Tribunal of International Commercial Arbitration of the Russian Chamber of Commerce and Industry
|
|
- Amos Owens
- 7 years ago
- Views:
Transcription
1 1. SUMMARY OF RULING Tribunal of International Commercial Arbitration of the Russian Chamber of Commerce and Industry 28 May 2004 [Case No. 175/2003] Translation [*] by Gayane Nuridzhanyan [**] Edited by Alexander Morari [***] 1.1 The Tribunal of International Commercial Arbitration at the Russian Federation Chamber of Commerce and Industry [hereinafter Tribunal] was found competent to arbitrate the dispute despite a number of inaccuracies in the wording of the arbitration clause in the contract. 1.2 Taking into account the arbitration clause provided in the contract, the Tribunal has the jurisdiction to consider the case despite the fact that the [Seller] brought an action before a national court in the country of its place of business. 1.3 Since the places of business of the parties to this contract for the international sale of goods are located in States parties to the Vienna Convention 1980 [UN Convention on Contracts for the International Sale of Goods (1980), hereinafter CISG], its provisions are applicable to the relations of the parties. In accordance with the conflict-of-law rules of Part III of the Russian Civil Code, for matters not expressly settled by the CISG and which cannot be settled in conformity with the general principles on which the CISG is based, the provisions of the Egyptian law are applied as the subsidiary statute since it is the law of the [Seller]'s main place of business. 1.4 Since the [Seller] did not perform its obligations to deliver the goods, for which the [Seller] received a prepayment, and for which an additional term of delivery of reasonable duration was fixed by the [Buyer], the Tribunal rules that the [Buyer] had sufficient grounds to declare the contract avoided and claim refund of the prepayment and payment of the sum of the relevant sanctions. 1.5 By virtue of art. 84(1) CISG, the [Seller] must pay interest on the sum of the prepayment starting from the date of the payment of the price. The interest rate is determined by the Egyptian law applicable to the present dispute since the CISG does not settle this matter. 1.6 Taking into account the non-delivery of the goods, the Tribunal found inapplicable the contract penalty for delay in delivery since, in the Tribunal's opinion, such a penalty implies recovery only if the [Seller] still has an obligation to deliver the goods specifically, whereas the [Buyer] demanded the refund of the price of the goods which led to the avoidance of the contract. 1.7 Based on art. 74 CISG, [Buyer]'s loss of profit in the form of the difference between the price of the goods under the contract and the average market price at the destination market is to be recovered from the [Seller]. Expenses for the payment of customs fees, VAT and other costs not incurred by the [Buyer] are not included in this amount.
2 2. FACTS AND PLEADINGS The action was brought by [Buyer], a Russian company, against [Seller], an Egyptian firm, in connection with non-delivery of the goods under an international sales contract concluded by the parties on 12 March 2003 with the delivery basis of "CPT point of destination in Russia". 2.1 In compliance with the contract, the [Buyer] paid for the first installment of goods. Yet, a part of the first installment of the goods delivered by the [Seller] proved to be unusable. The price of the defective goods was paid to the [Buyer] by an insurance company. The remaining amount of the goods paid for by the [Buyer] was not delivered by the [Seller] at all. [Buyer]'s claims included: - Refund of the prepayment with interest on it at the average minimum interest rate of the primary banks at the place of destination of the goods); - Payment of the contract penalty for the delay in delivery; - Recovery of the loss of profit calculated as the difference between purchasing price and average market price at the place of destination of the goods; and - Reimbursement of the arbitration fees The [Seller] did not submit a statement of defense and informed the Tribunal that it brought an action in an Egyptian [national] court against the [Buyer] for indemnification for moral and property damages stating that the action is to be considered in the Egyptian court since the contractual relations of the parties are to be regulated by the Egyptian law. [Seller]'s representatives failed to appear at the hearings of the Tribunal. Representatives of the [Buyer] maintained its claims in full and objected to the position taken by the [Seller]. 3. TRIBUNAL'S REASONING The ruling of the Tribunal contained the following main points. 3.1 [Jurisdiction of the Tribunal] Para of the contract provides that: "If parties cannot reach an agreement amicably, such disputes or differences are to be settled at the Chamber of Commerce and Industry, Moscow, Russian Federation pursuant to its rules and procedure." Pursuant to an established and widely known international practice, dispute settlement at chambers of commerce of different countries is carried out by arbitration bodies functioning at such chambers in accordance with procedural rules approved by these chambers. This practice is typical for Russia as well. This is confirmed by the Law of the Russian Federation
3 of 7 July 1993 "On Chambers of Commerce and Industry in the Russian Federation" (art. 3(2)(9); art. 12(1)(M); art. 15(4)). Thus, it follows from the substance of the contract that the parties have reached an agreement on settlement of the disputes at the Tribunal. The dispute between the [Buyer] and the [Seller] falls into the category of disputes arising out of international contractual relations in which one of the parties' place of business is abroad. This category falls within the competence of the Tribunal according to section 2 of the Tribunal's Regulations (Supplement No.1 to the Law of the Russian Federation "On International Commercial Arbitration") and section 1(2) of the Rules of Tribunal. Moreover, the Tribunal is the only arbitration body at the Chamber of Commerce and Industry authorized to consider disputes of this category. The contract confirms the intent of the parties to refer all disputes arising from the contract to the Tribunal. This is invoked by the [Buyer] in Section 4 of the statement of action ("Grounds for the Competence of the Tribunal") In its fax of 15 April 2004, the [Seller] informed the Tribunal that it had filed a claim before an Egyptian court with hearings scheduled for 30 May According to the [Seller], the subject-matter of the action brought before the Egyptian court is indemnification for moral and property damages inflicted by the non-performance of the contract by the [Buyer] and infliction of harm by dissemination of injurious information. The [Seller] requests the Tribunal to terminate the arbitration due to the filing of the claim in the Egyptian court. Moreover, the [Seller] alleged that application of the Egyptian law to the contract entails [unconditional] consideration of the case in the Egyptian court. Also, the [Seller] alleged that it is not correct to conclude that settlement of the dispute in the Tribunal is provided for by the contract. In respect of [Seller]'s fax of 15 April 2004, [Buyer]'s representatives stated at the hearing of 11 May 2004 that the [Buyer], as of the date of the hearing, had not received any court summons or any other notifications from Egyptian judicial bodies. In the opinion of the [Buyer]'s representatives, the allegation of the [Seller] that the Egyptian court has the jurisdiction over the dispute does not correspond to the facts since the contract contains an arbitration clause according to which all disputes and differences related to the contract are to be settled at the Tribunal. As for the [Seller]'s claim regarding the protection of its business reputation, such claims are not related to the present action and do not affect its consideration by the Tribunal. Accordingly, the representatives of the [Buyer] emphasized that there are no grounds for dismissal or suspension of the proceedings on the present case Art. II(1) of the New York Convention on Recognition and Enforcement of Foreign Arbitral Awards of 1958 (to which Russia and Egypt are Contracting States) provides that: "Each Contracting State shall recognize an agreement in writing under which the parties undertake to submit to arbitration all or any differences which have arisen or which may arise between them in respect of a defined legal relationship, whether contractual or not, concerning a subject matter capable of settlement by arbitration."
4 The [Seller] did not submit any evidence to the effect that the subject-matter of the present dispute cannot serve as the subject of the arbitration proceedings in accordance with applicable law. Since the location of the Tribunal is in the territory of the Russian Federation, the procedure of the arbitration proceedings is to be regulated by the Law of the Russian Federation "On International Commercial Arbitration", which is based on the UNCITRAL Model Law of The UNCITRAL Model Law "On International Commercial Arbitration" is also taken as a basis of the Egyptian legislation on international commercial arbitration. According to art. 8(2) of the UNCITRAL Model Law, when an action is brought before a [national] court arbitral proceedings may nevertheless be commenced or continued, and an award may be made, while the issue [of jurisdiction] is pending before the court. Thus, in compliance with procedural norms applicable in Russia as well as Egypt, the bringing of the action before a national court is not a basis for termination or suspension of the arbitral proceedings before the Tribunal. Further, the possible application to the contract of the substantive law of the state in which one of the parties is located does not per se predetermine obligatory consideration of the dispute between these parties by the national courts of that country Art. 16(1) of the Law of the Russian Federation "On International Commercial Arbitration" provides that "the arbitral tribunal may rule on its own competence, including any objections with respect to the existence or validity of the arbitration agreement". Based on the wording of the arbitration clause of the parties to the contract and following section 1 of the Rules of Tribunal, the Tribunal acknowledges its own competence to consider the present dispute and does not find any grounds that may hinder further arbitration proceedings and the making of an award. 3.2 [Default by the Seller] In respect to the non-appearance of the [Seller] at the hearings of the case, the Tribunal states that the [Seller] had been duly notified about the date and place of the hearings. In compliance with section 28(2) of the Rules of Tribunal, "default by a party duly notified of the date, time and place of the hearing does not preclude the Tribunal from continuing the arbitral proceedings and making an award unless the defaulting party submits a written application to postpone the proceedings due to a valid reason". The Tribunal notes that [Seller]'s fax message of 15 April 2004 cannot be regarded as an application to postpone the proceedings due to a valid reason, since it does not contain an obvious request for postponement nor any reference to reasons which might be considered as valid for postponement of the proceedings. At the hearings, the [Buyer]'s representatives alleged that the Tribunal is entitled to consider the case in the absence of the [Seller]'s representatives. Taking into account the above and in accordance with section 28(2) of the Rules of Tribunal, the Tribunal concludes that non-appearance of the [Seller] does not impede the consideration of the case and making an award.
5 3.3 [Applicable law] The parties to the contract did not reach an agreement on the applicable law. The parties concluded a sales contract. Since the parties' places of business are located in States parties to the CISG, and in accordance with art. 1(1)(a) CISG, the relations of the parties are to be governed by the CISG. In accordance with art. 7(2) CISG: "Questions concerning matters governed by this Convention which are not expressly settled in it are to be settled in conformity with the general principles on which it is based or, in the absence of such principles, in conformity with the law applicable by virtue of the rules of private international law." In the opinion of [Buyer]'s representatives expressed in the course of the hearings, there did not arise any need to apply any national law as the subsidiary law, since all the questions at issue in the present case can be settled on the basis of the contract and the CISG. As indicated above, the [Seller] regards only the Egyptian law as applicable to the contract. The Tribunal considers that issues of the case cannot be settled solely on the basis of the CISG and general principles on which it is based, as well as on the basis of the contract, without determining a national law applicable as the subsidiary statute. In this connection, the Tribunal is guided by art. 28(2) of the Law of the Russian Federation "On International Commercial Arbitration" according to which: "in the absence of any designation by the parties, the arbitral tribunal shall apply the law determined in compliance with the conflict of laws rules which it considers applicable." Taking account of the above, the Tribunal considers the conflict of laws rule of art of the Russian Civil Code applicable and concludes that the subsidiary law applicable to the contractual relations of the parties is the law of the country where the place of the [Seller]'s main activity is located, i.e. the law of Egypt. The Tribunal stated that since neither of the parties presented any documents supporting the content of Egyptian substantive law in respect to the matters at issue in the present dispute, the Tribunal made use of the available information concerning the substance of applicable provisions of the Egyptian law. 3.4 [Ruling on the merits of the case] Turning to the claims of the [Buyer] for recovery of the main sum in arrears (the sum which was transferred to the [Seller] as prepayment for the delivery of the first installment of the goods), the Tribunal holds that the [Buyer] performed the obligation provided by section 8.1 of the contract to pay in advance 50 per cent of the price of the first installment of the goods. The fact of the payment is confirmed by Payment Order No.06 of 21 March 2003, by the bank statement of [Buyer]'s account, as well as by the content of the parties' correspondence.
6 The burden of proof of the proper performance of the obligation to deliver the goods lay with the [Seller]. The [Seller] did not submit any evidence in this respect. According to section 3.3 of the contract, the goods had to be delivered by the [Seller] to the point of destination in Russia within thirty-five days from the date of the prepayment, i.e. by 25 April The only container delivered by the [Seller] contained unusable goods, which is confirmed by Report No. 0411/03 of 18 June 2003 composed with participation of an independent surveyor. Since the goods were insured, the insurance company paid the price of the goods contained in that container. The Tribunal states that the parties do not have any dispute in respect to the price of the goods contained in the container delivered by the [Seller] since the [Buyer] was paid insurance compensation in the amount of the price of the goods and this sum was excluded from the calculation of the [Buyer]'s claims for recovery of the main sum in arrears From the substance of the [Buyer]'s complaint of 23 May 2004, it follows that the [Buyer] suggested that the [Seller] either refund the whole sum of the prepayment, deducting the price of the single delivered container, or that the [Seller] deliver a specified quantity of goods which shall cover the sum of the prepayment paid by the [Buyer] within an additionally fixed term. The Tribunal finds that, in accordance with art. 47 of the CISG, the suggestion by the [Buyer] can be regarded as fixing an additional period of reasonable length for performance of the [Seller]'s obligations to deliver the goods. In its complaints of 5 June 2003 and of 26 June 2003, the [Buyer], pointing out the fundamental nature of the breaches of contract committed by the [Seller], declared the contract avoided and claimed refund of the prepayment and payment of the sum of the relevant sanctions. The Tribunal considers that by virtue of art. 49(1) of the CISG, the [Buyer] had reasonable grounds to declare the contract avoided in respect to the delivery of the first installment of the goods provided by Supplement to the contract No. 1 without even having to obtain [Seller]'s consent to avoidance of the contract. This conclusion is additionally confirmed by section 8.3 of the contract, which contains a provision obligating the [Seller] to refund the money transferred by the [Buyer] within ninety days from the time of prepayment if, within the fixed term, the goods are not imported within the boundaries of the customs territory of the Russian Federation. It follows from art. 81(2) of the CISG that restitution of the price of the goods is a legal consequence of the avoidance of the contract. Taking account of the above, it should also be noted that the parties, having contractually provided for the obligation to return the prepayment, anticipated the likelihood of avoidance of the contract (at least of its corresponding part) in case of non-delivery of the goods within the fixed term. In this connection, the Tribunal cannot agree with the opinion expressed by the representative of the [Buyer] at the arbitration hearing on 11 May 2004 that the complaints of 5 June 2003 and 26 June 2003 should be regarded merely as declarations of the intent to demand the avoidance of the contract for the only reason that [Seller]'s consent to an avoidance of the contract was not obtained. Besides, [Buyer]'s declaration of avoidance of the contract complied with art. 26 of the CISG In conformity with art. 81(2) of the CISG, in case of avoidance of the contract:
7 "A party who has performed the contract either wholly or in part may claim restitution from the other party of whatever the first party has supplied or paid under the contract." Based on the above and taking into account the provisions of the contract and since the facts of the prepayment transfer and of the avoidance of the contract in respect to the first installment of the goods is proved as well as the absence of any objections by the [Seller] related to the main sum in arrears claimed by the [Buyer], the Tribunal concludes that [Buyer]'s claim for recovery of the main sum in arrears from the [Seller] is well-founded and is to be granted. 3.5 [Recovery of interest] The [Buyer] also seeks recovery of interest for use of monetary funds calculated for the period from 21 March 2003 (date of the prepayment) to 27 October 2003 (date of the submission of the statement of action) at the rate of 14 per cent per annum. As alleged by the [Buyer], this was the minimal rate of the Russian banks at [Buyer]'s location as of the date on which the claim was brought. As explained by the [Buyer]'s representatives at the hearings of 11 May 2004, application of the rate fixed by Russian banks is well-founded since due to the improper performance by the [Seller] of its obligations under the contract, the [Buyer] had to take credits in Russian banks. The [Buyer] alleges that recovery of the interest for the use of monetary funds at the interest rate fixed by Russian banks will allow the [Buyer] to compensate for the indicated expenses related to getting credit resources. According to art. 84(1) of the CISG: "If the seller is bound to refund the price, he must also pay interest on it, from the date on which the price was paid." In conformity with art. 78 of the CISG: "If a party fails to pay the price or any other sum that is in arrears, the other party is entitled to interest on it, without prejudice to any claim for damages recoverable under article 74." Based on these provisions of the CISG, the Tribunal considers that the claim of the [Buyer] for recovery of the interest has legal foundation and is to be granted from the date of payment of the prepayment for the first installment of the goods. However, the CISG does not regulate the interest rate to be used. Pursuant to art. 7(2) of the CISG, this issue is to be settled on the basis of the national substantive law applicable as the subsidiary statute. As was indicated above, the Tribunal regards the Egyptian substantive law as the applicable subsidiary law. According to the information available to the Tribunal from the foreign sources on the Egyptian substantive law regarding the amount of the annual interest rate in respect to pecuniary obligations, the debtor is obliged to pay to the creditor interest at the rate of 5 per cent. Therefore, the Tribunal concludes that the interest is to be calculated for the period indicated by the [Buyer] at the rate of 5 per cent. Based on the above and following arts. 84(2) and 78 of the CISG and provisions of Egyptian substantive law applied to the dispute as the subsidiary statute, the Tribunal finds that
8 [Buyer]'s claim for recovery of the interest is well-founded and is to be granted in the amount determined with due account of the rules of the Egyptian law. 3.6 [Recovery of the penalty] The [Buyer] claimed recovery of the contract penalty at the rate of 0.3% for each day of delay for the period from 25 April (the date on which, according to section 3.3 of the contract, the first installment of the goods was to be delivered to the point of destination in Russia) to 27 October 2003 (the date on which the [Buyer] submitted the statement of action). As a basis for this claim, the [Buyer] invokes section 10.4 of the contract according to which: "In case of the violation of the delivery terms, the [Seller] shall pay to the [Buyer] a fine in the amount of 0.3% of the price of non-delivered goods for each day of delay." The Tribunal notes that in section 10.4 of the contract, the parties agreed on the application of the sanctions in the event of delay in delivery by the [Seller]. However, in the present case in respect to the main part of the first installment of the goods (except for the quantity of the goods contained in the single container delivered by the [Seller], the price of which was excluded by the [Buyer] from the calculation of the penalty) the [Seller] committed a violation of another nature, and namely-- non-delivery of the goods. The Tribunal cannot agree with the [Buyer]'s position that the wording of section 10.4 of the contract covers the non-delivery of the goods by the [Seller] as well as late delivery. This conclusion is confirmed by the procedure of the calculation of the contract sanctions agreed by the parties (a fixed percentage of the price of non-delivered goods for each day of delay), which makes it possible to recover the sanctions exclusively in case the [Seller] still has an obligation to deliver the goods specifically. The CISG does not expressly settle the issue of recovery of sanctions of the type provided for in section 10.4 of the contract. However, in the Tribunal's opinion, a general principle on which the CISG is based and which is applicable by virtue of art. 7(2) of the CISG is the principle of compatibility of admissible remedies to which parties resort in individual situations. This general principle is particularly established in a number of provisions of the CISG (including arts , 62-64, 82-83). The Tribunal holds that the claim of the [Buyer] for recovery of the sanctions for delay in delivery is not compatible with [Buyer]'s claim for refund of the price of the goods, which follows from the fact of avoidance of the contract in respect of the first installment of the goods established by the Tribunal. Based on the above, the Tribunal rejects [Buyer]'s claim for recovery of contract sanctions for delay in delivery. 3.7 [Recovery of the loss of profit] The [Buyer] claimed recovery of the loss of profit resulting from the difference between the purchase price of the goods under the contract and the average market price of the goods under the contract existent on the market at the place of destination in Russia in the middle of While calculating the loss of profit for one kind of goods, the applied difference is (in [Buyer]'s terms "increase in the price [or a mark-up]") USD 0.2 per 1 net kg and, for the other kind of goods, USD 0.3 per 1 net kg.
9 As a basis for the application of the increase of price, the [Buyer] presented findings of the Survey of 29 September 2003 on wholesale prices for such goods at the place of destination of goods in Russia composed by an independent consulting company as well as copies of contracts and accounting documents relating to the sale of such goods by the [Buyer] to its Russian customers in May-June According to the explanations submitted by the [Buyer]'s representatives at the hearings of 11 May 2004, when calculating the loss of profit it is necessary to take as a basis the average prices specifically on this market, since "delivery address" of the goods in accordance with Supplement to the contract No.1 is the indicated location in Russia and the [Buyer] intended to resell the received goods with an increase of the price [mark-up] -- of which the [Seller] could not have been unaware. Besides, the [Buyer]'s representatives alleged that, for the purpose of calculation of the loss of profit, the minimal increase of price existent on the present market in the middle of 2003 was used Art. 74 of the CISG states that: "Damages for breach of contract by one party consist of a sum equal to the loss, including loss of profit, suffered by the other party as a consequence of the breach. Such damages may not exceed the loss which the party in breach foresaw or ought to have foreseen at the time of the conclusion of the contract, in the light of the facts and matters of which he then knew or ought to have known, as a possible consequence of the breach of contract." The Tribunal holds that the [Seller] knew or ought to have known that the [Buyer], a trading company conducting its main activity in the indicated location in Russia, purchased goods under the contract for the purpose of subsequent resale in the Russian Federation with a profit to be earned in the form of the difference between the purchasing and the resale price of the goods. The [Seller] did not present any evidence to the contrary The [Buyer] did not exclude from the calculation of the loss of profit the quantity of the goods actually delivered by the [Seller] to the [Buyer]. The Tribunal finds this approach well-founded, since the evidence presented by the [Buyer] confirms that the goods delivered by the [Seller] were completely defective, and that it was not possible to use the goods for their intended purpose or to sell the goods to a third party (section 4 of the present award). Accordingly, as a result of [Seller]'s failure to properly perform its obligation, the [Buyer] was deprived of the possibility to gain profit in respect to this quantity of goods by way of reselling these goods at a higher price. The [Seller] did not contest the statement of the [Buyer] that the delivered goods were completely unfit for the intended purposes and did not submit any evidence to the contrary. The Tribunal considers it appropriate to note that insurance of the goods by the [Buyer] allowed [Buyer] to significantly reduce the total loss caused by improper performance of the contract by the [Seller] Turning to the procedure of calculation of the amount of the loss of profit, the Tribunal holds that the amount of the loss of profit calculated by the [Buyer] is well-founded due to the following circumstances: - In Supplement to the contract No.1, the parties expressly agreed upon the description and
10 quantity of the first installment of goods as well as its price. - The Survey by the independent consulting company of 29 September 2003 on wholesale prices of the goods to be delivered under the contract to the indicated place of destination in Russia contains information on average prices for wholesale consignments for the period from January to September Taking due account of the exclusion from the calculation of the loss of profit the expenses that were not suffered by the [Buyer] -- namely, payment of customs charges, VAT and other expenses related to the purchased installment of the goods -- the increase of the price determined by the [Buyer] appears to be well-founded and in compliance with the criterion of the foreseeability provided in art. 74 of the CISG. - Additionally, the reasonableness of the calculation of the loss of profit conducted by the [Buyer] is confirmed by the copies of the executed contracts and accounting documents between the [Buyer] and its customers attached to the statement of action, from which materials it follows that in the middle of 2003, the price at which the [Buyer] sold these goods considerably exceeded the market price, as indicated in the Survey by the independent consulting company of 29 September The [Seller] did not submit any objections in respect to the [Buyer]'s calculation of amount of the loss of profit Based on the above and with due consideration of the fundamental principle of adversarial proceedings, the Tribunal concludes that [Buyer]'s claim for recovery of the loss of profit is to be granted in the amount claimed by the [Buyer]. 3.8 [Justification for granting the claims] The amounts of the main sum in arrears, annual interest and loss of profit to be recovered on the basis of this award correspond to the principle of compatibility of legal remedies resorted to, which is confirmed, in particular, by art. 45(1) and (2), art. 49(1), art. 78, art. 81 and art. 84(1) of the CISG. 3.9 [Arbitration fee] The [Buyer] seeks to recover from the [Seller] expenses related to the arbitration fee paid by the [Buyer]. According to section 6(2) of the Rules of Arbitration Expenses and Fees (Supplement to the Rules of Tribunal): "If an action is granted partially, the arbitration fee is imposed on the Respondent in proportion to the amount of granted claims and on the Claimant in proportion to the amount of the claims that are not granted." Since the action is partially granted, the [Seller] is obliged to reimburse to the [Buyer] the expenses related to payment of the arbitration fee in proportion to the amount of the granted claims.
11 FOOTNOTES * All translations should be verified by cross-checking against the original text. For purposes of this translation, Claimant of Russia is referred to as [Buyer] and Respondent of Egypt is referred to as [Seller]. ** Gayane Nuridzhanyan, junior associate at the law firm Danylko, Kushnir, Solltys & Yakymyak, Attorneys & Counselors at Law, Kyiv, Ukraine < student at Kyiv International University with major in private international law; participant of Canada-Ukraine Parliamentary Program, member of Ukrainian team at 2005 Telders International Moot Court Competition, The Hague. *** Alexander Morari, born in the Republic of Moldova, has taken part in a number of international moot courts as a member of the Moldovan team and as the coach of a Russian team.
MODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS
MODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS International Trade Centre, August 2010 Model Contracts for Small Firms: International Commercial Sale of Goods Contents
More informationUNITED NATIONS CONVENTION ON CONTRACTS FOR THE INTERNATIONAL SALE OF GOODS (1980) [CISG]
UNITED NATIONS CONVENTION ON CONTRACTS FOR THE INTERNATIONAL SALE OF GOODS (1980) [CISG] For U.S. citation purposes, the UN certified English text is published in 52 Federal Register 6262, 6264 6280 (March
More informationIn force as of 15 March 2005 based on decision by the President of NIB ARBITRATION REGULATIONS
In force as of 15 March 2005 based on decision by the President of NIB ARBITRATION REGULATIONS Contents I. SCOPE OF APPLICATION... 4 1 Purpose of these Regulations... 4 2 Applicability to different staff
More informationPERMANENT COURT OF ARBITRATION OPTIONAL RULES FOR ARBITRATING DISPUTES BETWEEN TWO STATES
PERMANENT COURT OF ARBITRATION OPTIONAL RULES FOR ARBITRATING DISPUTES BETWEEN TWO STATES 39 OPTIONAL ARBITRATION RULES TWO STATES CONTENTS Introduction 43 Section I. Introductory Rules 45 Scope of Application
More informationFOR INFORMATION PURPOSES ONLY
On December 23, 2013, the debtor Metropolitní spořitelní družstvo v likvidaci, having its registered office at Balbínova 404/22, Prague 2, Postal Code 120 00, Identification Number: 255 71 150, registered
More informationGENERAL TERMS AND CONDITIONS OF SUPPLY OF MONT.EL APPARECCHIATURE ELETTROELETTRONICHE S.R.L. PRODUCTS
GENERAL TERMS AND CONDITIONS OF SUPPLY OF MONT.EL APPARECCHIATURE ELETTROELETTRONICHE S.R.L. PRODUCTS 1) Nature, validity and effectiveness of the General Terms and Conditions 1.1 These General Terms and
More informationBUILDING CONTRACT MEMORANDUM OF AGREEMENT AND CONDITIONS OF CONTRACT
BUILDING CONTRACT MEMORANDUM OF AGREEMENT AND CONDITIONS OF CONTRACT MADE and entered into by and between: (hereinafter referred to as the OWNER); and (hereinafter referred to as the BUILDER) WHEREAS the
More informationSale of Goods (Vienna Convention) Act 1986
Version: 1.4.1989 South Australia Sale of Goods (Vienna Convention) Act 1986 An Act to give effect within South Australia to the United Nations Convention on Contracts for the International Sale of Goods;
More information2. An agreement will be concluded at the moment of express acceptance of the order by the Seller in a manner that is customary in the sector.
General Terms and Conditions for the Wholesale Trade in Floricultural Products drawn up by the Association of Wholesalers in Floricultural Products (VGB) and filed with the Amsterdam Chamber of Commerce
More informationProvince of Alberta LIMITATIONS ACT. Revised Statutes of Alberta 2000 Chapter L-12. Current as of December 17, 2014. Office Consolidation
Province of Alberta LIMITATIONS ACT Revised Statutes of Alberta 2000 Current as of December 17, 2014 Office Consolidation Published by Alberta Queen s Printer Alberta Queen s Printer 5 th Floor, Park Plaza
More informationGeneral Terms and Conditions of Irlbacher Blickpunkt Glas GmbH
General Terms and Conditions of 1. Scope 1.1 All supplies and services by (in the following: Irlbacher) are subject exclusively to the following terms and conditions: 1.2 Terms and conditions of commercial
More informationLAW ON ARBITRATION. Official Gazette no. 88/2001) P a r t O n e GENERAL PROVISIONS Scope of application Article 1
Please note that the translation provided below is only provisional translation and therefore does NOT represent an offical document of the Republic of Croatia. It confers no rights and imposes no obligations
More informationUNITED NATIONS COMMISSION ON INTERNATIONAL TRADE LAW (UNCITRAL) UNCITRAL Conciliation Rules
UNITED NATIONS COMMISSION ON INTERNATIONAL TRADE LAW (UNCITRAL) UNCITRAL Conciliation Rules Contents GENERAL ASSEMBLY RESOLUTION 35/52 UNCITRAL CONCILIATION RULES Article 1: Application of the rules Article
More informationMODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS
MODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS International Trade Centre, August 2010 Contents Foreword Acknowledgements Introduction Chapter 1 International Contractual
More information10 20 ARBITRATION RULES
2010 ARBITRATION RULES MODEL ARBITRATION CLAUSE Any dispute, controversy or claim arising out of or in connection with this contract, or the breach, termination or invalidity thereof, shall be finally
More informationIn the United States District Court for the Northern District of Georgia Atlanta Division
Case 1:14-cv-02211-AT Document 61-1 Filed 12/28/15 Page 1 of 20 In the United States District Court for the Northern District of Georgia Atlanta Division Consumer Financial Protection Bureau, Plaintiff,
More informationGeneral Terms and Conditions for Working Capital Insurance for Loans to Sub-Contractors GTC WC-SC
General Terms and Conditions for Working Capital Insurance for Loans to Sub-Contractors GTC WC-SC Valid from 31 March 2012 (Version 2.2/2012) Table of Contents 1 Object and Scope of the Insurance 3 2 Liability
More informationTerms & Conditions Verder B.V. (02031806) Filed at the Chamber of Commerce on 29-01-2015
Terms & Conditions Verder B.V. (02031806) Filed at the Chamber of Commerce on 29-01-2015 1. General 1.1 These terms and conditions use the following terms and definitions: Product: items, as well as services
More informationSCC ARBITRATION RULES OF THE ARBITRATION INSTITUTE OF THE STOCKHOLM CHAMBER OF COMMERCE
APPENDIX 3.13 SCC ARBITRATION RULES OF THE ARBITRATION INSTITUTE OF THE STOCKHOLM CHAMBER OF COMMERCE (as from 1 January 2010) Arbitration Institute of the Stockholm Chamber of Commerce Article 1 About
More informationb) General Sales Conditions: these general sales and delivery conditions;
GENERAL SALES AND DELIVERY CONDITIONS OF LABORI INTERNATIONAL B.V. 1. DEFINITIONS 1.1 In these general sales and delivery conditions the following terms have the following meaning: a) Buyer: the person
More informationTerms and Conditions. 3012436v2 12285.01010
Terms and Conditions ACCEPTANCE. Except as otherwise agreed in a written agreement signed by both parties, these Terms and Conditions will govern Buyer s purchase order. BI Technologies acceptance of Buyer
More informationExecutive summary and overview of the national report for Denmark
Executive summary and overview of the national report for Denmark Section I Summary of findings There is no special legislation concerning damages for breach of EC or national competition law in Denmark,
More informationGENERAL TERMS OF PURCHASE of Globe Chemicals GmbH valid for contracts with merchants effective May 1 st, 2005
GENERAL TERMS OF PURCHASE of Globe Chemicals GmbH valid for contracts with merchants effective May 1 st, 2005 1. General 1.1 The terms of purchase set out below are valid for all also future purchases
More informationGeneral Terms and Conditions for Supplier Credit Insurance GTC S
General Terms and Conditions for Supplier Credit Insurance GTC S Valid from 31 March 2012 (Version 2.2/2012) Table of Contents 1 Object and Scope of the Insurance 3 2 Liability Period 3 3 Insured Risks
More information1. The place of performance for all aspects of the delivery agreement shall be the place of the commercial business of the seller.
Standard Conditions of the German Textile Industry Version as of: 01/01/2015 1 Scope of Application 1. The standard conditions shall apply solely between merchants. 2. All deliveries and services of the
More informationGENERAL TERMS AND CONDITIONS
GENERAL TERMS AND CONDITIONS OF: Europe Retail Packing BV ABC Westland 315 2685 DD Poeldijk hereinafter to be referred to as: ERP Article 1 Definitions 1. In the present general terms and conditions, the
More informationThe International Sales Law aka THE 1980 VIENNA SALES CONVENTION
The International Sales Law aka THE 1980 VIENNA SALES CONVENTION A brief exposé on the international law in general and on Section II of the CISG and the issue of conformity of goods with examples from
More informationDOCUMENT. General Purchase Conditions
1. Scope 1.1 These general purchase conditions (hereinafter the GPC ) shall apply to all kinds of materials, articles, products and services related to them, (hereinafter Products ), offered, sold or supplied
More information(1) Our offers are subject to change, unless they are explicitly designated as
General Terms of Sales and Service of MBA Design & Display Produkt GmbH (Status: May 2015) 1 The scope of application (1) Our General Terms and Conditions (GTC) apply exclusively and without further formal
More informationTITLE XVIII ENFORCEMENT AND RECOGNITION OF FOREIGN MONEY JUDGMENTS
TITLE XVIII ENFORCEMENT AND RECOGNITION OF FOREIGN MONEY JUDGMENTS 1 CHAPTER 1. ENFORCEMENT OF JUDGMENT... 3 18-1-1 Definitions... 3 18-1-2 Applicability... 3 18-1-3 Recognition and Enforcement... 3 18-1-4
More informationEASY LED Oy General Terms of Sale
EASY LED Oy General Terms of Sale 1. Scope of application These General Terms of Sale (hereinafter referred to as the Terms ) shall be applied to the sale and supply of lighting products manufactured by
More informationCHAPTER NINE DISPUTES SETTLEMENT ARTICLE 187 Scope of the Chapter The provisions of this Chapter shall apply to the settlement of disputes concerning
CHAPTER NINE DISPUTES SETTLEMENT ARTICLE 187 Scope of the Chapter The provisions of this Chapter shall apply to the settlement of disputes concerning the interpretation and application of the Treaty, including:
More informationMODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS
MODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS International Trade Centre, August 2010 Contents Foreword Acknowledgements Chapter 1 International Contractual Alliance ITC
More informationGENERAL TERMS AND CONDITIONS
GENERAL TERMS AND CONDITIONS Contents A. SCOPE...3 B. CONFIDENTIALITY, NAME, INTELLECTUAL PROPERTY AND TAX EXEMPT STATUS OF THE WTO...3 B.1. Confidentiality...3 B.2. Use of the name, logo or official seal
More informationHow To Accept A Delivery From A Customer
General Selling, Service, Delivery and Payment Conditions of BORGERS USA Corp., Vance, Alabama ( GSC ) (March 2015) 1. General Provisions These General Selling, Service, Delivery and Payment Conditions
More information9. Unforeseen Delay 9.1 neither party shall be responsible for any losses resulting in the fulfilment of any of the terms of the
STANDARD TERMS AND CONDITIONS OF BUSINESS 1. Definitions 1.1 In the context of these standard terms and conditions of business:- 1.1.1 'the seller' means Entwistle and Joynt Limited of 62 Darlington Street
More informationTerms of sale, payment and delivery. I. General Commitment
Terms of sale, payment and delivery I. General Commitment 1. Our deliveries, services and offers are exclusively based on these terms of sale, payment and delivery (General Business Terms). Deviating terms,
More informationInter-American Commercial Arbitration Commission RULES As Amended and in Effect April 1, 2002
Inter-American Commercial Arbitration Commission RULES As Amended and in Effect April 1, 2002 Scope of Application SECTION I. INTRODUCTORY RULES Article 1 Where the parties to a contract have agreed in
More informationIn these conditions "the Company" means Pro Formance Metals Limited
Terms and Conditions of Sale In these conditions "the Company" means Pro Formance Metals Limited 1. ALL CONTRACTS OF SALE - incorporate these Terms and Conditions. Any variation of these Terms and Conditions
More informationIRAINHAM STEEL I. Company Registration No...
IRAINHAM STEEL I Rainham Steel Company Ltd, Kathryn House, Manor Way Rainham, Essex, RM13 8RE Tel' 01708522311 Fax' 01708 559024 CUSTOMER CREDIT ACCOUNT APPLICATION Full Business Trading Name Registered
More informationGeneral Terms and Conditions for Pre-shipment Risk Insurance GTC P
General Terms and Conditions for Pre-shipment Risk Insurance GTC P Valid from 31 March 2012 (Version 2.2/2012) Table of Contents 1 Object and Scope of the Insurance 3 2 Liability Period 4 3 Insured Risks
More informationGeneral Contractual Terms and Conditions of KRÁLOVOPOLSKÁ SLÉVÁRNA, s.r.o.
General Contractual Terms and Conditions of KRÁLOVOPOLSKÁ SLÉVÁRNA, s.r.o. 1. General provisions 1.1. These terms and conditions (TC) govern the sale of products and services (hereinafter as goods ) of
More informationConsolidated implied terms in park home pitch agreements
Park homes factsheet Consolidated implied terms in park home pitch agreements Implied terms are contractual terms which are implied by statute into the pitch agreement between a resident and a park owner
More informationAdministered Arbitration Rules
22 00 11 33 Administered Arbitration Rules HONG KONG INTERNATIONAL ARBITRATION CENTRE ADMINISTERED ARBITRATION RULES Introduction These Rules have been adopted by the Council of the Hong Kong International
More informationDUIF S FLORIST ARTICLES B.V.
General Terms and Conditions of Sale and Delivery of DUIF S FLORIST ARTICLES B.V. having its registered office in Aalsmeer, the Netherlands, and principal place of business at Legmeerdijk 281 in (1432
More informationRULES OF THE GEORGIAN SECURITIES CENTRAL SECURITIES DEPOSITORY ON SETTLEMENT OF DISPUTES
Approved: by the General Meeting of Georgian Securities Central Depository October 25, 1999 RULES OF THE GEORGIAN SECURITIES CENTRAL SECURITIES DEPOSITORY ON SETTLEMENT OF DISPUTES TBILISI 1999 Introduction
More informationMODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS
MODEL CONTRACTS FOR SMALL FIRMS LEGAL GUIDANCE FOR DOING INTERNATIONAL BUSINESS International Trade Centre, August 2010 Contents Foreword Acknowledgements Introduction Chapter 1 International Contractual
More information2.4 In case of conflict between these Conditions and the terms of the Agreement, the Agreement shall prevail.
GENERAL TERMS AND CONDITIONS OF PURCHASE OF FONDEL ALLOYS LIMITED 1. Definitions For the purpose of these general terms and conditions of purchase Agreement shall mean the agreement entered into between
More information2.2 Stipulations deviating from these conditions must be agreed in writing.
GENERAL PURCHASE CONDITIONS OF THE MEMBERS OF THE NEDERLANDSE VERENIGING VAN ZIEKENHUIZEN [NETHERLANDS ASSOCIATION OF HOSPITALS], ARCARES, GGZ NEDERLAND AND THE VERENIGING GEHANDICAPTENZORG NEDERLAND [ASSOCIATION
More information15. Competent Court 15.1. The competent court within the district of the Seller s place of business takes cognizance of all disputes which may arise
General Terms and Conditions of Sale of Fruit Factor B.V. having its registered office in Ridderkerk with the place of business Handelsweg 120, 2988 DC in Ridderkerk, the Netherlands. Registered with the
More informationGeneral Terms and Conditions of ICTRecht
General Terms and Conditions of ICTRecht Version dated 1 September 2012 These General Terms and Conditions (the General Conditions ) govern each Contract with, and performance of work by, ICTRecht. Any
More informationGeneral Conditions for Loans reference No.: General Terms and Conditions for Loans dated 1 March 2016
General Conditions for Loans reference No.: General Terms and Conditions for Loans dated 1 March 2016 These General Conditions for Loans is made between ( Lender )and the Entity who signs the Schedule
More informationARBITRATION RULES OF THE COURT OF ARBITRATION AT THE POLISH CHAMBER OF COMMERCE
ARBITRATION RULES OF THE COURT OF ARBITRATION AT THE POLISH CHAMBER OF COMMERCE Chapter I Introductory provisions 1 Court of Arbitration 1. The Court of Arbitration at the Polish Chamber of Commerce (the
More informationGeneral Terms and Conditions for Contract Bond Insurance GTC CB
General Terms and Conditions for Contract Bond Insurance GTC CB Valid from 31 March 2012 (Version 2.2/2012) Table of Contents 1 Object and Scope of the Insurance 3 2 Liability Period 3 3 Insured Risks
More informationStephan Wilske and Ismael Esin, Act on Private International and Procedural Law (Act No. 5718), A contribution by the ITA Board of Reporters,
Act on Private International and Procedural Law (1) (Act No. 5718) Stephan Wilske and Ismael Esin, Act on Private International and Procedural Law (Act No. 5718), A contribution by the ITA Board of Reporters,
More informationGENERAL TERMS AND CONDITIONS OF SALE (N/GCOS/1301)
GENERAL TERMS AND CONDITIONS OF SALE () Definitions Seller: The Nutreco entity identified in the quotation and/or order. Buyer: The party that enters into a purchase agreement with the Seller for the purchase
More informationJOHN DEERE DIFFERENTIAL CORRECTION SOFTWARE LICENSE AGREEMENT
JOHN DEERE DIFFERENTIAL CORRECTION SOFTWARE LICENSE AGREEMENT IMPORTANT -- READ CAREFULLY. THIS IS A LEGAL CONTRACT BETWEEN YOU AND JOHN DEERE SHARED SERVICES, INC., A CORPORATION HAVING A PRINCIPAL ADDRESS
More informationIN THE MATTER OF AN ARBITRATION UNDER CHAPTER 11 OF THE NORTH AMERICAN FREE TRADE AGREEMENT AND THE UNCITRAL ARBITRATION RULES
IN THE MATTER OF AN ARBITRATION UNDER CHAPTER 11 OF THE NORTH AMERICAN FREE TRADE AGREEMENT AND THE UNCITRAL ARBITRATION RULES BETWEEN: MERRILL & RING FORESTRY L.P. CLAIMANT AND THE GOVERNMENT OF CANADA
More informationRULE 39 OFFER TO SETTLE
RULE 39 OFFER TO SETTLE Definitions (1) In this rule: Where available "defendant" includes "respondent"; "double costs" means double the fees allowed under Rule 60(2) and includes the disbursements allowed
More informationGENERAL CONDITIONS OF LATVIAN NATIONAL ASSOCIATION OF FREIGHT FORWARDERS and LOGISTIC LAFF
GENERAL CONDITIONS OF LATVIAN NATIONAL ASSOCIATION OF FREIGHT FORWARDERS and LOGISTIC LAFF Effective as of January 1, 2007 These conditions taking effect on January 1, 2007, have been agreed between the
More informationUnited Nations Convention On The Limitation Period In The International Sale Of Goods (New York, 14 June 1974) United Nations (UN)
United Nations Convention On The Limitation Period In The International Sale Of Goods (New United Nations (UN) Copyright 1974 United Nations (UN) ii Contents Contents Preamble 1 PART I. Substantive Provisions
More informationFALSE CLAIMS ACT STATUTORY LANGUAGE
33 U.S.C. 3729-33 FALSE CLAIMS ACT STATUTORY LANGUAGE 31 U.S.C. 3729. False claims (a) LIABILITY FOR CERTAIN ACTS. (1) IN GENERAL. Subject to paragraph (2), any person who (A) knowingly presents, or causes
More informationFACTORING INSURANCE CONTRACT GENERAL CONDITIONS
FACTORING INSURANCE CONTRACT GENERAL CONDITIONS OP/FI-FACT/034-GC-eng 1 GENERAL CONDITIONS Article 1 - DEFINITIONS For the purposes of this Contract: 1. Arab Origin shall mean, for the purpose of this
More informationPREFACE. The Contract for the Supply and Delivery of Goods has been prepared for use in supplies contracts which have the following characteristics:
Supply Chain Management Document Number: SCM006 Document Title: Supply Contract Version: 01 Purpose: Standard contract for all supplies of goods PREFACE The Contract for the Supply and Delivery of Goods
More informationISTANBUL ARBITRATION CENTRE ARBITRATION RULES
ISTANBUL ARBITRATION CENTRE ARBITRATION RULES Section I INTRODUCTORY PROVISIONS ARTICLE 1 The Istanbul Arbitration Centre and the Board of Arbitration 1. The Istanbul Arbitration Centre is an independent
More informationWork Injury Compensation Insurance (Contract)
Work Injury Compensation Insurance (Contract) Policy Wordings Please read this insurance Policy carefully to ensure that you understand the terms and conditions and that this Policy meets your requirements.
More information16TH FEBRUARY 1994, LAW GOVERNING ORGANISED TRAVEL CONTRACTS AND TRAVEL AGENCY CONTRACTS
16TH FEBRUARY 1994, LAW GOVERNING ORGANISED TRAVEL CONTRACTS AND TRAVEL AGENCY CONTRACTS CHAPTER 1 - DEFINITIONS AND AREA OF APPLICATION Article 1 - For the purpose of application of this law, the following
More informationARBITRATOR S GUIDELINES
ARBITRATOR S GUIDELINES 2 August 2014 Address: P.O. Box 16050 103 21 Stockholm, Sweden Phone: + 46 8 555 100 00 Fax: + 46 8 566 316 00 arbitration@chamber.se www.sccinstitute.com 2 INTRODUCTION The purpose
More informationPERSONAL INJURIES BAR ASSOCIATION STANDARD TERMS AND CONDITIONS TREATED AS ANNEXED TO THE CONDITIONAL FEE AGREEMENT BETWEEN SOLICITOR AND COUNSEL
PERSONAL INJURIES BAR ASSOCIATION STANDARD TERMS AND CONDITIONS TREATED AS ANNEXED TO THE CONDITIONAL FEE AGREEMENT BETWEEN SOLICITOR AND COUNSEL FOR USE AFTER 31 JANUARY 2013 PLEASE NOTE: THESE TERMS
More informationDESIRING to intensify economic cooperation between both States;
AGREEMENT BETWEEN THE GOVERNMENT OF THE REPUBLIC OF TRINIDAD AND TOBAGO AND THE GOVERNMENT OF THE REPUBLIC OF CUBA ON THE RECIPROCAL PROMOTION AND PROTECTION OF INVESTMENTS The Government of the Republic
More informationGeneral Procurement Terms and Conditions of SMEPRO INTERNATIONAL B.V.
General Procurement Terms and Conditions of SMEPRO INTERNATIONAL B.V. Article 1 - Definitions In these General Procurement Terms and Conditions, the terms below have the following meaning: SMEPRO : The
More informationThe Hague Convention on the Civil Aspects of International Child Abduction
The Hague Convention on the Civil Aspects of International Child Abduction The States signatory to the present Convention, Firmly convinced that the interests of children are of paramount importance in
More informationGeneral Terms and Conditions of: One-Q B.V. Nummer 49 9091 BA Wyns. Chamber of Commerce No. for Noord Nederland: 011173550000 (AS 224-12)
General Terms and Conditions of: One-Q B.V. Nummer 49 9091 BA Wyns (AS 224-12) Chamber of Commerce No. for Noord Nederland: 011173550000 Article 1: Applicability, definitions 1. These Terms and Conditions
More informationGeneral Terms and Conditions for the Purchase and Maintenance of Hardware
General Terms and Conditions for the Purchase and Maintenance of Hardware A COMMON INTRODUCTORY PROVISIONS 1 Object and validity 1.1 The present General Terms and Conditions (GTC) govern the conclusion,
More information5. Conferment of rights and duties resulting from the contract to third parties by the Orderer need prior written affirmation by the Contractor.
General Terms and Conditions of INGENERIC GmbH, Dennewartstr. 25-27, 52068 Aachen, Germany Scope of Application The following Terms and Conditions shall apply to all current and future agreements entered
More informationMIB Uninsured Agreement
MIB Uninsured Agreement THIS AGREEMENT is made on the 3rd July 2015 between the SECRETARY OF STATE ( the Secretary of State ) and the MOTOR INSURERS BUREAU ( MIB ), whose registered office is for the time
More informationGENERAL TERMS & CONDITIONS
GENERAL COMMERCIAL TERMS & CONDITIONS in case of deliveries in the non-eu 1 GENERAL TERMS & CONDITIONS The Order Confirmation and the General Terms & Conditions (GCT&C) regulate the relationship of the
More informationUNCITRAL Arbitration Rules
UNCITRAL UNITED NATIONS COMMISSION ON INTERNATIONAL TRADE LAW UNCITRAL Arbitration Rules (as revised in 2010) UNITED NATIONS Further information may be obtained from: UNCITRAL secretariat, Vienna International
More informationDACHSER TURKEY HAVA VE DENIZ TASIMACILIGI A.S. RULES FOR FREIGHT FORWARDING SERVICES
DACHSER TURKEY HAVA VE DENIZ TASIMACILIGI A.S. RULES FOR FREIGHT FORWARDING SERVICES PART I GENERAL PROVISIONS CONDITIONS OF APPLICATION 1.1. These rules shall be binding upon any reference, whether verbal
More informationThese Terms & Conditions may only be used by members of Koninklijke Metaalunie.
METAALUNIE CONDITIONS General delivery and payment conditions of Koninklijke Metaalunie (the Dutch organisation for small and medium-sized enterprises in the metal industry), referred to as the METAALUNIE
More informationDutch Association of Sport Product Manufacturers and Wholesalers
General terms and conditions of Sale and Delivery Of the Vereniging van Fabrikanten en Groothandelaren in Sportbenodigdheden (F.G.H.S.) [Dutch Association of Sport Product Manufacturers and Wholesalers]
More informationSales Agency Contract
Sales Agency Contract Between: (Supplier) whose registered office is at: (hereinafter called "the Principal") and: (Sales Agency) whose registered office is at: it is agreed as follow: (hereinafter called
More informationArticle 2. Offers and quotations
1 Article 1. General 1. These terms and conditions apply to all offers, quotations and agreements between Smets Food Trading B.V., with registered offices in (6131 GR) Sittard, at Odasingel 473, hereinafter
More informationUnited Nations Convention on Jurisdictional Immunities of States and Their Property 2004
United Nations Convention on Jurisdictional Immunities of States and Their Property 2004 Adopted by the General Assembly of the United Nations on 2 December 2004. Not yet in force. See General Assembly
More informationMOTOR INSURER S BUREAU OF IRELAND
MOTOR INSURER S BUREAU OF IRELAND COMPENSATION OF UNINSURED ROAD ACCIDENT VICTIMS Agreement dated 29th January 2009 between the Minister for Transport and the Motor Insurers Bureau of Ireland (MIBI) AGREEMENT
More informationCross Border Debt Collection Procedures
Cross Border Debt Collection Procedures Bulgaria Hungary Serbia Slovakia Romania Time Limit Time Limit Time Limit Time Limit Time Limit Time limits are connected with prescription.standard prescription
More informationBreed Communications Limited - limited company consultancy agreement 230113
Limited Company Consultancy Master Agreement DATED BETWEEN:- (1) Breed Communications Limited (Company Number 4809384) whose registered office is c/o Hilton Consulting, 119 The Hub, 300 Kensal Rise, London
More informationGENERAL CONDITIONS OF SUPPLY
GENERAL CONDITIONS OF SUPPLY Dated 8/2004 All of our deliveries and services to individuals and private companies are governed exclusively by the following terms and conditions: I. Offer and Acceptance/Written
More informationThe Government of Republic of India and the Government of The Republic of Cyprus (hereinafter referred to as the Contracting Parties );
AGREEMENT BETWEEN THE GOVERNMENT OF THE REPUBLIC OF INDIA AND THE GOVERNMENT OF REPUBLIC OF CYPRUS FOR THE MUTUAL PROMOTION AND PROTECTION OF INVESTMENTS The Government of Republic of India and the Government
More informationGeneral purchasing terms and conditions
General purchasing terms and conditions 1. Applicability 1.1. These general purchasing terms and conditions ( General Conditions ) apply to all purchases of products and services made by NV Bekaert SA
More informationSMALL CLAIMS RULES. (d) Record of Proceedings. A record shall be made of all small claims court proceedings.
SMALL CLAIMS RULES Rule 501. Scope and Purpose (a) How Known and Cited. These rules for the small claims division for the county court are additions to C.R.C.P. and shall be known and cited as the Colorado
More informationASSEMBLY BILL No. 597
AMENDED IN ASSEMBLY APRIL 14, 2015 california legislature 2015 16 regular session ASSEMBLY BILL No. 597 Introduced by Assembly Member Cooley February 24, 2015 An act to amend Sections 36 and 877 of, and
More informationLoan regulations (Adopted by the Administrative Council by Resolution 1562, on 14 November 2013)
Loan regulations (Adopted by the Administrative Council by Resolution 1562, on 14 November 2013) Edition updated in November 2014 CHAPTER 1 Object of the Loan Regulations ARTICLE 1.1 Object of the Loan
More informationSAMPLE VENDOR AGREEMENT VENDOR # 00000. Sample Vendor, Vendor Title Sample Vendor Company. Evelyn V. Martinez, Executive Director
VENDOR AGREEMENT VENDOR # 00000 TO: FROM: Sample Vendor, Vendor Title Sample Vendor Company Evelyn V. Martinez, Executive Director DATE: SUBJECT: Sample Vendor Project This Agreement, by and between the
More informationLIMITATIONS. The Limitations Act. being
1 LIMITATIONS c. L-16.1 The Limitations Act being Chapter L-16.1* of The Statutes of Saskatchewan, 2004 (effective May 1, 2005), as amended by the Statutes of Saskatchewan, 2007, c.28. *NOTE: Pursuant
More informationStandard conditions of purchase
Standard conditions of purchase 1 OFFER AND ACCEPTANCE 2 PROPERTY, RISK & DELIVERY 3 PRICES & RATES The Supplier shall provide all Goods and Services in accordance with the terms and conditions set out
More informationUNITED STATES DISTRICT COURT MIDDLE DISTRICT OF FLORIDA, TAMPA DIVISION
UNITED STATES DISTRICT COURT MIDDLE DISTRICT OF FLORIDA, TAMPA DIVISION Consumer Financial Protection Bureau and Office of the Attorney General, State of Florida, Department of Legal Affairs, Case No.
More informationCANADA PROVINCE OF QUEBEC ENFORCEMENT OF FOREIGN JUDGMENT
CANADA PROVINCE OF QUEBEC Part I: ENFORCEMENT OF FOREIGN JUDGMENT 1. What procedures exist for recognition and enforcement of foreign judgments pursuant to conventions? a. First of all it is important
More informationLAW OF DAMAGES AND REMEDIES. DIFC LAW No. 7 of 2005
------------------------------------------------------------------------------------------ LAW OF DAMAGES AND REMEDIES DIFC LAW No. 7 of 2005 ------------------------------------------------------------------------------------------
More informationInternational Purchasing Conditions for Suppliers not Resident in Germany
International Purchasing Conditions for Suppliers not Resident in Germany I. Application of the International Purchasing Conditions 1. These International Purchasing Conditions apply to all suppliers to
More information