ITEM DOCUMENT CONTROL MANAGEMENT DESCRIPTION:
|
|
- Jared Mosley
- 8 years ago
- Views:
Transcription
1 DESCRIPTION: Under this item the Contractor shall provide an individual(s), designated the Document Control Specialist. The Document Control Specialist shall use a software to prepare, status, electronically file, process and send all project correspondence, shop drawings, requests for information, meeting minutes, schedule narratives, and other standard NYSDOT construction Contract Business Practices. The software shall be a Document Control System (DCS) designated by the Department. This Document Control System (DCS) will also provide uniform project information and reporting. The Contractor shall also be required to provide training in the DCS to all necessary Contractor, Subcontractor, Material Suppliers and Fabricators, and NYSDOT staff as identified in this Specification and the Special Note in the Contract Proposal. The Contractor and the Document Control Specialist will access the DCS via the internet. Licenses for the DCS will be procured or provided in accordance with the Special Note in the Contract Proposal. All information that resides on the Document Control System (DCS) server shall become the sole property of the Department. DEFINITIONS Document Control System (DCS) - The Document Control System is the software application that provides document management along with document control and collaboration tools to facilitate construction project management and contract administration in a web based environment. The Document Control System will be a software application as identified in the Proposal Special Note which will be physically located in a secure location designated by the Department on the Document Control System (DCS) Server. Document Control System (DCS) Server The secure common file server provided by the Department for processing and storage of all DCS contract documents. Document Control System (DCS) Licenses The license required to access the DCS. All individuals accessing the DCS shall require use of individual licenses. These licenses shall either be procured by the Contractor or provided by the Department in accordance with the Proposal Special Note. Ownership of these licenses upon purchase shall also be in accordance with the Proposal Special Note. Document Control Specialist The Contractor employee designated by the Contractor who ensures the Contractor and all other parties utilize the DCS in accordance with this Specification. The Document Control Specialist shall be approved by the Department. The Document Control Specialist shall prepare, status, electronically file and send all project correspondence, Shop Drawings, Requests For Information, meeting minutes, schedule narratives, and other standard NYSDOT construction Contract Business Practices. A primary function of the document control system is to ensure timely processing of all contract documentation in coordination with the contract Progress Schedule. Additionally, named Document Control Specialist shall be responsible for maintaining information related to the responsibility, status, elapsed time since submission, held time, and a history of all submittal revisions. This individual is typically one of the Contractor s administrative employees. Page 1 of 6 10/15/2015
2 Document Control System (DCS) Training The dedicated training in the DCS system provided by the Contractor or a third party designee. The training shall be planned, organized, scheduled, coordinated, implemented and provided by the Contractor or its designee. The Contractor shall provide the minimum training described in, and for up to the maximum number of persons designated in, the Proposal Special Note. DCS training shall be provided to both Department and Contractor s Personnel. DCS Training shall consist of providing the necessary training accommodations, materials, manpower, professional services, equipment, travel for training, and training materials necessary to complete the training specified. Travel and accommodations to participate in the DCS training for Department Personnel shall not be the responsibility of the Contractor. Department Personnel All personnel employed by the Department of Transportation requiring access to the DCS. This includes Consultants or sub-consultants funded directly by the Department. Contractor Personnel All non-departmental persons requiring access to the Document Control System. These persons may include contractor, subcontractor, supplier, and fabricator personnel. CONSTRUCTION DETAILS A. DOCUMENT CONTROL SPECIALIST AND OTHER DCS ACSSESSING PERSONNEL: The Document Control Specialist shall be designated by name, in writing with a resume of their qualifications, within five (5) calendar days of the award of the Contract and shall not be changed without prior written notice to the Department. Although the Contractor may designate more than one person to perform the Document Control Specialist role, one person shall be responsible for coordinating the work of these individuals and shall be knowledgeable of the status of all contract documentation aspects of the work throughout the length of the Contract. The submission of the Document Control Specialist for approval may be made ahead of the DCS training, final approval and access to the DCS shall not be granted until the satisfactory completion of the DCS training by the proposed candidate. B. DOCUMENT CONTROL SYSTEM ACCESS REQUIREMENTS: Within five (5) days of Contract Award, the Contractor shall submit to the EIC a completed and signed Request For Access form requesting the Department establish a user account for the employee designated as the Document Control Specialist to logon to Document Control System. Access forms and access procedures can be found at location noted on the Proposal Special Note. Page 2 of 6 10/15/2015
3 The Contractor can submit additional Request For Access forms to the EIC to allow contractor personnel to access the DCS. The Contractor shall specify on the Request for Access form the contractor Role they are requesting for these users in the DCS application. All Contractor personnel requesting access authorization shall either complete the DCS Training provided as part of this specification or have previously completed a training course in the DCS meeting or exceeding the requirements of the DCS Training. Where persons have previously completed the necessary training, certification of adequate completion of training shall be provided prior to access to the DCS being granted by the Department. Request for Access may be submitted ahead of the completion of DCS training, but final issuance of a user identification and password shall not be completed until DCS training is successfully completed. C. DOCUMENTATION REQUIREMENTS: 1. Requirements: The Document Control System data, records and information shall not be a substitution or perceived to be required in lieu of any information requested or required by any other construction management software being utilized by the Department on the Contract. The informational requirements for all software utilized on the Contract shall be met by the Document Control Specialist and the Contractor. All written correspondence from the Contractor, or the Contractor s agents, to the Department, except as specified, for the duration of the project shall be produced and controlled using the designated Document Control System (DCS). All written correspondence shall include, but is not limited to: transmittals, meeting minutes, requests for information (RFI s), shop drawings, CPM schedule requirements, force account submittals, field memos, notices, letters, and punch lists. All common correspondence files (submittals, requests, answers, changes, reports, minutes, agendas, letters, etc) shall be generated from, and stored within the DCS server, including any and all file attachments. The Contractor is responsible for utilizing the DCS for all requirements of this specification for all materials generated after Contract Letting, even those generated prior to any scheduled formal training. All documents and materials generated after Letting and prior to access authorization shall be entered into the DCS upon access being granted to the Document Control Specialist. The Contractor is responsible to coordinate the overall creation and submission of all project documentation to meet the requirements of the Manual of Uniform Record Keeping (MURK), Contract Documents, and the project schedule. The Contractor is encouraged to supply the Department with corporate logos, formats, files, etc. to facilitate the creation and utilization of custom forms and reports. Any materials generated by the Contractor that require Department identification shall be prepared in accordance with Departmental branding standards. NYSDOT branding materials shall be provided at the Contractor s request. The Contractor shall be required to follow all document management business practice and processes identified by the Department. Document naming conventions, numbering conventions, title and identifier information for document management, and additional Page 3 of 6 10/15/2015
4 document information required to fully detail and describe the specific information and impact shall be designated by the Department and shall be followed by the Contractor. Unless specified or approved by the Department, all attachments including drawings shall be in Adobe PDF format in a version that is accessible to all parties. Multiple Submittal documents shall be combined into a multiple page PDF file. The maximum file size of a multiple page PDF file shall be 50 MB. Each package may have several PDF files attached Documents (letters, logs, drawings, sketches, etc) to be transmitted to the Department by the Contractor, for which the Contractor does not have an electronic version, shall be scanned, converted into an Adobe Acrobat PDF format, and attached accordingly in the DCS. Documentation shall be entered into the Document Control System by the generator of the information. Meeting minutes shall be entered by the organization preparing meeting minutes. Documents and shall be entered by the organization generating the document. Where the responsibility for entering information resides with the Contractor that duty shall be the responsibility of the Document Control Specialist. The Document Control Specialist shall be responsible for monitoring all logs and lists held in the Document Control System and conduct all work necessary to respond and coordinate the resolution of issues and items identified on such lists and logs. The Document Control Specialist may also submit requests on behalf of the Contractor for additions or changes to any list or log. Such requests will be reviewed and a Determination for the addition and/or change made by the Department. An example of lists and logs are Punch Lists, Noncompliance notices, and Issue logs. The Department reserves the right to modify the requirements of this specification as needed to meet project specific documentation processing requirements. 2. Exceptions: Correspondence between the Main Office Contract Management Bureau and the Contractor shall not be transmitted through the Document Control System. The use of the DCS is not required for Contractor proprietary cost and contract information, and any information deemed confidential by the Contractor and approved by the Department. D. DOCUMENTATION CONTROL SYSTEM AVAILABILITY: It is anticipated the DCS shall be available for Contractor use at all times unless system maintenance (i.e. backups, upgrades, etc) is being performed. System maintenance will generally be limited to non-core business hours. In the event a Contractor s authorized user cannot access the control system, the Contractor shall notify the Engineer-in-Charge or his/her designee. In the event the DCS becomes unavailable during normal business hours for an extended period of time, the Contractor may issue correspondence requiring immediate attention by the Department in hard copy format. System maintenance or system failure during normal business hours shall not be grounds for issuance of any hard copy format documentation or non use of the DCS. The hard copy correspondence must be Page 4 of 6 10/15/2015
5 entered into the control system immediately upon the DCS becoming available again. Inability by the Contractor to gain access to the document control system for any reason shall not be grounds for claim. E. SUBMITTAL DURATION REQUIREMENTS: The Department shall be allocated the appropriate durations outlined in the contract documents and/or the Steel Construction Manual for submission approval activities, Shop Drawing approval activities, Requests For Information and Requests For Deviation. For all other activities without a specific time period allocated in the contract documents for Department review a minimum of twenty (20) working days (using a 5-day work calendar, exclusive of holidays) shall be allocated for review and approval of each submittal. Whenever multiple Contractor submittals are under review by the Department, the Contractor shall prioritize the submittals and notify the Department thereof. The Department shall not be held responsible for any delay associated with the approval or rejection of any substitution or other revisions proposed by the Contractor. F. DCS TRAINING REQUIREMENTS: Within twenty-one (21) working days of the Pre-Construction Meeting, the Contractor shall complete all the requirements of DCS Training found in the Proposal Special Note. Deviation from this timetable or from any of the requirements of the Proposal Special Note shall require a request in writing and shall be approved by the Department. A list of all Contractor personnel requiring training shall be provided to the Department prior to scheduling training. The Contractor shall provide DCS Training for Departmental and Non-Departmental personnel with Department personnel and total personnel not to exceed the maximum numbers listed in the Proposal Special Note. The Contractor shall determine all logistical training information and submit to the Department for approval. A minimum of fourteen (14) calendar days notice shall be given prior to any scheduled training. Training required for DCS access for all contractor personnel who are unable to attend the DCS training shall be the responsibility of the Contractor and all additional training outside of the DCS training shall not qualify for reimbursement. All personnel participating in DCS Training shall be issued official certificates upon successful completion of the training. Certificates shall include the participant s name, the name of the course completed, and any third party training provider s company names and addresses. The certificate shall list trainer s name and title and be signed by the trainer. G. COMPUTER AND SYSTEM REQUIREMENTS: The Contractor shall provide all IT systems and equipment necessary for its Document Control Specialist and any other non-department personnel accessing the DCS. The equipment shall also include all necessary supplemental software and compatibility necessary to send and receive all required documents within the DCS in a format viewable by the department and to complete the requirements of this specification. The general minimum equipment specifications and supplemental software requirements are included in the Proposal Special Note. The Contractor shall provide to the Department valid addresses for each authorized user compatible with Department systems and the DCS. The Contractor shall ensure anti-virus software is installed, maintained, and in operation on any computer accessing the Department s DCS. The support for all contractor supplied equipment and Page 5 of 6 10/15/2015
6 systems shall be its responsibility. The Contractor shall employ all necessary support to ensure access to and use of the Department s Network based software. The Contractor s use of Department provided internet service and/or IT equipment shall not be allowed. METHOD OF MEASUREMENT: The quantity will be measured for payment on a Lump Sum basis. BASIS OF PAYMENT: The lump sum bid for this work shall include the cost of furnishing all labor, materials, equipment, professional services, expenses, travel specifically for training, overhead, profit, and other necessary items to provide any required Licenses, Training, utilize the DCS, and provide services of a Document Control Specialist. The Contractor will be reimbursed for any DCS Licenses and DCS Training based on the submission and approval of receipted costs of materials plus 5% for profit and overhead ( materials includes all labor, materials and equipment, including services provided). Any remaining monies after payment of DCS licenses and DCS Training shall be divided into equal payments corresponding to the number of whole months of the Contract and paid on a monthly basis. 1) Failure by the Contractor to utilize and regularly update the specified DCS in a manner acceptable to the Department or failure to utilize the DCS server for the storage of all project related files may result in the withholding of all contract payments pursuant to Article 8 No Payment on Contractor s Non-Compliance until such time as all specification requirements have been satisfied. 2) In the event the project extends beyond the original completion date by more than thirty (30) calendar days, and a time extension is granted to the Contractor, the Department may require the continued utilization of the Document Control System. For the time the Contract Completion Date is extended due to a Compensable Delay where the Engineer requires the work of the Document Control Specialist, payment for work to fulfill this specification shall be in accordance with Standard Specifications EXTRA WORK AND TIME RELATED COMPENSATION. MINIMUM BID ITEM The unit price shown in the proposal is the minimum bid amount required for this pay item. The contractor may bid a higher amount. But, should the amount bid be lower than the minimum required figure, the bid amount will be raised to the minimum bid required and the new figure will be used to determine the total amount bid for the Contract. Payment will be made under: Item No. Item Pay Unit Document Control Management LS Page 6 of 6 10/15/2015
Common File Server The secure common file server provided by the Department for storage of all contract documents.
DESCRIPTION: Under this item the Contractor shall prepare, status, electronically file and send all project correspondence, Shop Drawings, Requests For Information, meeting minutes, and schedule narratives
More informationMATERIALS: The Contractor shall provide the latest version of Primavera SureTrak software.
DESCRIPTION: '108-01, Start and Progress of Work, is hereby amended to require that the Contractor furnish and participate in a computerized CPM (critical path method) network scheduling system. The purpose
More informationAlexandria National Cemetery SECTION 01 32 16.13 NETWORK ANALYSIS SCHEDULE
SECTION 01 32 16.13 PART 1 - GENERAL 1.1 DESCRIPTION: A. The Contractor shall develop a Microsoft Project 2003 (or latest version) Bar Chart schedule demonstrating fulfillment of the contract requirements.
More informationEXHIBIT 2-2-C PROGRESS SCHEDULES
EXHIBIT 2-2-C PROGRESS SCHEDULES PART 1 GENERAL 1.01 SUMMARY A. The work specified in this section consists of furnishing transportation, labor, materials, equipment and incidentals necessary for preparation,
More informationSpec. Standard: 11/27/06 01310-1 Revision: 11/27/06
SECTION 01310 CONSTRUCTION SCHEDULES PART 1 - GENERAL 1.01 SCOPE: A. Construction Progress Schedule: The CONTRACTOR shall submit a detailed work progress schedule showing all work in a graphic format suitable
More informationREQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT SERVICES. Part I: Proposal Information
REQUEST FOR PROPOSAL FOR CONSTRUCTION MANAGEMENT SERVICES Part I: Proposal Information A. General Information The Berwick Area School District is soliciting proposals for construction management services
More informationMemorandum. Jeff Jasper, P.E. Director, Division of Design. Technical Support TEBM, Division of Construction. From: Jeremiah Littleton, P.E.
Memorandum To: Thru: Jeff Jasper, P.E. Director, Division of Design Rachel Mills, P.E. Technical Support TEBM, Division of Construction From: Jeremiah Littleton, P.E. Division of Construction Date: June
More informationRequest for Qualifications & Proposal. Architectural Team. Lake County School District R-1. On-Call Services. For
Request for Qualifications & Proposal Architectural Team For Lake County School District R-1 On-Call Services Provided by: Submittal Deadline: April 23, 2015 Time: 5:00 PM 1.0 Introduction On behalf of
More informationCITY OF HIGHLAND PARK
REQUEST FOR PROPOSALS CONSULTING SERVICES FOR THE PROCUREMENT OF AN ELECTRONIC DOCUMENT MANAGEMENT SYSTEM CITY OF HIGHLAND PARK PLEASE COMPLETE ATTACHMENT 1 RFP ACKNOWLEDGEMENT FORM AND RETURN TO THE CITY
More informationDocument Comparison. AIA Documents A134 2009 and A131CMc 2003
Document Comparison AIA Documents A134 2009 and A131CMc 2003 AIA Document A134 2009 is in the right-hand column. Corresponding sections of AIA Document A131 CMc 2003 are in the left-hand column. Sections
More informationMISSISSIPPI STATE UNIVERSITY Office of Planning Design and Construction Administration
SECTION 01 311 NETWORK ANALYSIS SCHEDULE Part 1.1 DESCRIPTION A. Scope: Provide projected network analysis schedules for the entire Work and revise periodically. This type of schedule is acceptable for
More informationUNIFIED FACILITIES GUIDE SPECIFICATIONS ************************************************************************** SECTION TABLE OF CONTENTS
USACE / NAVFAC / AFCEC / NASA UFGS-01 45 00.10 10 (February 2010) ----------------------------------- Preparing Activity: USACE Superseding UFGS-01 45 01.10 (January 2008) UNIFIED FACILITIES GUIDE SPECIFICATIONS
More informationSPECIFICATIONS - DETAILED PROVISIONS Section 01310 - Project Control Schedule C O N T E N T S
SPECIFICATIONS - DETAILED PROVISIONS Section 01310 - Project Control Schedule C O N T E N T S PART 1 - SCHEDULE REQUIREMENTS PROGRESS SCHEDULE... 1 PART 2 - SUBMITTAL PROCEDURES... 2 PART 3 - DEFINITIONS...
More informationInvitation to Bid and Instructions to Bidders (This is Phase I of the project please note on any Bid that it Applies to Phase I only) May 1, 2015
Invitation to Bid and Instructions to Bidders (This is Phase I of the project please note on any Bid that it Applies to Phase I only) May 1, 2015 For PROJECT : Renovation and Repair of Atlanta Jewish Academy
More informationPolicy Number: 3-804 Policy Name: Professional Services and Construction Services Procurement
Page 1 3-804 Professional Services and Construction A. Project Delivery Methods 1. A university may procure design services, construction and construction services, as applicable, under any of the following
More informationDescription: Publication Date: 9/21/2015. Closing Date/Time: Open Until Contracted
Description: The New River Valley Regional Jail Authority (NRVRJA) values and appreciates the contributions and efforts of its employees. Toward this end, the NRVRJA is committed to providing a supportive,
More informationPN 107-01/16/2009 - CRITICAL PATH METHOD PROGRESS SCHEDULE
PN 107-01/16/2009 - CRITICAL PATH METHOD PROGRESS SCHEDULE A. General. The progress schedule required for this project is the critical path method schedule (CPM schedule). The Contractor shall designate
More informationSECTION 01 32 00 - PROJECT PLANNING AND SCHEDULING PART 1: GENERAL 1.1 DEFINITIONS
SECTION 01 32 00 - PROJECT PLANNING AND SCHEDULING PART 1: GENERAL 1.1 DEFINITIONS A. The term Baseline Schedule, as used throughout the contract documents, shall refer to a fixed projection of the project
More informationConstruction Management Services Delmar School District RFP No. DSD16001-CONSTR_MAN
Construction Management Services Delmar School District RFP No. DSD16001-CONSTR_MAN The Delmar School District (DSD) is seeking the professional services of a Construction Management (CM) firm for the
More informationSection 100 Contractor Quality Control Program
7/21/2014 AC 150/5370-10G Section 100 Contractor Quality Control Program 100-01 General. When the specification requires a Contractor Quality Control Program, the Contractor shall establish, provide, and
More informationHow To Use P6 For A Project Scheduling System
Managing Assets Through Enterprise - Wide Scheduling Scott Lowe, P.E. Principal, Trauner Consulting Services, Inc. Scott Lowe, Principal, Trauner Consulting Services CPM Scheduler Claims Analyst Expert
More informationAttachment 5 Electrical Engineering
A. Phase 1, Preliminary Design: The CONSULTANT shall: Attachment 5 Electrical Engineering 1. Ascertain the requirements for each project through a meeting with the Capital Projects Division Manager or
More informationSUPPLIER PREQUALIFICATION QUESTIONNAIRE FORM
SUPPLIER PREQUALIFICATION QUESTIONNAIRE FORM BRIEF This Supplier Pre Qualification Questionnaire is provided for the following project types of ALARGAN PROJECTS: 1) Supply of Construction Materials 2)
More information01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION (SCHEDULING)
01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION (SCHEDULING) PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other
More informationREQUEST FOR PROPOSALS (RFP) - Construction Management Services. Germantown School District Office
REQUEST FOR PROPOSALS (RFP) - Construction Management Services From: Germantown School District Project: Germantown School District Addition & Renovations to Rockfield Elementary School N132 W18473 Rockfield
More informationNotes. Score. 1 Basic Services 1.1. A few instances; could have been more proactive
Jacobs Contract performance Tracking spreadsheet = Excellent 2 = Meets performance standards 1 = Improvement needed 0= Unsatisfactory Report for the time period: Annual report 210 Total average score 2.86
More informationTechnical Writing - Definition of the Heron Project Management System
00150.01 Internet Based Project Management Requirements (a) Scope - This Section specifies an Internet-based project management system, Heron, required for use by the Contractor and the Owner for the processing
More informationREQUEST FOR PROPOSAL FOR ARCHITECTURAL DESIGN SERVICES. The Battery Conservancy
REQUEST FOR PROPOSAL FOR ARCHITECTURAL DESIGN SERVICES The Battery Conservancy Issue Date: March 23, 2012 Responses Due: April 20, 2012 Introduction The Battery Conservancy ( TBC ) is a 501(c)(3) not-for-profit
More informationPublic Works Contract Completion
I. Policy A. The Port will formally identify when public works construction contracts are completed in order to administer payments in accordance with Washington statutes and in order to identify warranty
More informationCITY OF LEMOORE REQUEST FOR PROPOSALS FOR CREDIT CARD PROCESSING SERVICE. City of Lemoore Finance Department 119 Fox St Lemoore, CA 93245
CITY OF LEMOORE REQUEST FOR PROPOSALS FOR CREDIT CARD PROCESSING SERVICE City of Lemoore Finance Department 119 Fox St Lemoore, CA 93245 Notice is hereby given that the City of Lemoore is soliciting proposals
More informationMODEL SCHEDULING SPECIFICATION
MODEL SCHEDULING SPECIFICATION Introduction (Not part of the specification) Before implementation, we recommend that your contract and this provision be reviewed and modified to ensure compatibility with
More informationMAILGUARD, WEBGUARD AND EMAIL ARCHIVING SERVICE SCHEDULE
MAILGUARD, WEBGUARD AND EMAIL ARCHIVING SERVICE SCHEDULE 1. APPLICABILITY This Service Schedule is applicable only to the COF for the purchase of Mail Guard, Web Guard and Mail Archiving Services, to the
More informationSECTION 01310 COST LOADED CRITICAL PATH SCHEDULE
SECTION 01310 COST LOADED CRITICAL PATH SCHEDULE 1.0 General 1.1 Description The Work specified in this Section consists of developing and maintaining an accurate cost loaded critical path schedule in
More informationPublic Act No. 14-10
Public Act No. 14-10 AN ACT CONCERNING LONG-TERM CARE INSURANCE PREMIUM RATE INCREASES. Be it enacted by the Senate and House of Representatives in General Assembly convened: Section 1. Subsections (a)
More informationREQUEST FOR EXPRESSIONS OF INTEREST 4887 EOI NETWORK BACKUP/EMAIL ARCHIVING
4887 EOI REQUEST FOR EXPRESSIONS OF INTEREST 4887 EOI NETWORK BACKUP/EMAIL ARCHIVING Expressions of Interest will be received at the Information Counter, Main Floor, Richmond City Hall, addressed to the
More informationCONTRACT FOR PROJECT MANAGEMENT SERVICES (Green Repair Program)
CONTRACT FOR PROJECT MANAGEMENT SERVICES () This Contract is made this day of in the year between (day) (month) (year) the, (Owner), Massachusetts (City) (State), (Zip Code) hereinafter called "the Owner"
More informationCITY OF LANCASTER RFP NO. 621-15 LANCASTER PERFORMING ARTS CENTER TICKETING SOFTWARE SUBMISSION DEADLINE. July 24, 2015 BY 11:00 A.M.
CITY OF LANCASTER RFP NO. 621-15 LANCASTER PERFORMING ARTS CENTER TICKETING SOFTWARE SUBMISSION DEADLINE July 24, 2015 BY 11:00 A.M. SUBMIT TO: Office of the City Clerk Lancaster City Hall 44933 Fern Avenue
More informationCITY OF DALLAS. Request for Competitive Sealed Proposal (RFCSP) BUZ1524. For. SCADA Repair, Parts and Support
CITY OF DALLAS Request for Competitive Sealed Proposal (RFCSP) BUZ1524 For SCADA Repair, Parts and Support Purpose The purpose of this specification is to establish a thirty-six (36) month service agreement
More informationElectronic Statement Disclosure
Electronic Statement Disclosure Electronic Delivery of Statements and Notices By accepting the Cornerstone Bank Electronic Statement Disclosure, you consent and agree that Cornerstone Bank may provide
More informationAdditional Terms And Conditions E-2D Advanced Hawkeye (AHE) Pilot Production (Prime Contract No. N00019-03-C-0057)
Additional Terms And Conditions E-2D Advanced Hawkeye (AHE) Pilot Production (Prime Contract No. N00019-03-C-0057) All of the additional terms and conditions set forth below are incorporated in and made
More informationCONSTRUCTION MANAGER-AT-RISK AGREEMENT. between. Houston Independent School District. and. [insert legal name of firm] for
DRAFT CONSTRUCTION MANAGER-AT-RISK AGREEMENT between Houston Independent School District and [insert legal name of firm] for [insert name of school or project] CONSTRUCTION MANAGER-AT-RISK AGREEMENT TABLE
More informationCHAPTER 267. BE IT ENACTED by the Senate and General Assembly of the State of New Jersey:
CHAPTER 267 AN ACT concerning third party administrators of health benefits plans and third party billing services and supplementing Title 17B of the New Jersey Statutes. BE IT ENACTED by the Senate and
More informationDocument B101 TM. Standard Form of Agreement Between Owner and Architect
Document B101 TM 2007 Standard Form of Agreement Between Owner and Architect AGREEMENT made as of the th day of in the year 2014 (In words, indicate day, month and year.) BETWEEN the Architect s client
More informationREQUEST FOR QUALIFICATIONS/PROPOSALS (RFQ/P) FOR COMMERCIAL PROPERTY MANGEMENT SERVICES FOR 3737 MAIN STREET GROUND FLOOR COMMERCIAL
REQUEST FOR QUALIFICATIONS/PROPOSALS (RFQ/P) FOR COMMERCIAL PROPERTY MANGEMENT SERVICES FOR 3737 MAIN STREET GROUND FLOOR COMMERCIAL ISSUED: JUNE 21, 2016 PROPOSALS DUE: AUGUST 22, 2016 CITY OF RIVERSIDE
More informationREQUEST FOR QUALIFICATIONS RFP # 1027 CITY OF RIVERSIDE MOBILE APPLICATION. Proposal Due: Before 4:00 PM June 18, 2011. Issued by:
REQUEST FOR QUALIFICATIONS RFP # 1027 CITY OF RIVERSIDE MOBILE APPLICATION Proposal Due: Before 4:00 PM June 18, 2011 Issued by: CITY OF RIVERSIDE DEVELOPMENT DEPARTMENT 3900 Main Street, 5 th Floor Riverside,
More informationSenior Business Intelligence Project Manager
Senior Business Intelligence Project Manager R E Q U E S T F O R Q U O T A T I O N State Term Schedule Page 1 of 14 Table of Contents INTRODUCTION AND BACKGROUND...3 PURPOSE OF THE REQUEST FOR QUOTATION...3
More informationSolicitation Information February 26, 2016
Solicitation Information February 26, 2016 RFP#7550347 TITLE: SEARCH FOR AFFORDABLE CARE ACT TAX REPORTING SOLUTION Submission Deadline: Monday, March 21, 2016 @ 11:30 AM (Eastern Time) Questions concerning
More informationREQUEST FOR PROPOSAL FOR: IT CONSULTANT
SYS13-05 REQUEST FOR PROPOSAL FOR: IT CONSULTANT COMMUNITY COLLEGE SYSTEM OF NH PURPOSE: The purpose of this REQUEST FOR PROPOSAL is to establish a contract for the Community College System of NH System
More informationRFP Milestones, Instructions, and Information
This Request for Proposal is being issued by the Lower Colorado River Authority (LCRA). LCRA is a conservation and reclamation district of the State of Texas created pursuant to Article XVI, Section 59,
More informationDEPARTMENT OF WORKFORCE SERVICES LABOR STANDARDS DIVISION CHAPTER 4
DEPARTMENT OF WORKFORCE SERVICES LABOR STANDARDS DIVISION CHAPTER 4 CERTIFICATION OF RESIDENT CONTRACTORS, SUPPLIERS AND ENFORCEMENT OF PREFERENCE LAWS Section 1. Authority. The Department of Workforce
More informationREQUEST FOR INFORMATION (RFI) DRCI-16-2209 PREVENTATIVE MAINTENANCE OPTIMIZATION SYSTEM
Date February 1, 2016 Page 1 REQUEST FOR INFORMATION (RFI) PREVENTATIVE MAINTENANCE OPTIMIZATION SYSTEM RESPONSE DEADLINE: RFI responses are due by to Noon, Local Time on Tuesday, February 16, 2016 ADDRESS
More informationOAKLAND USD RFP /09) ATTOR RNEY ENSATION WORKERS' COMP
OAKLAND UNIFIED SCHOOL DISTRICTT REQUEST FOR PROPOSALSS ( NO. 15-16/ /09) ATTOR RNEY SERVICES WORKERS' COMP ENSATION DEFENSEE 1 OAKLAND USD RFP (NO. 15 16/ /09) ATTORNEY SERVICES, WORKERS COMPENSATION
More informationREQUEST FOR PROPOSAL TO PROVIDE CONSTRUCTION MANAGEMENT AND GENERAL CONTRACTOR SERVICES SPRINGVILLE CITY NEW AQUATICS AND ACTIVITIES CENTER
RFP #2016-02 REQUEST FOR PROPOSAL TO PROVIDE CONSTRUCTION MANAGEMENT AND GENERAL CONTRACTOR SERVICES FOR SPRINGVILLE CITY NEW AQUATICS AND ACTIVITIES CENTER RELEASE DATE: January 29, 2016 DUE DATE: February
More informationSECTION 01311 - CONSTRUCTION SCHEDULE B. Part 1 - General... 1. 1.01 Work Included... 1. 1.02 Related Requirements... 1. 1.03 Reference Standards...
SECTION 01311 - CONSTRUCTION SCHEDULE B CONTENTS: Part 1 - General... 1 1.01 Work Included... 1 1.02 Related Requirements... 1 1.03 Reference Standards... 1 1.04 Quality Assurance... 1 1.05 Measurement
More informationPERFORMANCE BOND LABOR AND MATERIAL PAYMENT BOND
Section 00 61 13.13 & 00 61 13.16 Douglas County School District Re.1 Castle Rock, Colorado PERFORMANCE BOND LABOR AND MATERIAL PAYMENT BOND 1. FORMS TO BE USED Two (2) separate bonds are required: Both
More informationATTACHMENT A. Ozarks Technical Community College Pre-Established Criteria for Construction Management and Design Build Construction Projects
Ozarks Technical Community College Pre-Established Criteria for Construction Management and Design Build Construction Projects Pursuant to Revised Statute of Missouri Section 8.250(3), Ozarks Technical
More informationAGREEMENT FOR CONSTRUCTION MANAGEMENT SERVICES BETWEEN THE REGENTS OF THE UNIVERSITY OF MICHIGAN AND
AGREEMENT FOR CONSTRUCTION MANAGEMENT SERVICES BETWEEN THE REGENTS OF THE UNIVERSITY OF MICHIGAN AND FORM DATE: January 31, 2014 TABLE OF CONTENTS PART 1. INDUCEMENT; BASIC AGREEMENT... 1 1.1. Inducement....
More informationPrepared by Office of Procurement and Real Property Management. This replaces Administrative Procedure No. A8.255 dated July 2012
Prepared by Office of Procurement and Real Property Management. This replaces Administrative Procedure No. A8.255 dated July 2012 A8.255 A8.255 Sole Source Procurement 1. Conditions for Use A8.200 Procurement
More informationWinona State University MINNESOTA STATE COLLEGES AND UNIVERSITIES WINONA STATE UNIVERSITY LAIRD NORTON PROJECT
Winona State University MINNESOTA STATE COLLEGES AND UNIVERSITIES WINONA STATE UNIVERSITY LAIRD NORTON PROJECT REQUEST FOR PROPOSALS (RFP) for CONSTRUCTION MANAGER at RISK (CM@r) SERVICES August 10, 2015
More informationREQUEST FOR QUALIFICATIONS
LITTLE ROCK ADVERTISING & PROMOTION COMMISSION Physical Address: 426 West Markham Street Little Rock, Arkansas 72201 Mailing Address: P.O. Box 3232 Little Rock, Arkansas 72203 REQUEST FOR QUALIFICATIONS
More informationGENERAL TERMS AND CONDITIONS FOR THE SUPPLY OF GRAPHIC PRODUCTS 2010 (ALG 10)
Translation GENERAL TERMS AND CONDITIONS FOR THE SUPPLY OF GRAPHIC PRODUCTS 2010 (ALG 10) Standard terms and conditions prepared by the Swedish Graphic Companies Federation (Grafiska Företagens Förbund),
More informationBusiness Intelligence Data Analyst
Business Intelligence Data Analyst REQUEST FOR QUOTATION Minority Business Enterprise (MBE) ONLY State Term Schedule Page 1 of 12 Table of Contents INTRODUCTION AND BACKGROUND...3 PURPOSE OF THE REQUEST
More informationRequest For Proposal. Furnish Schneider Business Park Signs Design Build Services. For the Cibolo Economic Development Corporation Cibolo, Texas
Request For Proposal Furnish Schneider Business Park Signs Design Build Services For the Cibolo Economic Development Corporation Cibolo, Texas The City of Cibolo, Texas Economic Development Corporation
More informationQuality Counts! Qualifications Based Selection (QBS)
Fall 2012 Kane County Division of Transportation Quality Counts! Qualifications Based Selection (QBS) Professional Services Procurement Process Kane County Division of Transportation 41W011 Burlington
More informationD3 Bus Wash Rehabilitation AC Transit Contract #2016-1372 SECTION 002113 INSTRUCTIONS TO BIDDERS
PART 1 GENERAL 1.01 GENERAL SECTION 002113 INSTRUCTIONS TO BIDDERS A. Information contained in this section is supplemental to or in explanation of information in the INVITATION TO BID contained in Section
More informationCOMMUNITY LIBRARY (SUNBURY) RFP for Construction Manager at Risk
Project Name: Addition to Community Library (Sunbury) Project Location: 44 Burrer Drive, Sunbury, Ohio 43074 Owner: Community Library Board of Trustees Address: 44 Burrer Drive, Sunbury, Ohio 43074 Project
More informationCONSULTING SERVICES AGREEMENT THE CORPORATION OF THE CITY OF GUELPH, an Ontario municipality. ( City ) and. an Ontario. ( Consultant").
Page 1 of 13 CONSULTING SERVICES AGREEMENT This consulting services agreement is between: THE CORPORATION OF THE CITY OF GUELPH, an Ontario municipality ( City ) and, an Ontario ( Consultant"). The parties
More informationSTATE UNIVERSITY CONSTRUCTION FUND GUIDELINES FOR AWARD OF PROCUREMENT CONTRACTS
STATE UNIVERSITY CONSTRUCTION FUND GUIDELINES FOR AWARD OF PROCUREMENT CONTRACTS Section I. Purpose The purpose of these Guidelines is to describe the methods and procedures governing the use, awarding,
More informationSAMPLE REQUEST FOR PROPOSALS TEMPLATE
SAMPLE REQUEST FOR PROPOSALS TEMPLATE Request for Proposals (RFP) For: [Title of RFP Project] Note: This sample is for a fabrication type of RFP. [RFP ID #] Issued: [Date] Submission deadline: [Time/Date]
More informationHunt Construction Group, Inc. LEVEL 1 DESIGN BUILD SPECIALTY CONTRACTOR PREQUALIFICATION DOCUMENTS FOR:
Hunt Construction Group, Inc. LEVEL 1 DESIGN BUILD SPECIALTY CONTRACTOR PREQUALIFICATION DOCUMENTS FOR: San Diego State University Basketball Practice Facility Project Number: 03400200 October 2013 San
More informationSECTION G CONTRACT ADMINISTRATION DATA. The person named below is designated as the Contracting Officer's Representative (COR):
SECTION G CONTRACT ADMINISTRATION DATA 1. CONTRACTING OFFICER'S REPRESENTATIVE The person named below is designated as the Contracting Officer's Representative (COR): Tom Patterson Cartographer The Contracting
More informationCHAPTER 7 PUBLIC PURCHASES, PURCHASE OF LAND OR STRUCTURES AND INVENTORY OF FIXED ASSETS
7-1 CHAPTER 7 PUBLIC PURCHASES, PURCHASE OF LAND OR STRUCTURES AND INVENTORY OF FIXED ASSETS The "Public Purchasing Law" applies to every expenditure of public funds by a governmental body, unless specifically
More informationMASTER AGREEMENT FOR PROJECT THE DEKALB COUNTY BOARD OF EDUCATION. Dated:
MASTER AGREEMENT FOR PROJECT MANAGEMENT SERVICES BETWEEN THE DEKALB COUNTY BOARD OF EDUCATION AND Dated: T A B L E O F C O N T E N T S ARTICLE 1 DEFINITIONS... 1 ARTICLE 2 REPRESENTATIONS... 4 2.1 Specific
More informationCity of Powell Request for Proposals for a Total Compensation Survey
City of Powell Request for Proposals for a Total Compensation Survey Section I The City of Powell is soliciting proposals from qualified consulting firms, experienced in the development of a job evaluation
More informationGREENBURGH CENTRAL SCHOOL DISTRICT No. 7 REQUEST FOR PROPOSALS CONSTRUCTION MANAGEMENT SERVICES
GREENBURGH CENTRAL SCHOOL DISTRICT No. 7 REQUEST FOR PROPOSALS CONSTRUCTION MANAGEMENT SERVICES Greenburgh Central School District No. 7 ( The District ) invites proposals to perform construction management
More informationAppendix A. Call-off Terms and Conditions for the Provision of Services
Appendix A Call-off Terms and Conditions for the Provision of Services Where an Order Form is issued by the Authority that refers to the Framework Agreement, the Contract is made between the Authority
More informationSECTION G CONTRACT ADMINISTRATION DATA. Betsy Ehrlich, Visual Information Specialist, (304) 535-6200
SECTION G CONTRACT ADMINISTRATION DATA 1. CONTRACTING OFFICER'S REPRESENTATIVE The person named below is designated as the Contracting Officer's Representative (COR): Betsy Ehrlich, Visual Information
More informationNOTICE REQUEST FOR PROPOSALS FOR INTERIM TOWN ACCOUNTANT SERVICES TOWN OF SCITUATE, MA
NOTICE REQUEST FOR PROPOSALS FOR INTERIM TOWN ACCOUNTANT SERVICES TOWN OF SCITUATE, MA The Town of Scituate, acting through its Chief Procurement Officer, seeks sealed proposals from qualified firms or
More informationPricing of Construction Contract Change Order Documentation
The contract language contained in this Exhibit will supplement and take precedence over all other change order pricing contract provisions in the Contract Documents provided by the Owner, Design-Builder
More informationREQUEST FOR PROPOSALS
REQUEST FOR PROPOSALS The Town of Ayer s Department of Planning & Development seeks proposals from qualified consultants to provide the following services in the Town of Ayer: INFRASTRUCTURE PROJECT CONSULTANT
More informationTOWN OF STRATFORD PURCHASING DEPARTMENT STRATFORD, CONNECTICUT REQUEST FOR PROPOSAL. Subject: Payroll Processing Services for Stratford Library
TOWN OF STRATFORD PURCHASING DEPARTMENT STRATFORD, CONNECTICUT REQUEST FOR PROPOSAL RFP No. 2014-027 Issued: March 24, 2014 Subject: Payroll Processing Services for Stratford Library The Town of Stratford
More informationTo: From: Patricia Baskerville, PCS Email: Email: patricia.baskerville@jfs.ohio.gov Phone: (000) Date: June 12, 2015 Pages: 10
Armond Budish Cuyahoga County Executive Cuyahoga County Division of Senior and Adult Services To: From: Patricia Baskerville, PCS Email: Email: patricia.baskerville@jfs.ohio.gov Phone: (000) Date: June
More informationSUBSTITUTION PROCEDURES 01 62 04-1
Section 01 62 04 Substitution Procedures PART 1 - GENERAL 1.1 SUMMARY A. Section Includes: 1.2 SUBSTITUTIONS 1. Administrative and procedural requirements for substitutions. A. Base Bid shall be in accordance
More informationConsultants Services, Lump-Sum Remuneration
1 S T A N D A R D F O R M O F C O N T R A C T FOR Consultants Services, Lump-Sum Remuneration CONTRACT FOR CONSULTANTS SERVICES Lump-Sum Remuneration Between [name of the Procuring Entity] and 2 [name
More informationMutual Savings Credit Union Internet Banking/ Electronic Statement (e-statement) Disclosure Agreement
Mutual Savings Credit Union Internet Banking/ Electronic Statement (e-statement) Disclosure Agreement Internet Banking Mutual Savings Credit Union Internet Banking Agreement and Disclosure Agreement is
More informationREQUEST FOR QUALIFICATIONS/PROPOSAL (RFQ/P) FOR A ROOF CONSULTANT
REQUEST FOR QUALIFICATIONS/PROPOSAL (RFQ/P) FOR A ROOF CONSULTANT Durango School District 9 R (Owner) 201 East 12 th Street Durango, Colorado 81301 Phone (970) 247 5411, ext. 1458 PROPOSAL DUE DATE/DELIVERY
More informationSTANDARD CONTRACT EXECUTION FORMS
THE BIDDING AND CONTRACT PROVISIONS Document Section 00 50 00 - Standard Contract Execution Forms (Standard Contract Set) STANDARD CONTRACT EXECUTION FORMS 1. EXECUTION OF THE AGREEMENT 1.1 Extraneous
More informationTABLE OF CONTENTS Surety Bond Guarantee Program for Small Contractors
Department of Economic Development Sec. 32-55 page 1 (9-97) TABLE OF CONTENTS Surety Bond Guarantee Program for Small Contractors Definitions.... 32-55-1 Eligibility... 32-55-2 Guarantee agreement... 32-55-3
More informationCITY OF RIVERSIDE, MISSOURI REQUEST FOR PROPOSALS PAYROLL SOLUTIONS AND SERVICES
CITY OF RIVERSIDE, MISSOURI REQUEST FOR PROPOSALS PAYROLL SOLUTIONS AND SERVICES 1 The City of Riverside is requesting Request for Proposals from interested persons and/or firms for the provision of Payroll
More informationOBJECTIVE To establish procedures for administration of construction manager agreements, including negotiation, contracting and payments.
OP-B-11-D2 ADMINISTRATION OF CONSTRUCTION MANAGER AGREEMENTS SPECIFIC AUTHORITY Sections 240.209(3)(p), 1001.74, 1013.46, F. S. OBJECTIVE To establish procedures for administration of construction manager
More informationNegotiated Relationship Agreement between the International Criminal Court and the United Nations. Preamble
Negotiated Relationship Agreement between the International Criminal Court and the United Nations Preamble The International Criminal Court and the United Nations, Bearing in mind the Purposes and Principles
More informationAtrium Skylight Repair Carleton Lodge
Requirement Period of Contract The successful bidder shall complete the work no later than 27 November 2015. Closing Date Quotations must be submitted no later than close of business day (11:59 pm) on
More informationINTER-PARLIAMENTARY UNION
INTER-PARLIAMENTARY UNION 5, CHEMIN DU POMMIER CASE POSTALE 330 1218 LE GRAND-SACONNEX / GENÈVE (SUISSE) TELEPHONE (41.22) 919 41 50 - FAX (41.22) 919 41 60 - E-MAIL postbox@mail.ipu.org TELEGRAPHIC ADDRESS
More informationREQUEST FOR PROPOSALS Occupational Therapy Services 2014-2015 July 29, 2014
REQUEST FOR PROPOSALS Occupational Therapy Services 2014-2015 July 29, 2014 RFP 140702 The Delaware City School District is seeking a vendor to provide occupational therapy to students with IEP s for the
More informationCanterbury Park Pool Chamber Replacement
Requirement Request For Quotation To provide services, equipment and materials to replace the Concrete Pool Service & Drainage vault at the Canterbury Park Pool located at 2185 Arch Street, Ottawa, ON
More informationAGREEMENT FOR PROVISION OF FOSTER CARE SERVICES
AGREEMENT FOR PROVISION OF FOSTER CARE SERVICES THIS AGREEMENT is made between the County of Washoe hereinafter referred to as County and, hereinafter referred to as Provider. 1. RECITALS WITNESSETH WHEREAS
More informationPN 126-4/15/05 - REVISIONS TO THE C&MS FOR DESIGN BUILD PROJECTS
PN 126-4/15/05 - REVISIONS TO THE C&MS FOR DESIGN BUILD PROJECTS 101.01 On page 7, Add the following: NOTE: The fact that the bid items for this Design-Build project are general rather than specific shall
More informationSeattle Public Schools The Office of Internal Audit
seaonly Seattle Public Schools The Office of Internal Audit Capital Internal Audit Report Issue Date: June 16, 2015 Introduction and Background Executive Summary This report contains the results of our
More informationAudit Guide for Consulting Services Cost Rates. March 11, 2015
Audit Guide for Consulting Services Cost Rates March 11, 2015 Columbus Regional Airport Authority Audit Guide for Consulting Services Cost Rates TABLE OF CONTENTS: History... 3 Page Purpose and Objectives...
More informationSolicitation 1210-014. Web Hosting Services for the Disaster Volunteer Network. State of California
Solicitation 1210-014 Web Hosting Services for the Disaster Volunteer Network State of California Oct 12, 2012 4:28:36 PM PDT p. 1 Bid 1210-014 Web Hosting Services for the Disaster Volunteer Network Bid
More information