriving passengers. UA and City of Denver could not agree on who should pay for the modifications They approached BAE who indicated that they would not continue without a signed contract Both UA and Continental geared up for protracted negotiations and possible litigation. United Airline s law firm pointed out that they had been hired to negotiste the proposed back-up baggage system at DIA not to initiate litigation procedures Continental maintained that the last-minute baggage system was a breach of contract for which it could sue the City or choose to cancel its lease of DIA `gates. UA urged the City to bring in mediators. because of the deteriorating relationship with BAE Following negotiations: the original contract was broken into two pieces: (i) The United Airways contract (ii) The remaining piece of the City contract Under the new contract: 1. UA used BAE ssystem to serve its Concourse B and it took over, and used, at reduced speed two loops of track that served concourse C It isolated its operation from BAE s system that served Concourse A The number of cars was reduced from 3,100 to 2,300 and the spacing between cars extended. 2. The rest of the baggage system was` designed around conveyor belts and propanepowered tugs and carts. Warning lights were installed in the baggage tunnels to guide the tugs. Negotiations also brought a change in the organisation structure. UA immediately hired a construction manger with full decision-making authority and contracted with a consulting company for further assistance. BAE hired its own consultant to develop and write test plans and prepare commissioning documents. According to BAE chairman: BAE were now working with people who understood the technology and its needs. BAE signed the contract with United Airlines in September 1994 and five months later the airport was open. The contract with UA required them to make $35 million worth of changes. They formed a team in which everybody had the same goal. They developed a proper schedule. Any time they hit a problem, they would clear it up almost immediately, rarely in more than 24 hours rather than 2 3 months with the City of Denver. All in all: a good example of what can be achieved by working with people, rather than working against them.
16 Software Forensics Centre TR January 1995 Following autumn and winter testing of the system, a full-scale three-hour 10,000-bag practice run of the substitute baggage` system. February 28, 1995 the DIA opened with a real flourish including jet flypasts, current/former Mayors and a large crowd including 1725 journalists. The airport opened with: 5 runways 88 gates cost of $5.2 billion $18.80 (average) per passenger airline fee (2 nd highest in the US) The Outcome In fact the BAE automated system worked well and the back-up system serving the other airlines did not provide any difficulties. The baggage system was almost back to the original planned installation with: United Airlines, who carried most passengers at DIA using an automated system while: Other airlines used a conventional system 1. United Airway s $300 million system comprises: 22 miles of rollercoaster-like track 3,500 cars 55 computers handling up to 30,000 pieces of luggage per day. Controlled more of the airport s rights of way than originally planned (Robert Davis Denver Still Working Out Kinks as its First Birthday Arrives, USA Today (Feb 28, 1996)) 2. A simplified automated system served United Airway s Concourse B 3. Continental used a tug-and-cart system on its Concourse A but was expoected to go automated in the future. 4. Other airlines were operating a very conventional, highly labour intensive system. 5. Airlines on Concourse C would have an automated system, only if BAE installed new track, and United Airlines granted rights for access. And finally 6. Given that the back-up system was designed to be 100% independent of BAE s system, there is now not one integrated baggage handling system, but three baggage handling systems!!!
DENVER AIRPORT INTEGRATED AUTOMATED BAGGAGE HANDLING SYSTEM. I a i n S i m m s & K y l e K e n n e d y
DENVER AIRPORT INTEGRATED AUTOMATED BAGGAGE HANDLING SYSTEM I a i n S i m m s & K y l e K e n n e d y INTRODUCTION We will discuss: Background of the airport. Baggage system functionality. Why it was needed.
DENVER INTERNATIONAL AIRPORT
GAO United States General Accounting Offke Testimony Before the Subcommittee on Aviation, Committee on Transportation and Infrastructure, House of Representatives For Releaie on Delivery Expected at 9
Synopsis. Background. Denver Airport Baggage Handling System Case Study Calleam Consulting
Case Study Denver International Airport Baggage Handling System An illustration of ineffectual decision making Calleam Consulting Ltd Why Technology Projects Fail Synopsis Dysfunctional decision making
Case Study : Software Disasters -1
Case Study : Software Disasters -1 WELL-KNOWN: DENVER INTERNATIONAL AIRPORT BAGGAGE HANDLING SYSTEM BY DHRUV P & UDIT P http://www.denv erairporttransportation.com/images/dia.jpg Background City of Denver
The transition imperative: from project to operations
The transition imperative: from project to operations Dr Andy Davies* Breakfast Seminar, Friday 17 th June 2011 BI, Norwegian Business School * Innovation and Entrepreneurship Group Imperial College Business
Software Engineering. A Software Crisis. Denver International Airport
Software Engineering Summer 2012 Everything on these slides can also be found on the Web site: http:// www.st.cs.unisaarland.de/edu/ se/2012/ A Software Crisis Denver International Airport (DIA) Construction
Dubai International Airport
Dubai International Airport A baggage handling system for the gate to the Arab world Success Story major hub between Europe and Asia www.siemens.com/mobility The customer: Dubai International Airport was
years in the community
Montréal-Trudeau, from the 70 past to the future years in the community The airport s beginnings Montréal Pierre Elliott Trudeau International Airport is 70 years old! It was on September 1, 1941, that
Building A New Denver Airport. Adam Danczyk, Saif Jabari, and Matthew Forsyth
Building A New Denver Airport Adam Danczyk, Saif Jabari, and Matthew Forsyth History Benjamin F. Stapleton, Mayor of Denver in 1920s, desired a new airport. Site was selected six miles east of downtown
LUBBOCK PRESTON SMITH INTERNATIONAL AIRPORT EMERGENCY CONTINGENCY PLAN
LUBBOCK PRESTON SMITH INTERNATIONAL AIRPORT EMERGENCY CONTINGENCY PLAN Lubbock Preston Smith International Airport has prepared this Emergency Contingency Plan pursuant to 42301 of the FAA Modernization
Nothing runs. modern system report. On its Iowa manufacturing campus, John Deere. is using AGVs to move tractor cabs down the
Nothing runs like an AGV On its Iowa manufacturing campus, John Deere is using AGVs to move tractor cabs down the assembly line. The result has been savings in labor, a safer work environment and improved
Existing Facilities. Current and Forecast Demand
Existing Facilities JIA is served by a number of airside and landside facilities. There are two runways that serve the airport in an open V configuration. The Annual Service Volume (ASV) of the runway
Room for growth DÜSSELDORF INTERNATIONAL AIRPORT CUSTOMER STORY
Room for growth DÜSSELDORF INTERNATIONAL AIRPORT CUSTOMER STORY Düsseldorf International Airport is the third-largest airport in Germany. In 2009, it transported nearly 18 million passengers and managed
Dnata Airport Operations
Dnata Airport Operations Dnata Airport Operations, the ground handling agent at the Dubai International Airport and employer of more than 6,500 people, has played a significant and leading role in the
AFRAA AIRLINE PASSENGER SERVICE COMMITMENT
AFRAA AIRLINE PASSENGER SERVICE COMMITMENT PREAMBLE African Airlines members of African Airlines Association (AFRAA) have developed the Airline Passenger Service Commitment following consultation with
ISI Debtor Testimonials. April 2015 ISI. Tackling problem debt together
ISI Debtor Testimonials April 2015 ISI Tackling problem debt together The following are the words of debtors who have availed of the ISI s debt solutions and are real cases. They have reviewed and agreed
Our strategy and objectives
24 / British Airways 2008/09 Annual Report and Accounts Our strategy and objectives In an incredibly tough trading environment we have to focus hard on pulling ourselves through the immediate crisis, while
Written Testimony of Sonia Ellis Submitted to the Special Committee on Aging United States Senate Hearing on the Jamaican Lottery Scam March 13, 2013
Written Testimony of Sonia Ellis Submitted to the Special Committee on Aging United States Senate Hearing on the Jamaican Lottery Scam March 13, 2013 I would like to thank Chairman Nelson, Ranking member
Basic Guide. General Conditions of Contract for Construction Works (GCC 2004)
Basic Guide General Conditions of Contract for Construction Works (GCC 2004) February 2008 Preface The Construction Industry Development Board (CIDB) is a national body established by an Act of Parliament
AN OVERVIEW OF THE CONTRACT SURETY BOND CLAIMS PROCESS
The Associated General Contractors of America 333 John Carlyle Street Suite 200 Alexandria, VA 22314 AN OVERVIEW OF THE CONTRACT SURETY BOND CLAIMS PROCESS Developed by the Associated General Contractors
General Liability Insurance Application (Contractors Supplemental Questionnaire)
Insurance Services www.metroinsurance.com General Liability Insurance Application Note: Throughout this questionnaire the words you and your include all entities seeking coverage. Note: This and other
Construction Practice Group
Advising and counseling our clients through every phase of even the most complex construction matters is what differentiates the lawyers in Gould & Ratner s construction practice. As a group, they possess
Department Chair Online Resource Center Starting a New Program: A Case Study
Department Chair Online Resource Center Starting a New Program: A Case Study Melvyn Jay Oremland, director, B.S./M.S. Forensic Science Program, Pace University. Starting a New Program: A Case Study. In
WHAT ATTORNEYS AND CLAIMS ADJUSTERS REALLY NEED TO KNOW ABOUT COLLISION INVESTIGATION 2 nd Edition
WHAT ATTORNEYS AND CLAIMS ADJUSTERS REALLY NEED TO KNOW ABOUT COLLISION INVESTIGATION 2 nd Edition Robert E. Stearns, B.S., ACTAR #661 Kinetic Energy Press Rocklin, California Copyright 2007, All Rights
The total estimated PFC revenue for the application is $266,900,000. The estimated charge effective date for this application is December 1, 2016.
Public Notice of Application for Authority to Impose and Use Passenger Facility Charges (PFCs) at EWR, LGA, JFK and SWF and Amendment to Approved PFC Applications at EWR, LGA, and JFK The Port Authority
OFFICE OF PERSONNEL MANAGEMENT ATLANTA OVERSIGHT DIVISION ATLANTA, GEORGIA
OFFICE OF PERSONNEL MANAGEMENT ATLANTA OVERSIGHT DIVISION ATLANTA, GEORGIA CLASSIFICATION APPEAL DECISION Under section 5112(b) of title 5, United States Code Appellant: [the appellant] Position: Engineering
MASTER PLAN PREPARATION
Located in the East Valley of the Phoenix Metropolitan Area, Phoenix-Mesa Gateway Airport is a former military airfield that has successfully made the transition to a full service commercial passenger
Position Classification Standard for Traffic Management Series, GS-2130. Table of Contents
Position Classification Standard for Traffic Management Series, GS-2130 Table of Contents SERIES DEFINITION... 2 EXCLUSIONS... 2 OCCUPATIONAL INFORMATION... 2 TITLES... 5 EVALUATING POSITIONS... 5 GRADE
Within online customer support, you will find customer support contact information, a link to e-mail our corporate travel agents and online help.
Tufts Traveler & Arranger Manual Spring 2006 GETTING HELP Corporate Travel Agents You may contact your custom agent or a corporate travel agent for help with the site, booking assistance or general support
Standard Bank. Case Study
Standard Bank Case Study A move to a new London landmark headquarters built to the latest environmental standards triggered an IT revolution for a top international bank. Today, Standard Bank is reaping
The person who the claim is made against pays all the costs if the claim is paid. That s Girlguiding in this case.
PUBLIC LIABILITY Public Liability (we call it PL) is an insurance that protects you/girlguiding against claims made by members of the public accusing you of causing damage to their property or injury to
PORT OF SEATTLE MEMORANDUM. COMMISSION AGENDA Item No. 6a ACTION ITEM Date of Meeting January 6, 2015
PORT OF SEATTLE MEMORANDUM COMMISSION AGENDA Item No. 6a ACTION ITEM Date of Meeting January 6, 2015 DATE: TO: FROM: Michael Ehl, Director Airport Operations Wayne Grotheer, Director Aviation Project Management
Bond Form Commentary and Comparison
Bond Form Commentary and Comparison AIA Document A310 2010, Bid Bond, and AIA Document A312 2010, Performance Bond and Payment Bond INTRODUCTION Since the first publication of The Standard Form of Bond
Key Facts. Passenger growth at the airport is projected to grow to approximately 3 million passengers per annum by 2030.
Bournemouth Airport & Business Park 7 7 Bournemouth Airport & Business Park Introduction 7.1 Bournemouth Airport is a key asset for the region, one of the UK s fastest growing regional airports and is
Changing the Face at the Busiest Airport in the World through Project Management
Changing the Face at the Busiest Airport in the World through Project Management Refurbishing Heathrow Airport Terminal 1, On Time, On Budget, With No Disruptions to Travelling Public Background: Dated
E-Booking at London International Airport
Standard Grade Computing Studies Commercial Data Processing Frank Frame Acknowledgement Thanks to Dorothy Tedman for her contribution to the review of the content. First published 2004 2004 This publication
Dealing with flight disruption
Dealing with flight disruption Guide to dealing with flight disruption The following guide offers practical information about what you re entitled to if your flight is delayed or cancelled, your legal
THE BAGGAGE SYSTEM AT DENVER: PROSPECTS AND LESSONS
THE BAGGAGE SYSTEM AT DENVER: PROSPECTS AND LESSONS Dr. Richard de Neufville Professor of Civil Engineering Chairman, Technology and Policy Program Massachusetts Institute of Technology Cambridge, MA 02139
ARIEL AIRPORT OWNERS AND OPERATORS LIABILITY INSURANCE
ARIEL AIRPORT OWNERS AND OPERATORS LIABILITY INSURANCE The Insurers hereby agree to the extent and in the manner hereinafter provided, to pay on behalf of the Insured all sums which the Insured shall become
UK SLOT ALLOCATION PROCESS AND CRITERIA
Introduction The IATA Worldwide Scheduling Guidelines (currently 18 th Edition) provide the framework for slot allocation for all coordinators world-wide and set the timetable of events in the scheduling
Dallas/Fort Worth International Airport SMS Safety Risk Management Airport Early Implementation
Dallas/Fort Worth International Airport SMS Safety Risk Management Airport Early Implementation ACI-NA 15 th Annual Risk Management Conference January 13, 2014 Paul Martinez DFW Airport, VP Operations
Bikecat s Terms and Conditions
1 Bikecat s Terms and Conditions WHAT IS INCLUDED? The following items are included in the trip: English-speaking expert guides, land transportation to and from Barcelona airport and Girona, including
: : : : : : : : : : : : : : : : :
DAVIS POLK & WARDWELL 450 Lexington Avenue New York, New York 10017 Telephone (212) 450-4000 Facsimile (212) 450-6501 Benjamin S. Kaminetzky Elliot Moskowitz Daniel J. Schwartz Counsel to the Debtors and
Basic Airport Security Awareness
Basic Airport Security Awareness Mineta San Jose International Airport Training Standards Program Division of Employee Services, Safety & Training Mineta San Jose International Airport Key Points: The
U.S. Airport Slot Regulations
U.S. Airport Slot Regulations Current Practices and New Proposals University of Tokyo, ITPU International Seminar on Transport Congestion Policy Brian Meehan Consultant, U.S. Federal Aviation Administration
Current and Forecast Demand
Existing Facilities A new terminal opened in September 2005 at the Southwest Florida International Airport (RSW), replacing the 17-gate original terminal that opened in 1983. The $438 million Midfield
CONTRACTORS GENERAL LIABILITY APPLICATION Note: Throughout this questionnaire the words you and your include all entities seeking coverage
CONTRACTORS BEST INSURANCE SERVICES INC. 20335 Ventura Blvd., Ste 426, Woodland Hills, CA 91364 Phone No: 818-348-4900 FAX No: 866-309-9237 CA License #0F37560 CONTRACTORS GENERAL LIABILITY APPLICATION
Road Traffic Accidents Do s and Don ts & the Legal Process
Legal Discussion on Tipp FM with Orlagh Wafer 22 nd January 2013 Road Traffic Accidents Do s and Don ts & the Legal Process Introduction As the temperatures are dropping and the roads are becoming more
Predictive Maintenance in a Mission Critical Environment
March 2009 Predictive Maintenance in a Mission Critical Environment This paper discusses the need to proactively protect mechanical and electrical support systems in data processing centers and data storage
AIRLINE PASSENGER SERVICE COMMITMENT 28 March 2001
AIRLINE PASSENGER SERVICE COMMITMENT 28 March 2001 PREAMBLE Airlines in Europe have developed the Airline Passenger Service Commitment following consultation with representatives of Air Travellers, European
SMALL CLAIMS COURT IN ARKANSAS
SMALL CLAIMS COURT IN ARKANSAS Note: The information contained in this publication is designed as a useful guide to remind you of your rights as a citizen of this state. You should not rely totally on
Airline Disruption Management
Airline Disruption Management In a world of crowded planes and crowded skies, and where operational problems are quickly magnified by tight systemic constraints, one of the few ways airlines can truly
THE STATE OF TEXAS LANDOWNER S BILL OF RIGHTS
THE STATE OF TEXAS LANDOWNER S BILL OF RIGHTS PREPARED BY THE OFFICE OF THE ATTORNEY GENERAL OF TEXAS STATE OF TEXAS LANDOWNER S BILL OF RIGHTS This Landowner s Bill of Rights applies to any attempt by
Headquarters Army Legal Assistance Catterick Barracks British Forces Post Office 39
Headquarters Army Legal Assistance Catterick Barracks British Forces Post Office 39 Tel Civilian: (0049) (0)521 9254 3191 or 3196 Fax Civilian: (0049) (0)521 9254 3115 Tel Military: 94 8(81) 3191 or 3196
AGENCY: Federal Aviation Administration (FAA), Department of Transportation.
This document is scheduled to be published in the Federal Register on 05/11/2016 and available online at http://federalregister.gov/a/2016-11116, and on FDsys.gov [4910-13] DEPARTMENT OF TRANSPORTATION
airport transfers Challenges Solutions Impact Case Study Intel Atom Processor Internet of Things Transportation
Case Study Intel Atom Processor Internet of Things Transportation ICT Adding develops intelligence predictive to services airport transfers ICT Automatisering leverages iota* on the Intel IoT Gateway,
Cargo Management Software: What to Look for When Choosing a Platform
White Paper Number 1 September 2014 Cargo Management Software: What to Look for When Choosing a Platform The Boeing Company 2014, QuantumID Technologies. All rights reserved. Introduction For decades in
national consumer agency gníomhaireacht náisiúnta tomhaltóirí putting putting consumers first Property Management Companies and You
national consumer agency gníomhaireacht náisiúnta tomhaltóirí putting putting consumers first Property Management Companies and You This booklet is based on information provided by DKM Consultants in association
Ergonomic Solutions: Baggage Handling. Ergonomic Solutions: Baggage Handling. Division of Workers Compensation HS02-023B (02-14)
Ergonomic Solutions: Baggage Handling Ergonomic Solutions: Baggage Handling Division of Workers Compensation HS02-023B (02-14) Table of Content Baggage Check-In 3 Transferring Baggage to Main Conveyor
A Guide to Renovation and Repair Contract Warranties
A Guide to Renovation and Repair Contract Warranties By Gerald A. Dalrymple, PE A fter being retained to review the merits of several major disputes involving the scope of warranties in renovation and
Signature Flight Support
Signature Flight Support Proposed Lease Amendments at Love Field Briefing to the Council Economic Development Committee Department of Aviation November 1, 2010 Purpose Background on leasing objectives
Business Ethical Dilemma One. a Sarbanes-Oxley (SOX) compliance initiative. My direct supervisor was the CTO, but as part
Business Ethical Dilemma One I was an IT Director at a publicly-held company and was responsible for the IT portion of a Sarbanes-Oxley (SOX) compliance initiative. My direct supervisor was the CTO, but
REQUEST FOR PROPOSAL FOR ARCHITECTURAL DESIGN SERVICES. The Battery Conservancy
REQUEST FOR PROPOSAL FOR ARCHITECTURAL DESIGN SERVICES The Battery Conservancy Issue Date: March 23, 2012 Responses Due: April 20, 2012 Introduction The Battery Conservancy ( TBC ) is a 501(c)(3) not-for-profit
Linbeck Construction used the Last Planner system of production control on a $22 million remodel of the Chemistry Building at Rice University.
Linbeck Construction used the Last Planner system of production control on a $22 million remodel of the Chemistry Building at Rice University. This was one of four innovative practices was described by
REQUEST FOR PROPOSALS Art Storage and Handling Services
LOWER MANHATTAN DEVELOPMENT CORPORATION REQUEST FOR PROPOSALS Art Storage and Handling Services The Lower Manhattan Development Corporation, a subsidiary of the New York State Urban Development Corporation
PROCUREMENT, OUTSOURCING, PRIVATIZATION
PROCUREMENT, OUTSOURCING, PRIVATIZATION The Procurement, Outsourcing, & Privatization Subcommittee believes that the Charleston County Procurement Department is both efficient and effective in carrying
E-retailing Project. E-retailing - An Exciting Opportunity for the Logistics Sector
E-retailing Project E-retailing - An Exciting Opportunity for the Logistics Sector May 2012 Goodman E retailing Research Report About Transport Intelligence Headquartered in the UK, Ti is one of the world
Aerodrome Advisory Circular
Aerodrome Advisory Circular AC(AD) NO-13 Integration of International Aviation Security (AVSEC) Measures into Designs and Constructions of New Facilities and alterations to Existing Facilities. CIVIL AVIATION
Walt Disney World Walt Disney World Walt Disney World Walt Disney World Walt Disney World Walt Disney World Walt Disney World
Disney s Magical Express is a complimentary service that includes round-trip motor coach transportation and baggage handling between Orlando International Airport and Walt Disney World Resort for guests
Ethics Case Study for ABC Incorporated and Questions
Ethics Case Study for ABC Incorporated and Questions By Renee Rampulla, CPA, Technical Manager, AICPA Professional Ethics Division and updated by Ellen Goria, CPA, Senior Manager Independence and Special
Intelligent Drivesystems, Worldwide Services. Baggage conveyor technology at Hamburg Airport DRIVESYSTEMS
Intelligent Drivesystems, Worldwide Services GB Baggage conveyor technology at Hamburg Airport NORD Drivesystems Intelligent Drivesystems, Worldwide Services Airport conveyor technology with NORD drive
PRICING SCHEDULE. Interest Rates and Interest Charges Annual Percentage Rate (APR) for Purchases
PRICING SCHEDULE This is an example of terms that were available to recent applicants as of 3/31/15. They may not be available now. If you apply, your terms will be based on the terms of the offer when
1. Acceptance of Terms 1.1 You acknowledge & warrant to Kirra that you have accessed, read & accept these terms by making a booking with Kirra.
1. Acceptance of Terms 1.1 You acknowledge & warrant to Kirra that you have accessed, read & accept these terms by making a booking with Kirra. 2. Contracting party 2.1 Any reference to Kirra, Kirra Tours
Lee County Port Authority. Southwest Florida International Airport Emergency Contingency Plan
01 1514 Southwest Florida International Airport (As required under section 42301 of the FAA Modernization and Reform Act of 2012) Table of Contents Airport Information Page 1 1. Plan to Provide for the
PRICING SCHEDULE. Interest Rates and Interest Charges Annual Percentage Rate (APR) for Purchases
PRICING SCHEDULE This is an example of terms that were available to recent applicants as of 3/31/15. They may not be available now. If you apply, your terms will be based on the terms of the offer when
ICT Project Management
THE UNITED REPUBLIC OF TANZANIA PRESIDENT S OFFICE PUBLIC SERVICE MANAGEMENT ICT Project Management A Step-by-step Guidebook for Managing ICT Projects and Risks Version 1.0 Date Release 04 Jan 2010 Contact
TERMINAL 2 ANNUAL REPORT 2006/07
TERMINAL 2 To meet future increases in passenger throughput, in 2006/07 we began the phased opening of a new passenger terminal. A few minutes walk from the existing passenger terminal, Terminal 2 (T2)
An ombudsman s view of good costs service
A guide for lawyers An ombudsman s view of good costs service www.legalombudsman.org.uk Introduction 01 Pre engagement 04 - Providing information - Initial consultation meeting - Charging structure - Service
How to Report A Claim
How to Report A Claim Claims. They are why you buy professional liability insurance. Make an error or omission carrying out your professional services and chances are your client or some other party to
COMMERCIAL AND GENERAL AVIATION
Existing Facilities Daytona Beach International Airport is served by a number of airside and landside facilities. The airport has three asphalt runways: Runway 7L/25R (10,500 feet long by 150 feet wide),
Charter Services. Frequently Asked Questions
Charter Services Frequently Asked Questions What advantages does chartering a private airplane have over traveling with the commercial airlines? Chartering a private aircraft provides you with numerous
Australian Maritime Safety Authority. Aviation rescue
Australian Maritime Safety Authority Aviation search and rescue Rescue Coordination Centre Australia Rescue Coordination Centre Australia (RCC Australia) is the national aviation and maritime search and
Plug IT In 5 Project management
Plug IT In 5 Project management PLUG IT IN OUTLINE PI5.1 Project management for information systems projects PI5.2 The project management process PI5.3 The project management body of knowledge LEARNING
