Managing programme change on an NEC3 form of contract
|
|
- Evangeline Parsons
- 8 years ago
- Views:
Transcription
1 Managing programme change on an NEC3 form of contract
2 Presentation: Summary of Key NEC3 Programme Principles Timing of compensation events relative to the last Accepted Programme Assessing effects of a compensation event
3 Clause 31 The programme Items to be shown on the programme include: starting date/completion Date/Key Dates planned Completion order and timing of operations to Provide the Works float time risk allowances health and safety requirements Plant & Materials from Employer acceptances information from Others statements of how the Contractor plans to do the work
4 Reasons for not accepting a programme Under clause 31.3 there are only four reasons not to accept a programme: The Contractor s plans which it shows are not practicable It does not show the information which this contract requires It does not represent the Contractor s plans realistically or It does not comply with the Works Information Project Manager has to accept or not accept the programme within two weeks. If the Project Manager withholds acceptance for a reason not stated in contract it is a compensation event. If the Project Manager does not respond within the period for Acceptance it is NOT deemed accepted.
5 Clause 32 - Revising the programme Contractor shows on each revised programme: actual progress achieved on each operation activity and affect upon remaining work effects of implemented compensation events how Contractor plans to deal with any delays and to correct notified Defects any other changes that Contractor proposes to make 32.2 Contractor submits a revised programme: Within the period for reply after Project Manager has instructed When the Contractor chooses to At no longer interval than stated in the contract
6 If programme not accepted: Neither party clear on the Completion Date and contractor entitlement in terms of outturn cost 25% of the cumulative Price for Work Done to Date deducted until first programme submitted showing the information the contract requires Employer will in the absence of a newly accepted programme assess change (CE s) on the last accepted programme Important to both parties programme regularly accepted. Otherwise enjoy the traditional end of project bun-fight to sort out the final account
7 Clause 64 Project Manager s Assessment The Project Manager may make his own assessment of a compensation event for the reasons stated in Clause 64.1: if the Contractor has not submitted a quotation within the timescale, the Contractor has not assessed the compensation event correctly and does not instruct the Contractor to submit a revised quotation, he has not submitted a programme or alterations to a programme which this contract requires him to submit or If, the Project Manager has not accepted the Contractor s latest programme for one of the reasons stated in this contract.
8 Quote from a senior lawyer: Programme under the NEC3 is the beating heart of the contract
9 Example of Timing of Events
10 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F float planned Completion Completion Date
11 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F planned Completion Completion Date Acceleration CE s
12 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F planned Completion Completion Date ANYTHING!!
13 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F CE planned Completion Completion Date
14 WEEK NUMBERS Start Activity A Accepted programme Activity B Activity C Activity D CE Activity E Activity F 1w float planned Completion Completion Date
15 WEEK NUMBERS Start Activity A 1w delay Activity B Activity C Activity D CE (Delay Damages) Activity E Activity F 2w planned Completion Completion Date
16 WEEK NUMBERS Start Activity A Accepted programme Activity B Activity C Activity D Activity E Activity F 1w float planned Completion Completion Date
17 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F planned Completion Completion Date CE
18 Start WEEK NUMBERS Activity A Activity B Activity C Activity D Activity E Activity F planned Completion Completion Date CE
19 Start Activity A Activity B Activity C Activity D Activity E Activity F WEEK NUMBERS planned Completion Completion Date CE 1w float No delay damages Forecast cost 1 week delay in CE
20 Common Questions: what programme do you use to assess a compensation event what progress/change (if any) should you first take into account?
21 Clause 62.2 states that if the programme for remaining work is altered by the compensation event, the Contractor includes the alterations to the Accepted Programme in his quotation. Clause 63.3 also states that a delay to the Completion Date is assessed as the length of time that, due to the compensation event, planned Completion is later than planned Completion as shown on the Accepted Programme.
22 What then happens if that Accepted Programme is several months old and contains logic that is now clearly known to be wrong and varying degrees of progress compared to that originally planned?
23 Systematic input of a CE into a programme Sequence progress programme with works to date reschedule programme and check if any effect to Key Dates or planned Completion. If yes reschedule to mitigate effect rebaseline (interim) programme input CE and reschedule programme to assess effect save and print a filtered programme demonstrating the effect the CE has had if there is a second CE to input at the same time then rebaseline once more and repeat the process to assess any FURTHER effect that the second CE has had
24 Systematic input of a CE into a programme WEEK NUMBERS EXCAVATE CE001 WORKS INSTALL PIPE INSTALL ACCESS ROAD BACKFILL REFURB BUILDING PLANNED COMPLETION Last agreed programme was week 6 now week 8 CE002 involves 2 weeks additional works to Refurb Building 1. Progress programme 2. Rebaseline 3. Input CE, add logic links and rebaseline
25 Systematic input of a CE into a programme WEEK NUMBERS EXCAVATE CE001 WORKS INSTALL PIPE INSTALL ACCESS ROAD BACKFILL REFURB BUILDING PLANNED COMPLETION 1. Progress programme
26 Systematic input of a CE into a programme WEEK NUMBERS EXCAVATE CE001 WORKS INSTALL PIPE INSTALL ACCESS ROAD BACKFILL REFURB BUILDING PLANNED COMPLETION 1. Progress programme 2. Rebaseline (Interim)
27 Systematic input of a CE into a programme WEEK NUMBERS EXCAVATE CE001 WORKS INSTALL PIPE INSTALL ACCESS ROAD BACKFILL REFURB BUILDING CE002 ADDITIONAL WORKS PLANNED COMPLETION 1. Progress programme 2. Rebaseline (interim) 3. Input CE002, add logic links and rebaseline
28 Systematic input of a CE into a programme WEEK NUMBERS EXCAVATE CE001 WORKS INSTALL PIPE INSTALL ACCESS ROAD BACKFILL 1 week float REFURB BUILDING CE002 ADDITIONAL WORKS PLANNED COMPLETION 1. Progress programme 2. Rebaseline (interim) 3. Input CE, add logic links 4. Once agreed Rebaseline (permanent) and note any change to Critical Path
29 Relative Movement of Completion Date/ planned Completion with Compensation Events
30 Movement of Completion Date Month 1 Start Activity A Activity B Accepted Programme 4m 4m planned Completion Completion Date
31 Movement of Completion Date month 2 Start Activity A Activity B Accepted Programme 4m 4m CE 01 planned Completion Completion Date 2m 2m
32 Movement of Completion Date month 3 Start Activity A Activity B Accepted Programme 4m 4m CE 01 CE 02 planned Completion Completion Date 2m 4m 2m
33 Movement of Completion Date month 4 Start Activity A Activity B Accepted Programme 4m 4m CE 01 CE 02 CE 03 planned Completion Completion Date 2m 2m 6m 2m
34 Importance of Detail in the Programme WEEK NUMBERS Activity A Activity B Activity C Activity D planned Completion Completion Date Activity B is electrical works in six separate rooms each needing two electricians for one week each. At the start of week 4 you are informed that there is no access to two of the rooms and they will not be available for five weeks. What will the effect of this CE be?
35 Delay to Completion Date Example WEEK NUMBERS Activity A Activity B1 Activity B2 Activity B3 Activity B4 Activity B5 Activity B6 Activity C Activity D What if: planned Completion Completion Date CE CE a) B3 has to follow B2, or b) B1-B6 can be in any order What is the effect now?
36 Contractor: Make sure your programme fully complies with clause 31.2 (and 32.1) Show difference between planned Completion/ Completion Date Comprehensive programme narrative with each submission Programme review meeting during acceptance period with PM If no response to programme call a meeting and try to bring it to a head
37 Employer: Review programme well within two week response period and give early comment Aim for a one week response for programme acceptance where ever possible Give clear specific detailed reasons why it is not accepted - only four reasons under the contract Accept with comments comments being minor issues that can be put right on the next programme issue
38
39 Conclusions/Summary Programme is the beating heart of the contract Both parties need to work together to ensure that a programme is regularly updated and accepted through out the life of the contract Keep on top of change add compensation events to the programme at the earliest opportunity to agree effect of change as you go however hard at a point in time it appears to be (as it will only ever get worse). Any questions/thoughts?
Producing a programme under the NEC form of contract
Proceedings of the Institution of Civil Engineers Management, Procurement and Law 163 May 2010 Issue MP2 Pages 59 64 doi: 10.1680/mpal.2010.163.2.59 Paper 900033 Received 02/05/09 Accepted 19/08/09 Keywords:
More informationAppendix 18 NEC3 Options
Appendix 18 NEC3 Options December 2007 Page 449 Appendix 18 NEC3 Options NEC3 Main Options There are six main options as set out below. The Contractor carries the greatest risk under options A and B, and
More informationGuidance Notes for the NEC Engineering and Construction Contract
The first objective of the Risk Register is to identify the risks inherent in a project. Some of these risks are generic, and will apply to whatever work is carried out. An example is the risk of errors
More informationSECTION 01311 - CONSTRUCTION SCHEDULE B. Part 1 - General... 1. 1.01 Work Included... 1. 1.02 Related Requirements... 1. 1.03 Reference Standards...
SECTION 01311 - CONSTRUCTION SCHEDULE B CONTENTS: Part 1 - General... 1 1.01 Work Included... 1 1.02 Related Requirements... 1 1.03 Reference Standards... 1 1.04 Quality Assurance... 1 1.05 Measurement
More informationNEC3: The Engineering and Construction Contract An overview
NEC3: The Engineering and Construction Contract An overview Michael Dunn FRICS FCIArb LLB LLM T: 02079 976 520 and 01274 693 622 E: m.dunn@rpp.co.uk www.rpp.co.uk Delivering Professional Solutions to the
More informationSpec. Standard: 11/27/06 01310-1 Revision: 11/27/06
SECTION 01310 CONSTRUCTION SCHEDULES PART 1 - GENERAL 1.01 SCOPE: A. Construction Progress Schedule: The CONTRACTOR shall submit a detailed work progress schedule showing all work in a graphic format suitable
More informationNEC3 Engineering & Construction Contract An Overview
NEC3 Engineering & Construction Contract An Overview Delivering Professional Solutions to the Property Industry Michael Dunn FRICS FCIArb LLB LLM Director of Contract Services T: 01274 693 622 E: m.dunn@rpp.co.uk
More informationMISSISSIPPI STATE UNIVERSITY Office of Planning Design and Construction Administration
SECTION 01 311 NETWORK ANALYSIS SCHEDULE Part 1.1 DESCRIPTION A. Scope: Provide projected network analysis schedules for the entire Work and revise periodically. This type of schedule is acceptable for
More informationThe following amendments have been made to the June 2005 edition. 10 32.1 4 deleted: and of notified early warning matters
AMENDMENTS JUNE 2006 The following amendments have been made to the June 2005 edition. Page Clause Line 10 32.1 4 deleted: and of notified early warning matters 43 Contract Data Part one, 1. 3 added: (with
More informationActivity Schedules in the NEC3 Engineering and Construction Contract
Activity Schedules in the NEC3 Engineering and Construction Contract Prepared by Dr Ron Watermeyer Briefing Note NEC3#2 March 2013 Overview This briefing note outlines the NEC3 provisions for a Activity
More informationANNEX 8 Contract Management Strategy
ANNEX 8 Contract Management Strategy Bath & North East Somerset, Bristol, North Somerset and South Gloucestershire Councils working together to improve your local transport Contract Management Strategy
More informationIN FIDIC 99 RED BOOK COULD IT BE SUPERVISION CONSTRUCTION. Dr. Munther M. Saket. The Role of the Engineer
THE ROLE OF THE ENGINEER IN FIDIC 99 RED BOOK COULD IT BE PERFORMED BY A SUPERVISION CONSULTANT & A CONSTRUCTION MANAGER? Dr. Munther M. Saket December 2010 The Role of the Engineer 1 The ENGINEER S ROLE
More informationBasic Construction Management for Local Governments
Basic Construction Management for Local Governments 1 AGENDA Project Documentation Requirements Contract Work Orders Claims Discussion 2 CREDITS National Highway Institute (NHI) Managing Highway Contract
More informationAsset Protection Agreement Templates - Customer Explanatory Notes. Explanatory Notes on Asset Protection Agreement
Asset Protection Agreement Templates - Customer Explanatory Notes Explanatory Notes on Asset Protection Agreement Clause Heading Background The Asset Protection Agreement is intended for use where the
More informationCLIENT / PROJECT MANAGER AGREEMENT
Authorship of this work is claimed by The Association of Construction Project Managers and any unauthorised reproduction constitutes an infringement in terms of the Copyright Act No 98 of 1978. CLIENT
More informationUnderstanding variations a contractor's perspective Jonathan Brooks, Tim Tapper, Andrew Ash & Stuart McGee. 21 March 2011 & 23 March 2011
Understanding variations a contractor's perspective Jonathan Brooks, Tim Tapper, Andrew Ash & Stuart McGee 21 March 2011 & 23 March 2011 Introduction Jonathan Brooks osborneclarke.com osborneclarke.com
More informationSECTION 01310 COST LOADED CRITICAL PATH SCHEDULE
SECTION 01310 COST LOADED CRITICAL PATH SCHEDULE 1.0 General 1.1 Description The Work specified in this Section consists of developing and maintaining an accurate cost loaded critical path schedule in
More informationMODEL SCHEDULING SPECIFICATION
MODEL SCHEDULING SPECIFICATION Introduction (Not part of the specification) Before implementation, we recommend that your contract and this provision be reviewed and modified to ensure compatibility with
More informationSCHEDULE 25. Business Continuity
SCHEDULE 25 Business Continuity 1. Scope 1.1 This schedule covers TfL s requirements in respect of: any circumstance or event which renders, or is likely (in TfL s absolute discretion (subject to paragraph
More informationPlanning and Scheduling Consideration and Constraints in Automated Construction Environment. Chotchai Charoenngam, Ph.D. ABSTRACT
Planning and Scheduling Consideration and Constraints in Automated Construction Environment Chotchai Charoenngam, Ph.D. Assisatant Professor, School of Civil Engineering, Asian Institute of Technology,
More informationBasic Guide. General Conditions of Contract for Construction Works (GCC 2004)
Basic Guide General Conditions of Contract for Construction Works (GCC 2004) February 2008 Preface The Construction Industry Development Board (CIDB) is a national body established by an Act of Parliament
More informationREQUEST FOR QUOTATION/ PURCHASE ORDER
REQUEST FOR QUOTATION/ PURCHASE ORDER Conditions of Contract- Services These Conditions may be varied only by the written agreement of the Council. No terms or conditions put forward at any time by the
More informationExplaining an architect s services. General information on the usual tasks undertaken by an architect
Explaining an architect s services General information on the usual tasks undertaken by an architect June 2008 What an architect may do for you Introduction The root cause of disputes and complaints against
More informationSCHEDULE 5.2 WHOLESALE ACCESS PRICING
SCHEDULE 5.2 WHOLESALE ACCESS PRICING Page 1 of 2 Table of contents Clause heading and number Page number 1. BACKGROUND... 1 2. PROJECT WHOLESALE ACCESS PRICES... 1 3. WHOLESALE ACCESS PRICE BENCHMARK
More informationHeritage Grants - Receiving a grant
Heritage Grants - Receiving a grant Mentoring and monitoring; Permission to Start; and December 2013 If you require a copy of this guidance in an alternative format (large print, Braille or audio version),
More informationThe New Standard Construction Contracts: NZS3910, 3916 and 3917
The New Standard Construction Contracts: NZS3910, 3916 and 3917 Brian Clayton, Partner FEBRUARY 2014 3258689.3 Chapman Tripp Introduction Standards New Zealand has recently completed the first review of
More informationMemorandum. Jeff Jasper, P.E. Director, Division of Design. Technical Support TEBM, Division of Construction. From: Jeremiah Littleton, P.E.
Memorandum To: Thru: Jeff Jasper, P.E. Director, Division of Design Rachel Mills, P.E. Technical Support TEBM, Division of Construction From: Jeremiah Littleton, P.E. Division of Construction Date: June
More informationProcedures for Buyer Cash Compensation
Date 18 March 2013 Version1.0 Contents A. Introduction... 3 B. New Sell Trade Rejection Procedures... 3 C. Implementing the Buyer Cash Process... 6 D. Failed Trade Settlement... 6 E. Determining the Buyer
More informationNorth London Plumbing & Heating Terms and Conditions
North London Plumbing & Heating Terms and Conditions Christopher Michael Darby North London Plumbing & Heating 2 Perth Road Wood Green London N22 5RB 0203 592 4340/07400 616 686 info@nlph.org 1 DEFINITIONS
More informationHow To Write New Government Construction Contracts
HUSSEY FRASER SOLICITORS 1. Objectives of new contracts 2. How objectives are to be achieved Risk Transfer Procedural / Information Burden 3. Termination Provisions 4. Collateral Warranties 5. Conclusion
More informationMATERIALS: The Contractor shall provide the latest version of Primavera SureTrak software.
DESCRIPTION: '108-01, Start and Progress of Work, is hereby amended to require that the Contractor furnish and participate in a computerized CPM (critical path method) network scheduling system. The purpose
More information4.1 The property and any copyright or other intellectual property rights in any Input Material shall belong to the Subscriber.
1 Interpretation 1.1 In these Conditions: THE SERVICE PROVIDER means Cutec Remote Backup Terms and Conditions THE SERVICE PROVIDER S STANDARD CHARGES means the charges shown in the Order Sheet or other
More informationSPECIFICATIONS - DETAILED PROVISIONS Section 01310 - Project Control Schedule C O N T E N T S
SPECIFICATIONS - DETAILED PROVISIONS Section 01310 - Project Control Schedule C O N T E N T S PART 1 - SCHEDULE REQUIREMENTS PROGRESS SCHEDULE... 1 PART 2 - SUBMITTAL PROCEDURES... 2 PART 3 - DEFINITIONS...
More informationSmart Meters Programme Schedule 9.1. (TUPE) (CSP South version)
Smart Meters Programme Schedule 9.1 (TUPE) (CSP South version) Schedule 9.1 (TUPE) (CSP South version) Amendment History Version Date Status v.1 Signature Date Execution copy SCHEDULE 9.1 TUPE 1. PURPOSE
More informationPN 107-01/16/2009 - CRITICAL PATH METHOD PROGRESS SCHEDULE
PN 107-01/16/2009 - CRITICAL PATH METHOD PROGRESS SCHEDULE A. General. The progress schedule required for this project is the critical path method schedule (CPM schedule). The Contractor shall designate
More informationBorderland Fencing Centre - Credit Account Application Form
Account Application Borderland Fencing Centre - Credit Account Application Form Trading Name: Trading Registered Office: Main Contact Name: Telephone Number: Email Website: LTD Company Registration No:
More informationManaging construction procurement risks
CONSTRUCTION PROCUREMENT BEST PRACTICE GUIDELINE #A5 Construction Industry Development Board Pretoria - Head Office Tel: 012 482 7200 Fraudline: 0800 11 24 32 Call Centre: 0860 103 353 E-mail: cidb@cidb.org.za
More informationTine 2.0 Maintenance and Support Services
Tine 2.0 Maintenance and Support Services 1 Overview of Maintenance and Support Services Metaways Tine 2.0 Maintenance and Support Editions: SERVICES Software Maintenance Business Professional SW Maintenance
More informationSchedule of Rates @ 01 May 2015
Schedule of Rates @ 01 May 2015 We believe in always being 100% transparent. We are clear, upfront and honest about our company charges. Charges are per hour with a one hour minimum charge and thereafter
More informationGeneral Terms of Public Procurement in Service Contracts JYSE 2014 SERVICES
General Terms of Public Procurement in Service Contracts January 2015 Contents Introduction...3 Issues to be observed in applying...5 General Terms of Public Procurement in Service Contracts ()...9 1 Definitions...9
More informationRisks in International Consultancy Appointments: The FIDIC White Book
Risks in International Consultancy Appointments: The FIDIC White Book An increasing number of UK based consultants are involved in international projects. Given the forecasted growth in global construction
More informationFirewall and Managed Security Specific Terms and Conditions
Firewall and Managed Security Specific Terms and Conditions Rev 1.3 01.09.10 1. DEFINITIONS AND INTERPRETATION These Specific Terms and Conditions are to be read in conjunction with our General Terms and
More informationSCT AND MCAS MIRAMAR FOTS SOUTHERN CALIFORNIA TRACON
1-5 CONSTRUCTION SCHEDULES 1-5.1 General, Network Analysis System (NAS).- 1-5.1.1 Applicable documents.- The Publication listed below forms a part of this specification and is applicable to the extent
More informationSECTION 01320 - CONSTRUCTION PROGRESS DOCUMENTATION PART 1 - GENERAL 1.1 RELATED DOCUMENTS
SECTION 01320 - CONSTRUCTION PROGRESS DOCUMENTATION PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division
More informationDealing with leaks. Our code of practice: on leakage
Dealing with leaks Our code of practice: on leakage Our code of practice on leakage In this leaflet Here at Northumbrian Water we have a duty to all of our customers and to the environment to promote the
More informationPublic Lecture. Engineers Ireland. How the Public Works Contracts. might be used in the Private Sector. Proposed Contract
Public Lecture at Engineers Ireland on How the Public Works Contracts might be used in the Private Sector by Ciaran Fahy Anthony Hussey Proposed Contract comprising Articles of Agreement Conditions of
More informationClick to edit Master title style
Click to edit Master title style Presentation September 2013 Disallowance Under the NEC ICES Seminar Pioneering Bahrain Construction Public sector Energy Real estate London Tax IT Dubai Manchester Infra
More informationCollaborative Scheduling using the CPM Method
MnDOT Project Management Office Presents: Collaborative Scheduling using the CPM Method Presenter: Jonathan McNatty, PSP Senior Schedule Consultant DRMcNatty & Associates, Inc. Housekeeping Items Lines
More informationMarket Standards for Corporate Actions Processing
Revised version 2012 Prioritised standards marked Market Standards for Corporate Actions Processing 1 Table of contents Introduction 3 Glossary 6 Sequence of dates graphs 10 Distributions Cash Distributions
More informationFinancial Controls over Payments to Contractors on Major Projects (IA 12 119 F) Leon Daniels, Managing Director, Surface Transport
FINAL INTERNAL AUDIT REPORT Financial Controls over Payments to Contractors on Major Projects (IA 12 119 F) Leon Daniels, Managing Director, Surface Transport Audit Conclusion: Audit Closed 28 June 2013
More informationTo be used in conjunction with the Invitation to Tender for Consultancy template.
GUIDANCE NOTE Tendering for, choosing and managing a consultant Using this guidance This information is not intended to be prescriptive, but for guidance only. Appointing consultants for relatively small
More informationDIRECTORATE OF ESTATES & FACILITIES
DIRECTORATE OF ESTATES & FACILITIES PROCEDURE AND INFORMATION MANUAL EPM PM4 Client Representative (University Project Manager) for Capital Projects Scope of Services Document Originated: April 2006 By:
More informationGeneral Terms and Conditions of the Association of Dutch Designers (BNO) February 2013
General Terms and Conditions of the Association of Dutch Designers (BNO) February 2013 1 Agreement, offer and confirmation 1.1 These General Terms and Conditions ( General Terms and Conditions ) govern
More informationGeneral Terms and Conditions of Sale and Delivery of Federatie Aandrijven en Automatiseren (Trading Companies)
General Terms and Conditions of Sale and Delivery of Federatie Aandrijven en Automatiseren (Trading Companies) Filed at the Registry of the Court of The Hague, the Netherlands, on 6 December 2011, under
More informationBUILDING AND CONSTRUCTION AUTHORITY SINGAPORE CONDITIONS OF TENDER
BUILDING AND CONSTRUCTION AUTHORITY SINGAPORE CONDITIONS OF TENDER TENDER NO : TENDER DESCRIPTION : THE LICENCE OF STORAGE PLOT AT THE PULAU PUNGGOL AGGREGATE TERMINAL EVALUATION CRITERIA 1. Unless otherwise
More informationEXHIBIT 2-2-C PROGRESS SCHEDULES
EXHIBIT 2-2-C PROGRESS SCHEDULES PART 1 GENERAL 1.01 SUMMARY A. The work specified in this section consists of furnishing transportation, labor, materials, equipment and incidentals necessary for preparation,
More informationProject Bank Account Awareness
Project Bank Account Awareness Background of Fair Payment and PBAs PBAs explained Business Case Perceptions v reality HA forecast take up Impact on HA & the extended the supply chain Responsibilities KPIs
More informationDashboards and Reporting for Program Management
MnDOT Project Management Office Presents: Dashboards and Reporting for Program Management Presenter: Jonathan McNatty Senior Schedule Consultant DRMcNatty & Associates, Inc. Housekeeping Items Lines will
More information108-C-215 CRITICAL PATH METHOD SCHEDULE. (Revised 03-24-10)
CRITICAL PATH METHOD SCHEDULE (Revised 03-24-10) The Standard Specifications are revised as follows: SECTION 108, BEGIN LINE 177, INSERT AS FOLLOWS: 108.04.1 Critical Path Method Schedule (a) General Requirements
More informationGENERAL CONDITIONS OF CONTRACT MINOR WORKS AND SERVICES
GENERAL CONDITIONS OF CONTRACT MINOR WORKS AND SERVICES GENERAL CONDITIONS OF CONTRACT FOR MINOR WORKS PAGE 1 BASE D ON WA LOCAL GOVERNMENT ASSOCIATION MODEL 2010 TABLE OF CONTENTS 1 INTERPRETATION 2 RISE
More informationPROJECT MANAGEMENT GUIDELINES NATIONAL TRANSPORT AUTHORITY
PROJECT MANAGEMENT GUIDELINES FOR PROJECTS FUNDED BY THE NATIONAL TRANSPORT AUTHORITY (UP TO 20 MILLION IN VALUE) december 2011 Table of Contents Section A 1. Introduction 4 1.1 Purpose 4 1.2 Applicability
More informationConstruction Performance Bond. THIS CONSTRUCTION PERFORMANCE BOND ( Bond ) is dated, is in the penal sum of. Sample Preview CONTRACTOR: Address
Construction Performance Bond THIS CONSTRUCTION PERFORMANCE BOND ( Bond ) is dated, is in the penal sum of [which is one hundred percent of the Contract Price], and is entered into by and between the parties
More informationHow To Write A Contract
Commercial Management the NEC Way Hong Kong Institute of Surveyors Ian.Heaphy@turntown.com Mark.Lyddon@turntown.com, July 2014 Turner & Townsend plc July 14 making the difference Health, safety & wellbeing
More informationPractical Completion
Practical Completion Richard Davies CIBSE Home Counties SE Region 1 Practical Completion What is Practical Completion? A certificate of Practical Completion marks the point at which the Contractor has
More informationGeneral Terms and Conditions for Service companies
for Service companies Applicable to the provision of services and the delivery of goods by members facility companies of the listed trade association. These general conditions of sale and delivery shall
More informationCONDITIONS OF TENDER TENDER DESCRIPTION : THE CONSTRUCTION, MANAGEMENT AND OPERATION OF READY-MIX CONCRETE BATCHING PLANT AT
CONDITIONS OF TENDER TENDER NO : XXX TENDER DESCRIPTION : THE CONSTRUCTION, MANAGEMENT AND OPERATION OF READY-MIX CONCRETE BATCHING PLANT AT EVALUATION CRITERIA 1. Unless otherwise allowed by the Ministry
More informationSmart Meters Programme Schedule 5.2. (Software) (CSP North version)
Smart Meters Programme Schedule 5.2 (Software) (CSP North version) Schedule 5.2 (Software) (CSP North version) Amendment History Version Date Status v.1 Signature Date Execution copy SCHEDULE 5.2 SOFTWARE
More informationGETTING STARTED WITH THE NEC3
GETTING STARTED WITH THE NEC3 NEC3 TERM SERVICE CONTRACT (TSC) AND NEC3 TERM SERVICES SHORT CONTRACT (TSSC) Supported by: Published by the British Institute of Facilities Management April 2015 Introduction
More informationTerms and Conditions of Offer and Contract (Works & Services) Conditions of Offer
Conditions of Offer A1 The offer documents comprise the offer form, letter of invitation to offer (if any), these Conditions of Offer and Conditions of Contract (Works & Services), the Working with Queensland
More informationMnDOT Project Management Office Presents: Schedule Updates. Presenter: Eric Costantino Senior Schedule Consultant DRMcNatty & Associates, Inc.
MnDOT Project Management Office Presents: Schedule Updates Presenter: Eric Costantino Senior Schedule Consultant DRMcNatty & Associates, Inc. Housekeeping Items Lines will be muted during the webinar Questions
More informationTitle 10: COMMERCE AND TRADE
Title 10: COMMERCE AND TRADE Chapter 201-A: CONSTRUCTION CONTRACTS Table of Contents Part 3. REGULATION OF TRADE... Section 1111. DEFINITIONS... 3 Section 1112. APPLICATION... 4 Section 1113. OWNER'S PAYMENT
More informationTechnical Support Supplementary Terms Technical Support The Hideout
Technical Support Supplementary Terms We re The Hideout. www.thehideout.co.uk 1. Interpretation 1.1 The following definitions and rules of interpretation apply in these supplementary terms. Commercially
More informationImplementation and Customer Services ( ICS") Installation Services Standard Terms and Conditions of Supply. (Effective September 2013)
Implementation and Customer Services ( ICS") Installation Services Standard Terms and Conditions of Supply 1. General (Effective September 2013) This web page content defines the standard terms and conditions
More informationGeneral Terms of Public Procurement in service contracts JYSE 2009 SERVICES
General Terms of Public Procurement in service contracts November 2009 Contents Introduction........................................................................................................................................3
More informationwww.hughesjenkins.co.uk
HUGHES JENKINS SOLICITORS TERMS AND CONDITIONS OF BUSINESS Hughes Jenkins and Hughes Jenkins Solicitors are the trading names of Hughes Jenkins Limited A company limited by shares registered In England
More informationEXPERIENCE SHARING ON THE ADMISITRATION OF THE DSD PILOT CONTRACT (NEC
2 June 2012 EXPERIENCE SHARING ON THE ADMISITRATION OF THE DSD PILOT CONTRACT (NEC Option C) Contract No. DC/2008/02 Improvement of Fuk Man Road Nullah in Sai Kung Change of Consultant s Role & Highlights
More informationPLANNING & FORENSIC DELAY ANALYSIS
PLANNING & FORENSIC DELAY ANALYSIS Experts in international construction & engineering disputes 01 www.gtfairway.com Fairway Fairway is an internationally recognised company that provides expert analysis
More information01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION (SCHEDULING)
01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION (SCHEDULING) PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other
More informationboth the Employer and Contractor teams access and administer contracts in a common environment available 24hrs per day, 365 days per year
CEMAR is a simple to deploy, web-based solution to contract management and reporting with a minimum 99.5% availability. CEMAR achieves compliance through tailored workflow that: covers NEC3 ECC, TSC, PSC,
More informationST ANDREWS COMMUNITY HOSPITAL AND HEALTH CENTRE PROJECT MANAGEMENT AND MONITORING THE BOARD S OBLIGATIONS
ST ANDREWS COMMUNITY HOSPITAL AND HEALTH CENTRE PROJECT MANAGEMENT AND MONITORING THE BOARD S OBLIGATIONS GENERAL LEAD RESPONSIBILITY OBLIGATIONS UNDER THE PROJECT AGREEMENT Deliver to Project Co the Completion
More informationOptimizing Mega Project Execution with Integrated Interface Management and Project Scheduling
Optimizing Mega Project Execution with Integrated Interface Management and Project Scheduling By: Sandra MacGillivray VP, Product & Marketing 519-772-3181 Introduction In today s mega projects, implementing
More informationConditions of Contract for CONSTRUCTION
Conditions of Contract for CONSTRUCTION FOR BUILDING AND ENGINEERING WORKS DESIGNED BY THE EMPLOYER Multilateral Development Bank Harmonised Edition June 2010 General Conditions This publication is exclusive
More informationConstruction Claims in
Construction Claims in the Gulf ICES CPD Event 12/2012 ADMC Auditorium 19 December 2012 DISPUTES & INVESTIGATIONS ECONOMICS FINANCIAL ADVISORY MANAGEMENT CONSULTING Context» Aftermath of 2008 / 2009 financial
More informationProject Implementation Plan (PIP) User Guide
eea financial mechanism Project Implementation Plan (PIP) User Guide 23 November 2007 norwegian financial mechanism Page 2 of 20 1 Introduction The Project Implementation Plan (PIP) is a representation
More information15 For clarification and other details Please contact: 1. Asst. Manager - 8978027919 Please Note:
TENDER NOTICE 1 Name of the work and place Electrical works at sbi.intouch BRANCH (KADAPA), Y.S.R. District, Andhra Pradesh. 2 Estimated Cost Rs.9,51,186/- 3 Date of issue of tender through 23/06/16 Bank
More informationInsurance plans in accordance with the KVG
Insurance plans in accordance with the KVG Regulations Version 01.2014 To make the provisions of the contract easier to read, the male personal pronoun is used; these designations also apply to females.
More informationThames Water Utilities Limited. Settlement deed
Thames Water Utilities Limited Settlement deed DATED [ ] THAMES WATER UTILITIES LIMITED the Undertaker [ ] the Owner DEED relating to the mitigation of the effects of settlement arising from the construction
More informationSECTION 01 32 00 - PROJECT PLANNING AND SCHEDULING PART 1: GENERAL 1.1 DEFINITIONS
SECTION 01 32 00 - PROJECT PLANNING AND SCHEDULING PART 1: GENERAL 1.1 DEFINITIONS A. The term Baseline Schedule, as used throughout the contract documents, shall refer to a fixed projection of the project
More informationC1.2 CONTRACT DATA PROVIDED BY EMPLOYER (ECC3)
C1.2 CONTRACT DATA PROVIDED BY EMPLOYER (ECC3) The conditions of contract are the NEC3 Engineering and Construction Contract (June 2005), copies of which may be obtained from the South African Institution
More informationHelpdesk Service Guide. Building a Future with Care
Service Guide Building a Future with Care 1. Introduction and objectives 2. Prime overview 1. Introduction and objectives 3. Hours of operation 2. prime Help desk overview 4. How to contact Prime 3. Hours
More informationI loved reading the terms & conditions! said no one, ever. term deposit terms + conditions
I loved reading the terms & conditions! said no one, ever term deposit terms + conditions index. Part a - general terms and conditions. 2 1 Purpose of this booklet. 2 2 Meaning of words used. 2 3 Opening
More information1. Interpretation of this Schedule
Schedule 6 Programming Requirements 1. Interpretation of this Schedule 1.1 Primavera The following capitalised terms used in this Schedule 6 have the meanings given to them in the proprietary computer
More informationDRV Accountants & Adviseurs General terms and conditions Corporate Finance Versie 01-03-12 1
Filed with the Rotterdam Chamber of Commerce in Rotterdam on 26 March 2009 under number 24117094. Internet: www.drvcf.nl Offices in: Rotterdam Hoofdweg 52 P.O. Box 8560-3009 AN Rotterdam, Netherlands Telephone:
More informationConsumer Code. for Home Builders
Consumer Code for Home Builders This document contains the Consumer Code requirements together with non-mandatory good practice guidance for Home Builders Second Edition January 2010 Contents Meaning of
More informationWINTERSHALL NORGE AS GENERAL TERMS & CONDITIONS I FOR ONSHORE GOODS. Table of Content
WINTERSHALL NORGE AS GENERAL TERMS & CONDITIONS I FOR ONSHORE GOODS Table of Content Page 1. APPLICATION... 2 2. DEFINITIONS... 2 3. PURCHASE ORDER; ORDER CONFIRMATION... 2 4. THE GOODS... 2 5. QUALITY
More informationAll Portfolios - Actual against Budget
LEADERSHIP GROUP Project Cash Flow Forecasting Executive summary 1. At its meeting on 20 th September 2010, OMG discussed the tendency for projects to show an under spend in the first half of the financial
More informationATCO Gas Australia Commercial Gas Connection Request (CGR) Terms and Conditions Version Jan2015
ATCO Gas Australia Commercial Gas Connection Request (CGR) Terms and Conditions Version Jan2015 1. Definitions ATCO Gas Australia means ATCO Gas Australia Pty Ltd ACN 089 531 975 Authorised Representative
More informationUNIFIED FACILITIES GUIDE SPECIFICATIONS ************************************************************************** SECTION TABLE OF CONTENTS
USACE / NAVFAC / AFCEC / NASA UFGS-01 32 16.00 20 (February 2015) Change 2-11/15 ----------------------------------- Preparing Activity: NAVFAC Superseding UFGS-01 32 16.00 20 (November 2009) UNIFIED FACILITIES
More informationGeneral Terms and Conditions of NEC Tokin Europe GmbH
General Terms and Conditions of NEC Tokin Europe GmbH 1 Scope 1.1 These terms and conditions shall apply exclusively to all deliveries, services and quotations from NEC Tokin Europe GmbH hereafter referred
More informationEmployees monitoring of information and communication technologies private usage Guidelines updated in Portugal
COELHO RIBEIRO E ASSOCIADOS SOCIEDADE CIVIL DE ADVOGADOS Employees monitoring of information and communication technologies private usage Guidelines updated in Portugal CRA Coelho Ribeiro e Associados,
More information