American College of Real Estate Lawyers Tucson, Arizona March 18, FORCE MAJEURE IN BUILD-TO-SUIT LEASES By: Charles W.

Save this PDF as:
Size: px
Start display at page:

Download "American College of Real Estate Lawyers Tucson, Arizona March 18, 2005. FORCE MAJEURE IN BUILD-TO-SUIT LEASES By: Charles W."

Transcription

1 American College of Real Estate Lawyers Tucson, Arizona March 18, 2005 FORCE MAJEURE IN BUILD-TO-SUIT LEASES By: Charles W. Trainor An excusable delay, or force majeure, clause is an important element of all performance-based contracts, because delays occur which are beyond the ability of any party to the contract to control. Such provisions are standard fare in business contracts, and an essential part of real estate contracts. Since 9/11, force majeure clauses have become of greater importance in many other types of contracts because of the increased risk of terrorist attacks. In standard office, retail or industrial leases, the force majeure clause has always been important, but is generally a four or five-line provision which is rarely negotiated by a party. For example, if the landlord is constructing tenant improvements in an existing building, the force majeure clause will protect the landlord from tenant claims caused by excusable delays. It will also protect both the landlord and tenant from excusable delays which occur in the reconstruction of the premises after damage or destruction occurs. In the context of a build-to-suit lease, the force majeure clause becomes of greater importance for several reasons. First, the nature of a build-to-suit lease is generally the entire building (not just the tenant improvements) is being built to the tenant's specification. As a result, the construction work letter in a build-to-suit lease is much more extensive than in a standard lease. In fact, in such situations, it is not unusual for the work letter to exceed the length of the lease. The tenant is expecting the landlord to produce a particular building, usually with completed improvements, suited for its business by a particular time. The landlord is usually relying on its contractor to meet the tenant's requirements and does not want to be responsible for the contractor's delays (or at

2 least to shift the responsibilities or liabilities for such delays to the contractor). By their nature, build-to-suit leases have much greater economic implications than a lease for space in an existing single or multi-tenant building. While most leases give little credence to force majeure clauses, construction contracts treat delay, including force majeure, carefully. On a build-to-suit lease which involves a large construction project, it is wise for both the landlord and the tenant to carefully address the force majeure clause. You can be assured that it will be carefully addressed in the underlying construction contracts affecting the project. Excusable vs. Non-Excusable Delays. An excusable delay, or force majeure ("greater force"), is generally one that will justify the extension of a contractual deadline, excusing the delayed party from timely performance and default under the agreement. There are dozens of examples of excusable delay, many of which are set forth below. A non-excusable delay generally includes other delays which occur in the performance of a contract, and should have been anticipated or were caused by the party responsible for such delay or its contractor, subcontractors or consultants. Non-excusable delays usually result in penalties, defaults or other consequences. In the case of a build-to-suit lease, the tenant may include a penalty clause which would be activated for each day that the landlord is late in delivering the building due to non-excusable delay. Other Contract Provisions To Consider. When drafting an excusable delay clause, it is important to confirm that other clauses within the lease regarding times for performance are carefully coordinated in order to make the force majeure clause meaningful. First, the "time of the essence" clause is essential to the enforcement of delay claims. Although a simple clause, the absence of a time of the essence clause makes the timelines within the contract somewhat meaningless. Without the time of the essence clause, according to one court, the time

3 periods set forth in the contract can be interpreted as guidelines, rather than contract obligations (Burgess Construction Co. v. M. Morrin & Sons, 526 F.2d 108 (10th Cir. 1976)). In addition, great care must be given to clearly specifying the dates for performance. Of critical importance is the date that the timeline begins to run for construction of the project, as well as the date for completion of the contract. The circumstances of each transaction will dictate the appropriate language or documentation, but it is always an excellent idea, if the start date is not clearly specified in the contract, to execute an amendment to the contract when the time for performance begins. In leases, many times, the landlord agrees to construct the improvements within a certain period of time after approval of the plans by the municipality. This is a good example of a circumstance where the parties should agree upon the actual start date of that project. Clearly defining the date for performance is essential in implementing the force majeure provision. Non-Critical and Concurrent Delays. Many times, excusable delays will occur which do not delay the "critical path" of the project. For instance, unusual weather may occur which delays the project a few days, but the contractor may have already incorporated an anticipated number of "weather days" into its project schedule. As a further example, the delivery of certain materials may be delayed, but those components of the structure may be able to be installed at a later time without delaying the completion date of the project. Therefore, those types of delays are not "Critical Delays," and should not be the subject of force majeure extensions. Likewise, when there are multiple, concurrent force majeure events, the days of force majeure delay must be added together only to the extent that the date for performance is actually delayed. Definition of Force Majeure. Force majeure, in early leases, was defined as "Acts of God." The court in Akwa-Downey Construction Co., ASBCA No , 75-1 B.C.A. (CCH) (1975), defined Acts of God as "singular, unexpected and irregular

4 visitations of a force of nature." Obviously, force majeure in a build-to-suit lease situation should be defined broader than "uninvited forces of nature." The list of possible force majeure delays are probably endless. The following list, grouped into five categories, plus a catch-all category, lists numerous variations found by the author in a review of more than a dozen force majeure clauses: Labor Strikes Lockouts Labor Disturbances Walkouts Unavailability of Labor Materials Unavailability Theft Freight Embargo Unusual Delays in Transportation Acts of Others Vandalism Sabotage Harassment Terrorist Acts Acts of God Fires (except if caused by the contractor or subs) Floods Earthquakes Epidemics Quarantine Restrictions Accident, Fire Explosion or Catastrophe Unanticipated Weather Governmental Moratoriums Regulatory / Approval Delay Failure to Connect Utilities

5 Catch-All Phrases Beyond the Reasonable Control of the Landlord Unavoidable Calamities Unsafe Conditions on the Project Site Drafting Tips. Weather. A brief survey of force majeure cases indicated that weather delays were frequently the subject of litigation. Since any exterior construction contract will be subject to delays regarding weather, it is an area of force majeure that should be carefully considered by the drafting attorney. First, contractors will generally include, in their critical path timeline, a number of days for weather delays. A drafter should determine how many days the landlord in a build-to-suit lease has allocated for unanticipated weather, and take those into account in the force majeure clause (see sample clause below). In addition, the definition of weather delays should be carefully considered. The standard Federal construction contract refers to "unusually severe weather." The AIA Document A201 provides for excusable delays due to "adverse weather conditions not reasonably anticipatable." The AIA contract goes on to provide that a time extension as the result of weather will only be granted when (a) the weather conditions were abnormal, (b) the weather conditions could not have been reasonably anticipated, and (c) the weather conditions had an adverse affect on the scheduled construction. Documenting the Delay. In order to avoid unnecessary controversies, it is highly recommended that delays in force majeure be documented within a very short period of time after their occurrences, or waived. The typical scenario is a significantly delayed (in this example) owner, who attempts to justify the delays at the end of the project by claiming there were force majeure events which occurred near the beginning of the contract. This situation obviously creates a dispute which will be difficult to resolve without recreating events which may have happened months earlier. By requiring the immediate reporting or waiver of the force majeure events, any controversy over the

6 validity of such events can be addressed promptly, thereby avoiding recreation of facts and fading memories. The clause below attempts to deal with this issue, and a sample force majeure delay reporting form is attached hereto as an exhibit. As an alternative to a reporting form, construction meeting minutes which incorporate this information, signed by both parties, should be an alternative to the formal reporting method. Validity of Claim. The force majeure clause should address the validity of the claim by ensuring that the clause addresses the following five questions: a. Was the delay reasonable? b. Who was the cause of the delay? c. Was there actually a critical path delay extending the completion date? d. Was it concurrent with other delays? Exclusions. Certain matters should be excluded from force majeure delays, such as the financial inability of the landlord to perform. Also, in selecting the force majeure provisions to include into the contract, you should carefully take into account the party that you are representing. If a tenant prefers to process its own tenant improvement plans, and those plans are delayed, the landlord may very well not want to have the delay in processing the improvement plans by the governmental agency as a force majeure event. On the other hand, if the landlord is processing the tenant improvement plans with its building plans, it may be willing to assume the risk of a delay by the governmental agency in the approval of the plans as a force majeure event. Limitations on Force Majeure Events. No tenant wants to wait indefinitely for its building to be constructed, no matter how many force majeure events occur. Likewise, no landlord wants its rent to be delayed indefinitely, no matter how many tenant force majeure events occur. Therefore, it is important to place, in the force majeure clause or elsewhere, the limitations on the maximum number of days of delay which can occur before a termination of the lease, commencement of the rent, etc. In the case of a build-to-suit lease, where the building and improvements are being constructed

7 by the landlord, the tenant may want both the right to terminate the lease or to exercise self-help in completing the project, if the landlord's delays pass a specified date. Likewise, a landlord will want the rent under a lease to eventually begin, no matter how many days of force majeure delay a tenant has prior to opening its business. In either event, it is important to address these provisions within the body of the lease. Force Majeure Sample Clause (Build-to-Suit Lease). In the event that either party is prevented from timely performing its obligations hereunder by a Force Majeure Event (as hereinafter defined), and such Force Majeure Event (a) is timely reported as hereinafter provided, (b) actually results in a Critical Delay (as hereinafter defined) and (c) does not cause the number of Force Majeure Days (as hereinafter defined) to exceed the Maximum Force Majeure Days (as hereinafter defined) applicable to that party, if any, such party shall be excused from its timely performance hereunder, and no default shall have occurred, nor any penalties or damages shall be assessed as a result of such delay. As used herein, the term "Force Majeure Event" means the following events, to the extent that they are not caused by the negligent actions or inactions of the party, its contractors, subcontractors or consultants: (a) fires, floods, earthquakes, Unusually Severe Weather (as hereinafter defined) or other natural catastrophe; (b) labor strikes, lockouts, disturbances or walkouts, or unavailability of labor; (c) vandalism, accidents, sabotage, harassment, terrorist acts, riots or acts of war; (d) governmental moratoriums, significant and unusual delays in governmental approvals, or the failure of third parties to provide necessary services (such as utilities) to the premises; (e) unavailability, theft, or embargo of materials, or unanticipated delays in the delivery of materials; (f) unsafe conditions on the premises; or (g) matters beyond the reasonable control of the parties which are not expressly stated above, but are of the same type and character as the foregoing examples. A Force Majeure Event shall not include any occurrence caused by the financial inability of a party, its contractors or subcontractors to perform their obligations, or the delay in financial performance by a party, its contractors or subcontractors. A "Critical Delay," as used herein, is a delay caused by a Force Majeure Event which necessarily and actually results in a delay of the final date for performance of an obligation by a party (such as a completion date for improvements). Force Majeure Events, including concurrent Force Majeure Events, which do not necessarily and actually extend the final date for performance are not Critical Delays. The party experiencing a Force Majeure Event shall use its commercially reasonable efforts to minimize the Critical Delay caused by such Event. A "Force Majeure Day," as used herein, is a Business Day (as defined in Section ) of Critical Delay caused by a

8 Force Majeure Event. The "Maximum Force Majeure Days," as used herein, as it relates to Landlord's completion of the Improvements, is seventy-five (75) Business Days. The Maximum Force Majeure Days for Tenant prior to Commencement of the Rent is twenty (20) Business Days. There are no other restrictions on the Maximum Number of Force Majeure Days except as set forth in the Lease. The term "Unusually Severe Weather," as used herein, means abnormal weather conditions which could not have been reasonably anticipated and which actually delayed the performance by a party of its obligations hereunder. To the extent that a party had anticipated and included weather delays in its critical path for completion of an obligation hereunder, those anticipated days of Unusually Severe Weather must be exhausted before Force Majeure Days will be granted hereunder. No Force Majeure Days will be granted to a party unless that party has completed and submitted to the other party a fully completed and executed Excusable Delay Reporting Form in the form attached hereto. The party receiving such form must sign and return the form, approving or disapproving the Force Majeure Days to the submitting party within five (5) Business Days, or the request for Force Majeure Days shall be deemed approved. The failure of a party to submit a request for Force Majeure Days to the other party within ten (10) Business Days after the Force Majeure Event shall be deemed a waiver of the right to any Force Majeure Days as a result of the particular Force Majeure Event. In the event that the parties are holding regular construction meetings, and include an agreement of such Force Majeure Days in the construction minutes within ten (10) business days of the Force Majeure Event, such signed minutes shall be deemed to have satisfied this reporting requirement. In the event that the parties are unable to agree upon the validity of a Force Majeure Event, or the number of Force Majeure Days, the matter shall be resolved by the dispute resolution provisions of Section of the Lease

9 EXCUSABLE DELAY REPORTING FORM This Form must be submitted to Tenant within ten business days after the occurrence of an excusable delay. Failure to timely submit this Form shall result in an automatic denial of the request for excusable delay. Failure to timely respond to such request for excusable delay shall be deemed approval. Project: Owner: Tenant: Date of Request: Number of Force Majeure Days Requested: Dates on Which the Force Majeure Event Occurred: Reason for the Request: Attach supporting documentation relevant to this request (letters from suppliers, weather data, etc., as needed) The undersigned hereby certifies that Critical Delays have occurred due to a Force Majeure Event and the completion date for the project (or the portion thereof on which the undersigned is working) has been delayed for the number of days requested above as a result of reasons stated above. Revised Completion Date: Signed Date: Approved Disapproved: Reason for Disapproval Signed Date:

PROVO CITY UTILITIES NET METERING LICENSE AGREEMENT

PROVO CITY UTILITIES NET METERING LICENSE AGREEMENT PROVO CITY UTILITIES NET METERING LICENSE AGREEMENT Customer-Owned Electric Generating Systems of 25kW or Less This NET METERING LICENSE AGREEMENT ( Agreement ) is between ( Customer ) and Provo City -

More information

SolarEdge Technologies Ltd.

SolarEdge Technologies Ltd. SolarEdge Technologies Ltd. GENERAL TERMS AND CONDITIONS 1. General. This document, entitled General Terms and Conditions (referred to herein as the Agreement ), forms an integral part of the quotation

More information

1.4 Licenses, Permits, Fees and Assessments.

1.4 Licenses, Permits, Fees and Assessments. PROFESSIONAL SERVICES AGREEMENT THIS CONTRACT SERVICES AGREEMENT (herein Agreement ), is made and entered into this day of, 2012, by and between the Anaheim Transportation Network, a California non-profit

More information

CONSULTANT AGREEMENT

CONSULTANT AGREEMENT CONSULTANT AGREEMENT AGREEMENT made this day of, 20, by and between PACE UNIVERSITY, One Pace Plaza, New York, New York 10038 (hereinafter referred to as Pace ), and [FULL LEGAL NAME OF CONSULTANT], with

More information

WEB HOSTING AGREEMENT

WEB HOSTING AGREEMENT WEB HOSTING AGREEMENT This Hosting Agreement (this Agreement ) is made and entered into by and between Rotovac Corporation, a Washington corporation with offices at 17905 Bothell Everett Hwy, Mill Creek,

More information

CARACOL LIMITED TIME HOME BUILDING INCENTIVE RIDER

CARACOL LIMITED TIME HOME BUILDING INCENTIVE RIDER CARACOL LIMITED TIME HOME BUILDING INCENTIVE RIDER Attached to and made a part of the Purchase Agreement dated, 2012 (the Agreement ) between Blackberry Island, LP ( Seller ) and ( Purchaser ) Purchaser

More information

Design Development Agreement

Design Development Agreement Design Development Agreement June 2010 prepared by Larry Kirkland, PAN Council Member and The Law Office of Sarah Conley Disclaimer The Public Art Commission Agreement is made available as a service of

More information

LOGGING SUBCONTRACT. Recital

LOGGING SUBCONTRACT. Recital LOGGING SUBCONTRACT This Logging Contract (this Contract ) is entered as of the day of, 200, by and between ("Contractor") and ("Subcontractor") as follows: Recital The owners of certain timber growing

More information

CEI Standard Form Consulting Services Agreement

CEI Standard Form Consulting Services Agreement CEI Standard Form Consulting Services Agreement The parties to this Consulting Services Agreement ("Agreement") are Competitive Energy Insight, Inc., a California Corporation ("CEI") having its principal

More information

How to Negotiate Adequate Casualty Provisions

How to Negotiate Adequate Casualty Provisions How to Negotiate Adequate By Alan M. Cohen, Esq. provisions in commercial leases typically receive less attention than other provisions during lease negotiations. However, recent hurricanes and earthquakes

More information

TRANSPORTATION AGREEMENT

TRANSPORTATION AGREEMENT TRANSPORTATION AGREEMENT THIS AGREEMENT ( Agreement ) is dated as of, 200 between including its subsidiaries (collectively, Shipper ), and Dick Harris and Son Trucking Co., Inc. (Carrier). Carrier agrees

More information

The Processing Agreement

The Processing Agreement The Processing Agreement THIS AGREEMENT is effective this day of, 201, by and between Intelligent ecommerce, Inc. hereinafter ATMDepot.com, 119 N El Camino Real Ste #E-136 Encinitas, CA 92024 (the "Company")

More information

SERVICES AGREEMENT. 2. Term. This Agreement will commence and expire. Medical Center Representative: Name and Title

SERVICES AGREEMENT. 2. Term. This Agreement will commence and expire. Medical Center Representative: Name and Title This Services Agreement ( Agreement ) dated is made by and between [INSERT CONTRACTOR S NAME AND ADDRESS] (hereinafter called "Contractor"), and UMass Memorial Medical Center, Inc., Worcester, MA (hereinafter

More information

Newcomb Transportation & Logistics, Inc. Shipper/Broker Terms & Conditions

Newcomb Transportation & Logistics, Inc. Shipper/Broker Terms & Conditions NEWCOMB TRANSPORTATION AND LOGISTICS SHIPPER TERMS & CONDITIONS 1. APPLICABILITY These Terms & Conditions and agreed upon pricing documents apply to all broker services (the Services ) provided by Youbulk,

More information

To Whom It May Concern:

To Whom It May Concern: To Whom It May Concern: The Ohio Treasurer of State ( Treasurer ) may be eligible for an initial allocation of 100,000 student loan accounts to become a Not-For-Profit Direct Loan Servicer, as permitted

More information

Master Service Agreement

Master Service Agreement This Master Services Agreement ( MSA ) is entered into by Rack Alley Inc., a Wyoming corporation, and its affiliates ( Company ), and the below-signed customer ( Customer ) on the date Customer signs the

More information

General Terms and Conditions of Sale and Delivery BruggemannChemical U.S., Inc. Date: January 1, 2012. I. General

General Terms and Conditions of Sale and Delivery BruggemannChemical U.S., Inc. Date: January 1, 2012. I. General General Terms and Conditions of Sale and Delivery BruggemannChemical U.S., Inc. Date: January 1, 2012 I. General 1.1 The following general terms and conditions of sale and delivery (hereinafter General

More information

Relocation Services Request for Proposal

Relocation Services Request for Proposal SCOPE OF WORK The University of South Carolina (University) is seeking proposals from qualified entities to provide comprehensive relocation services to interested faculty and staff being employed on any

More information

MIGHTY MIKE PLUMBING, INC. PLUMBING GENERAL CONTRACTOR SERVICES PROPOSAL

MIGHTY MIKE PLUMBING, INC. PLUMBING GENERAL CONTRACTOR SERVICES PROPOSAL MIGHTY MIKE PLUMBING, INC. PLUMBING GENERAL CONTRACTOR SERVICES PROPOSAL PROPOSAL: Proposal No./Date: Address of Property where Services are to be Performed: Name of Person on Whose Behalf Services are

More information

0%- Shop Now Pay Later Program- Terms & Condition

0%- Shop Now Pay Later Program- Terms & Condition 0%- Shop Now Pay Later Program- Terms & Condition In consideration of First Gulf Bank PJSC (hereafter referred to as the Bank ) agreeing to make available the 0% Program ( as defined hereunder) to the

More information

BECKER COUNTY ENHANCED REMOTE ACCESS AGREEMENT

BECKER COUNTY ENHANCED REMOTE ACCESS AGREEMENT BECKER COUNTY ENHANCED REMOTE ACCESS AGREEMENT This agreement is entered into by and between the county of Becker, through its Recorder/Registrar of Titles Office, 915 Lake Avenue, Detroit Lakes, MN 56501,

More information

Geomant Americas Inc. END USER SOFTWARE LICENSE AGREEMENT

Geomant Americas Inc. END USER SOFTWARE LICENSE AGREEMENT Geomant Americas Inc. END USER SOFTWARE LICENSE AGREEMENT 1.Definitions. The following terms are defined for the purposes of this Agreement as follows: (a) Client shall mean any Reseller provided client

More information

This AGREEMENT is made as of the day of in the year of, by and between the following parties, for the sale of materials.

This AGREEMENT is made as of the day of in the year of, by and between the following parties, for the sale of materials. MCPU Standard Contract 101 Agreement Between Seller and Buyer For Sale on Credit This document has important legal consequences. Consultation with an attorney is recommended with respect to its completion,

More information

CONSULTING AGREEMENT. Affordable Wireless Solutions

CONSULTING AGREEMENT. Affordable Wireless Solutions CONSULTING AGREEMENT SERVICES AND CONSULTING RATES & FEES Travel Expenses Reimbursement: 1. Mileage, in excess of 20 miles traveled per day, reimbursed per the most recent IRS guidelines 2. Parking Fees

More information

AIA Document A141 TM - 2004 Standard From of Agreement Between Owner and Design- Builder

AIA Document A141 TM - 2004 Standard From of Agreement Between Owner and Design- Builder AIA Document A141 TM - 2004 Standard From of Agreement Between Owner and Design- Builder AGREEMENT made as of the day of in the year of (In words, indicate day, month and year) BETWEEN the Owner: (Name,

More information

Master Agreement Applicable to System Integration Services Furnished By KDDI America, Inc.

Master Agreement Applicable to System Integration Services Furnished By KDDI America, Inc. Master Agreement Applicable to System Integration Services Furnished By KDDI America, Inc. Page 1 of 9 THIS MASTER AGREEMENT FOR SYSTEM INTEGRATION SERVICE (the Agreement ) is made by and between KDDI

More information

AGENT AGREEMENT. I. Agent s Obligations

AGENT AGREEMENT. I. Agent s Obligations AGENT AGREEMENT This Agent Agreement ( Agreement ) is made on this day of, 2009, by and between Krascar International Travel Club, Inc (hereinafter referred to as Company ) located at 1162 St Georges Ave

More information

SELLING TERMS AND CONDITIONS

SELLING TERMS AND CONDITIONS SELLING TERMS AND CONDITIONS 1. The Agreement. All sales by Sterling Machinery, Inc., an Arkansas corporation (the Seller ) to the purchaser of Seller s Goods (the Buyer ) shall be governed by the following

More information

EXHIBIT 1 Standard Contract Addendum

EXHIBIT 1 Standard Contract Addendum EXHIBIT 1 Standard Contract Addendum This Standard Contract Addendum ( Addendum ) is between Texas Southern University ( University ) and the other party ( Contracting Party ) indicated in the signature

More information

M AINTENANCE S ERVICE A GREEMENT L ABOR O NLY

M AINTENANCE S ERVICE A GREEMENT L ABOR O NLY M AINTENANCE S ERVICE A GREEMENT L ABOR O NLY This Maintenance Service Agreement ("Agreement") is entered into as of the day of, 2002 between, (the "Client"), whose address is, and Florida Sound Engineering

More information

SEO Agreement SEARCH ENGINE OPTIMIZATION AND REPORTING AGREEMENT

SEO Agreement SEARCH ENGINE OPTIMIZATION AND REPORTING AGREEMENT SEO Agreement SEARCH ENGINE OPTIMIZATION AND REPORTING AGREEMENT This Search Engine Optimization and Reporting Agreement ("Agreement") is hereby entered into between India Market Softech (P)Ltd. (hereinafter

More information

CONSULTING SERVICES AGREEMENT

CONSULTING SERVICES AGREEMENT EXHIBIT 10.2 CONSULTING SERVICES AGREEMENT THIS CONSULTING SERVICES AGREEMENT, effective as of July 6, 2011, is between RICHARD PENNER CONSULTING, INC., a Washington corporation located in Blaine, Washington,

More information

CONSTRUCTION AND PURCHASE CONTRACT (Fixed Price - Builder-owned Lot)

CONSTRUCTION AND PURCHASE CONTRACT (Fixed Price - Builder-owned Lot) Home Builders Association of HBA Phone Contract No. CONSTRUCTION AND PURCHASE CONTRACT (Fixed Price - Builder-owned Lot) THIS CONTRACT, dated, 20, between (referred to as "Builder") and (referred to as

More information

E-MAIL LIST RENTAL PROCESSING ACKNOWLEDGEMENT FORM

E-MAIL LIST RENTAL PROCESSING ACKNOWLEDGEMENT FORM E-MAIL LIST RENTAL PROCESSING ACKNOWLEDGEMENT FORM Anchor Computer, Inc. requires that each customer sign an E-Mail List Rental Processing Acknowledgement Form prior to the commencement of any E-MAIL LIST

More information

DIR Information Security Forum

DIR Information Security Forum Texas Department of Information Resources DIR Information Security Forum May 20-21, 2015 Palmer Events Center Austin, Texas Terms and Conditions 1. Purpose The Information Security Forum (ISF) is an educational

More information

Balance Transfer Holiday PROGRAM- TERMS & CONDITIONS

Balance Transfer Holiday PROGRAM- TERMS & CONDITIONS Balance Transfer Holiday PROGRAM- TERMS & CONDITIONS In consideration of First Gulf Bank PJSC (the Bank ) agreeing to make available the Program (as defined below) to the Cardholder at the Cardholder s

More information

CLAIMS ADMINISTRATION SERVICES AGREEMENT

CLAIMS ADMINISTRATION SERVICES AGREEMENT Attachment D.13 CLAIMS ADMINISTRATION SERVICES AGREEMENT This AGREEMENT is made and entered into by and between SANTA BARBARA SCHOOL DISTRICTS hereinafter referred to as "DISTRICT", and KEENAN & ASSOCIATES,

More information

MASTER SERVICES AGREEMENT

MASTER SERVICES AGREEMENT MASTER SERVICES AGREEMENT Customer: City of Irondale, Water Works Board Customer Address: (PO Box 100188) 101 20 th Street South, Irondale, AL 35210 Contact for Notices to Customer: Customer Phone/Fax/Email

More information

6. WARNING BY BUYER. BUYER shall give warning of any possible hazard to any person or persons to whom BUYER resells, gives or delivers the Property

6. WARNING BY BUYER. BUYER shall give warning of any possible hazard to any person or persons to whom BUYER resells, gives or delivers the Property TERMS AND CONDITIONS FOR ONLINE TRANSACTIONS TO PURCHASE GP PROPERTY (VIA GOINDUSTRY DOVEBID) By submitting a bid to purchase the Property (as defined below), BUYER (as defined below) agrees that the following

More information

DEDICATED SYSTEM HOSTING AGREEMENT BETWEEN RAPIDHOST LIMITED AND <COMPANY NAME>

DEDICATED SYSTEM HOSTING AGREEMENT BETWEEN RAPIDHOST LIMITED AND <COMPANY NAME> DEDICATED SYSTEM HOSTING AGREEMENT BETWEEN RAPIDHOST LIMITED AND Dedicated System Hosting Agreement THIS AGREEMENT is dated and is made between (1) RapidHost being RapidHost Ltd.

More information

INSTRUCTIONS PAGE (Great-West Retirement Services ISA)

INSTRUCTIONS PAGE (Great-West Retirement Services ISA) INSTRUCTIONS PAGE (Great-West Retirement Services ISA) Fillable PDF Forms: These PDF forms can be filled out at your computer by simply clicking on the lines or boxes on the form and then typing the information

More information

SMALL GENERATION SYSTEM INTERCONNECTION AGREEMENT (10 kw OR LESS)

SMALL GENERATION SYSTEM INTERCONNECTION AGREEMENT (10 kw OR LESS) SMALL GENERATION SYSTEM INTERCONNECTION AGREEMENT (10 kw OR LESS) Interconnection Agreement, Terms, and Conditions This Small Generation System Interconnection Agreement (10 kw or less) ( Agreement ),

More information

NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT INTERNET SERVICE Contract Number: 044552-1415

NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT INTERNET SERVICE Contract Number: 044552-1415 NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT INTERNET SERVICE Contract Number: 044552-1415 This agreement for the provision of Exchange Hosting service ("Agreement") is entered

More information

This service agreement (hereinafter referred to as the Agreement ) is between

This service agreement (hereinafter referred to as the Agreement ) is between SEATTLECLOUDS WHITE LABEL SERVICE AGREEMENT This service agreement (hereinafter referred to as the Agreement ) is between Mobiblocks, LLC. (hereinafter referred to as Mobiblocks ), a Washington Corporation,

More information

ADVISORY AGREEMENT. 1) Advisor s Services. 235 Harrison St. Mail Drop #69 Syracuse, NY 13202 (315) 288-6340 www.picowealthmanagement.

ADVISORY AGREEMENT. 1) Advisor s Services. 235 Harrison St. Mail Drop #69 Syracuse, NY 13202 (315) 288-6340 www.picowealthmanagement. 235 Harrison St. Mail Drop #69 Syracuse, NY 13202 (315) 288-6340 www.picowealthmanagement.com ADVISORY AGREEMENT This Engagement Agreement sets forth the Advisory contract entered into by and between Pico

More information

[INSERT COMPANY NAME IN CAPS]

[INSERT COMPANY NAME IN CAPS] MINUTE OF AGREEMENT Between CHURCH OF SCOTLAND CONGREGATION (hereinafter referred to as the Church ) And [INSERT COMPANY NAME IN CAPS], a company incorporated under the Companies Acts (Company Number [

More information

LEASE AGREEMENT INSURANCE AND INDEMNIFICATION LANGUAGE

LEASE AGREEMENT INSURANCE AND INDEMNIFICATION LANGUAGE LEASE AGREEMENT INSURANCE AND INDEMNIFICATION LANGUAGE Tenant assumes the liability for damage to its improvements, fixtures, partitions, equipment and personal property therein, and all appurtenances

More information

ECLIPSE FOUNDATION, INC. MEMBERSHIP AGREEMENT

ECLIPSE FOUNDATION, INC. MEMBERSHIP AGREEMENT ECLIPSE FOUNDATION, INC. MEMBERSHIP AGREEMENT THIS MEMBERSHIP AGREEMENT (the Agreement ) is effective as of this day of, 20 (the Effective Date ) by and between Eclipse Foundation, Inc. (the Eclipse Foundation

More information

PROFESSIONAL/CONSULTING SERVICES AGREEMENT

PROFESSIONAL/CONSULTING SERVICES AGREEMENT This SERVICES AGREEMENT ( Agreement ) is entered into by and between the undersigned, ( Contractor ), (Social Security Number or Federal I.D. No.), located at and Texas Southern University ( TSU ), an

More information

Hosting Service Agreement

Hosting Service Agreement tesseract-online.com Hosting Service Agreement Cranbox Limited T/A Tesseract Commencement Date: 1. Agreement 1.1. This Agreement is made between you (the 'Customer') and Cranbox Limited trading as Tesseract

More information

General Terms and Conditions of Sale

General Terms and Conditions of Sale RUETGERS Canada Inc. General Terms and Conditions of Sale 1 Defined Terms In these terms and conditions of sale: Advice means any advice, opinion, assistance, representation or statement of any sort whatsoever,

More information

WAREHOUSE SERVICE AGREEMENT ( AGREEMENT ) DIRECT INTEGRATED TRANSPORTATION ULC d/b/a DIRECT DISTRIBUTION CENTRES ( Service Provider )

WAREHOUSE SERVICE AGREEMENT ( AGREEMENT ) DIRECT INTEGRATED TRANSPORTATION ULC d/b/a DIRECT DISTRIBUTION CENTRES ( Service Provider ) WAREHOUSE SERVICE AGREEMENT ( AGREEMENT ) BETWEEN: THIS AGREEMENT is entered into as of the day of, 201_, DIRECT INTEGRATED TRANSPORTATION ULC d/b/a DIRECT DISTRIBUTION CENTRES ( Service Provider ) AND:

More information

CONSULTANT AGREEMENT

CONSULTANT AGREEMENT CONSULTANT AGREEMENT THIS AGREEMENT, entered into this day of, 2015, by and between CITY OF ALAMEDA, a municipal corporation (hereinafter referred to as "City"), and, a whose address, hereinafter called

More information

Virtual Office Lease Agreement between. Lease Name, Tenant. JAMESTOWNE PROFESSIONAL PARK LLC., Landlord

Virtual Office Lease Agreement between. Lease Name, Tenant. JAMESTOWNE PROFESSIONAL PARK LLC., Landlord Virtual Office Lease Agreement between Lease Name, Tenant & JAMESTOWNE PROFESSIONAL PARK LLC., Landlord 1769 Jamestown Road, Williamsburg VA 23185 757-220-1210 (P). 757-220-1694 (F). Info@JProPark.com.

More information

Queen Margaret University, Musselburgh, Edinburgh, EH21 6UU APPENDIX A: CONFERENCING & EVENTS GENERAL TERMS & CONDITIONS

Queen Margaret University, Musselburgh, Edinburgh, EH21 6UU APPENDIX A: CONFERENCING & EVENTS GENERAL TERMS & CONDITIONS Queen Margaret University, Musselburgh, Edinburgh, EH21 6UU APPENDIX A: CONFERENCING & EVENTS GENERAL TERMS & CONDITIONS THIS IS APPENDIX A REFERRED TO IN THE FOREGOING BOOKING BETWEEN QUEEN MARGARET UNIVERSITY

More information

CONCIERGE SERVICE AGREEMENT. THIS AGREEMENT made this day of, 20, by and between QILIVING,

CONCIERGE SERVICE AGREEMENT. THIS AGREEMENT made this day of, 20, by and between QILIVING, CONCIERGE SERVICE AGREEMENT THIS AGREEMENT made this day of, 20, by and between QILIVING, LLC., a New York Limited Liability Company with an address at 234 East 58 th Street, Suite 3 New York, New York

More information

7504-52 Street Edmonton Alberta T6B 2G3 Tel: 780-439-6746 Fax: 780-439-6807 howcogroup.com. Canada Terms

7504-52 Street Edmonton Alberta T6B 2G3 Tel: 780-439-6746 Fax: 780-439-6807 howcogroup.com. Canada Terms Canada Terms The following terms and conditions shall control the terms of any contracts relating to the sales of goods by Howco Group Canada Limited (Howco), and shall supersede and replace any preprinted

More information

Kiwi Energy NY LLC 144 North 7 th Street #417 Brooklyn, NY 11249 1-877- 208-7636 www.kiwienergy.us

Kiwi Energy NY LLC 144 North 7 th Street #417 Brooklyn, NY 11249 1-877- 208-7636 www.kiwienergy.us Kiwi Energy NY LLC 144 North 7 th Street #417 Brooklyn, NY 11249 1-877- 208-7636 www.kiwienergy.us Natural Gas / Electricity SALES AGREEMENT Customer Disclosure Statement Page 1 Price: Variable rate per

More information

Residential Lease. LAST MONTH'S RENT. Landlord will be collecting $[ propzip ] as last month's rent at the commencement of this Lease.

Residential Lease. LAST MONTH'S RENT. Landlord will be collecting $[ propzip ] as last month's rent at the commencement of this Lease. Residential Lease This Lease is entered into by and between [ landlordfirst ] [ landlordmiddle ] [ landlordlast ], whose address is [ landlordaddress ] [ landlordapt ], [ landlordcity ], [ landlordstate

More information

PENNSYLVANIA BUILDERS ASSOCIATION INSTRUCTIONS TO HOME IMPROVEMENT MODEL CONTRACT STANDARD FORM Introduction

PENNSYLVANIA BUILDERS ASSOCIATION INSTRUCTIONS TO HOME IMPROVEMENT MODEL CONTRACT STANDARD FORM Introduction PENNSYLVANIA BUILDERS ASSOCIATION INSTRUCTIONS TO HOME IMPROVEMENT MODEL CONTRACT STANDARD FORM Introduction Below are instructions for use with the Home Improvement Model Contract Standard Form, which

More information

Terms and Conditions for Purchase Orders for Recycling Materials

Terms and Conditions for Purchase Orders for Recycling Materials Terms and Conditions for Purchase Orders for Recycling Materials This Agreement is made by and between AEROJET-GENERAL CORPORATION, an Ohio corporation with a place of business at Rancho Cordova, California

More information

THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE

THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE WHEREAS The Sustainable Energy Authority of Ireland (hereinafter called SEAI ) of Wilton Park House, Wilton Place,

More information

WASTE SERVICES & DISPOSAL AGREEMENT. By: By: Name: Name: Title: Title:

WASTE SERVICES & DISPOSAL AGREEMENT. By: By: Name: Name: Title: Title: WASTE SERVICES & DISPOSAL AGREEMENT COMPANY: CUSTOMER: By: By: Name: Name: Date Date Title: Title: Effective Date of Agreement: Initial Term: Contract No. This Waste & Disposal Services Agreement, consisting

More information

GENERAL CABLE COMPANY LTD. TERMS AND CONDITIONS OF SALE (Canada)

GENERAL CABLE COMPANY LTD. TERMS AND CONDITIONS OF SALE (Canada) GENERAL CABLE COMPANY LTD. TERMS AND CONDITIONS OF SALE (Canada) 1. ACCEPTANCE. This is an offer for General Cable Company Ltd. ( Seller ) to sell the product(s) ( Goods ) offered by it to the party to

More information

Please Refer to Attached Sample Form

Please Refer to Attached Sample Form Pacific Gas and Electric Company San Francisco, California U 39 Revised Cal. P.U.C. Sheet No. 33014-E Cancelling Original Cal. P.U.C. Sheet No. 20623-E Electric Sample Agreement for Customers Taking Service

More information

AGREEMENT FOR INTERCONNECTION AND PARALLEL OPERATION OF DISTRIBUTED GENERATION

AGREEMENT FOR INTERCONNECTION AND PARALLEL OPERATION OF DISTRIBUTED GENERATION AGREEMENT FOR INTERCONNECTION AND PARALLEL OPERATION OF DISTRIBUTED GENERATION This Interconnection Agreement ( Agreement ) is made and entered into this day of,, by Sharyland Utilities, L.P. McAllen (

More information

NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT VoIP Contract Number: 44552-IPTEL1519

NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT VoIP Contract Number: 44552-IPTEL1519 NORTHEAST OHIO NETWORK FOR EDUCATIONAL TECHNOLOGY SERVICE PROVIDER CONTRACT VoIP Contract Number: 44552-IPTEL1519 This agreement for the provision of IP Telephony service ("Agreement") is entered between

More information

MASTER ROAD REPAIR AGREEMENT STATE OF TEXAS KNOW ALL MEN BY THESE PRESENTS: COUNTY OF HOOD

MASTER ROAD REPAIR AGREEMENT STATE OF TEXAS KNOW ALL MEN BY THESE PRESENTS: COUNTY OF HOOD SUP-20 - Date or PL-20 - Date GW-20 - Date MASTER ROAD REPAIR AGREEMENT STATE OF TEXAS KNOW ALL MEN BY THESE PRESENTS: COUNTY OF HOOD This Road Repair Agreement, ( Agreement ), is made and entered into

More information

(c) Support Response Time Target 30 minute Support Response Time Target for Emergency Incidents; and

(c) Support Response Time Target 30 minute Support Response Time Target for Emergency Incidents; and Service Level Terms Service Level Agreement Public IaaS Service Level Terms This document (the Public IaaS Service Level Terms ) describes the Service Levels and Service Level Credits applicable to Cisco

More information

(insert name and address)

(insert name and address) Lease Agreement for Plant and Machinery LESSOR; LESSEE; DATE: (insert name and address) (insert name and address) 1. LEASE: The lessor hereby agrees to lease to Lessee and the Lessee hereby agrees to take

More information

Universal Commodity Services, Inc. Sale Order Terms and Conditions

Universal Commodity Services, Inc. Sale Order Terms and Conditions Universal Commodity Services, Inc. Sale Order Terms and Conditions The Sale Order Form, these Sale Order Terms and Conditions, and any attachments hereto (collectively, the Sale Order ) are the exclusive

More information

Instructions for Requesting a Custodial Letter of Credit

Instructions for Requesting a Custodial Letter of Credit Instructions for Requesting a Custodial Letter of Credit The forms in this document may be printed and completed, or you may complete them in Adobe Acrobat Reader: Select the hand tool. Position the pointer

More information

System Implementation Agreement. Between Scott County Emergency Communications Center, and CONTRACTOR WITNESSETH:

System Implementation Agreement. Between Scott County Emergency Communications Center, and CONTRACTOR WITNESSETH: Request for Proposals # SECC0209-1 Page 1 of 44 Between Scott County Emergency Communications Center, and CONTRACTOR WITNESSETH: This Agreement, (hereinafter referred to as the Agreement ) is made and

More information

CHEAP RATES NO WAITS LOAN PROMOTION OFFICIAL RULES

CHEAP RATES NO WAITS LOAN PROMOTION OFFICIAL RULES CHEAP RATES NO WAITS LOAN PROMOTION OFFICIAL RULES 1. Eligibility: The loan promotion is open to adults, aged 18 years or older as of September 6, 2014; and who live, work, worship or attend school in

More information

Purchasing Terms and Conditions

Purchasing Terms and Conditions Purchasing Terms and Conditions ( Terms and Conditions ) Wincor Nixdorf Pte Ltd 1 Purchase Order and Acknowledgement of Order 1.1 These Terms and Conditions shall apply to all orders and/or agreements

More information

LEASE. The term of this Lease is for a period of months, commencing on day of,, and terminating on the day of,.

LEASE. The term of this Lease is for a period of months, commencing on day of,, and terminating on the day of,. LEASE PARTIES The parties to this lease (Lease) are the state of North Dakota, acting through its (STATE), and having its principal place of business at (LANDLORD); SCOPE OF LEASE LANDLORD, in consideration

More information

C O N T R A C T N o. F M V I D 2015/106. ACL Desktop

C O N T R A C T N o. F M V I D 2015/106. ACL Desktop Annex 4 To the Regulations of the Procurement Provision of Maintenance Service for the Computerised Accounting Audit Software ACL Desktop, procurement identification No. FM VID 2015/2016, organised by

More information

AfDB New Procurement Policy: Training Program for the Bank s Procurement Staff. Risk Allocation in Construction Contracts

AfDB New Procurement Policy: Training Program for the Bank s Procurement Staff. Risk Allocation in Construction Contracts 11 AfDB New Procurement Policy: Training Program for the Bank s Procurement Staff Risk Allocation in Construction Contracts Risks 2 In the absence of a contract, all risks are the owner's Contracting is

More information

GENERAL TERMS AND CONDITIONS OF SALE OF DSM

GENERAL TERMS AND CONDITIONS OF SALE OF DSM 1. GENERAL 1.1 These General Terms and Conditions of Sale ( Conditions ) govern the offering, sale and delivery of all goods and/or services (the goods and services herein both separately and jointly referred

More information

WEBSITE DEVELOPMENT STANDARD TERMS AND CONDITIONS

WEBSITE DEVELOPMENT STANDARD TERMS AND CONDITIONS WEBSITE DEVELOPMENT STANDARD TERMS AND CONDITIONS A. Client commitment: Client agrees to allocate time and process information, as needed, during the duration of the project. Client agrees to review the

More information

BUYING AGENCY AGREEMENT

BUYING AGENCY AGREEMENT THIS AGREEMENT ( Agreement ) is made this day of, 20xx, by and between, with its principal place of business at referred to hereinafter as Buyer, and, with its principal office at, hereinafter referred

More information

CONTRACT AGREEMENT FOR PROVISION OF SECURITY SERVICES BETWEEN

CONTRACT AGREEMENT FOR PROVISION OF SECURITY SERVICES BETWEEN CONTRACT AGREEMENT FOR PROVISION OF SECURITY SERVICES BETWEEN. AND ADVANCED SECURITY COMPANY LTD P.O BOX 5820 DAR ES SALAAM-TANZANIA Landline No: +255 22 2774258 Fax. +255 22 2773541 E-Mail: info@advancedsecurity.co.tz

More information

ADAPT LASER SYSTEMS LLC GENERAL TERMS AND CONDITIONS OF RENTAL AGREEMENT

ADAPT LASER SYSTEMS LLC GENERAL TERMS AND CONDITIONS OF RENTAL AGREEMENT ADAPT LASER SYSTEMS LLC GENERAL TERMS AND CONDITIONS OF RENTAL AGREEMENT 1. General. Capitalized terms are defined below. Unless other terms are specified in the Rental Agreement (attached hereto and incorporated

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS PLYMOUTH-CANTON COMMUNITY SCHOOLS REQUEST FOR PROPOSALS Assignment of Rights to Wireless Telecommunication Lease, Tower and/or Tower Management Agreement Plymouth-Canton Community Schools E.J. McClendon

More information

Scheduling Best Practices

Scheduling Best Practices The eighth article in the Scheduling Best Practices series is How to Handle the Weather. Our colleague Beth Blair, a managing consultant in Warner s Disputes Resolution Group, has over 20 years of experience

More information

PDQ Workholding LLC Terms and Conditions of Sale

PDQ Workholding LLC Terms and Conditions of Sale PDQ Workholding LLC Terms and Conditions of Sale Unless otherwise specifically stated in the offer to sell goods submitted herewith ( Sales Quotation ), these Terms and Conditions establish the rights,

More information

CITY OF NEWPORT, OREGON PERSONAL SERVICES CONTRACT

CITY OF NEWPORT, OREGON PERSONAL SERVICES CONTRACT CITY OF NEWPORT, OREGON PERSONAL SERVICES CONTRACT THIS AGREEMENT is between the City of Newport, an Oregon municipal corporation (City), and Associated Cleaning Service, Inc. (Contractor). This agreement

More information

Negotiating Commercial Leases

Negotiating Commercial Leases Negotiating Commercial Leases by Dean P. Cazenave and Brett N. Brinson Kean Miller Hawthorne D Armond McCowan & Jarman, L.L.P. P. O. Box 3513 Baton Rouge, LA 70821-3513 (225) 387-0999 Introduction Like

More information

TERMS AND CONDITIONS

TERMS AND CONDITIONS TERMS AND CONDITIONS ACCEPTANCE OF ANY PURCHASE ORDER FROM A CUSTOMER FOR USE OF ANY EQUIPMENT AND SOFTWARE PROVIDED BY RX MONITORING SYSTEMS INC. ( RXMS ) IS CONDITIONED UPON THESE TERMS AND CONDITIONS.

More information

CSA CONSTRUCTION, INC. 2314 McAllister Road Houston, Texas 77092 SUBCONTRACTOR AGREEMENT

CSA CONSTRUCTION, INC. 2314 McAllister Road Houston, Texas 77092 SUBCONTRACTOR AGREEMENT CSA CONSTRUCTION, INC. 2314 McAllister Road Houston, Texas 77092 SUBCONTRACTOR AGREEMENT THIS AGREEMENT made this day of Month, Year, by and between CSA CONSTRUCTION, INC., a Texas corporation whose principal

More information

SITE LEASE AGREEMENT

SITE LEASE AGREEMENT Sample Site Lease Agreement for Antenna on Water tower SITE LEASE AGREEMENT THIS SITE LEASE AGREEMENT ( Lease ), made this day of, year, between City of ("Landlord"), and organization and existing under

More information

RATE 834 RATE FOR ELECTRIC SERVICE GENERAL SERVICE

RATE 834 RATE FOR ELECTRIC SERVICE GENERAL SERVICE Original Sheet No. 15 No. 1 of 6 Sheets TO WHOM AVAILABLE Available to GENERAL service Customers for electric service, who have auxiliary 60 Hertz electric generation equipment and who are located on the

More information

CLEARING MEMBERSHIP AGREEMENT

CLEARING MEMBERSHIP AGREEMENT CLEARING MEMBERSHIP AGREEMENT DATED between LCH.CLEARNET LLC and LCH.CLEARNET LIMITED 17 State Street, 28th floor, New York, NY 10004 Telephone: +1 (212) 513-8282 Website: www.lchclearnet.com In consideration

More information

Standard Terms & Conditions for Supply of Software Development Services

Standard Terms & Conditions for Supply of Software Development Services Sell your Products Online and Web by Numbers are brands of Web by Numbers Ltd (hereinafter referred to as Web by Numbers ) Standard Terms & Conditions for Supply of Software Development Services These

More information

No change, modification or revision to this PO shall be valid and binding unless in writing and signed by the authorized representative of Buyer.

No change, modification or revision to this PO shall be valid and binding unless in writing and signed by the authorized representative of Buyer. PURCHASE ORDER TERMS AND CONDITIONS 1. Agreement This Purchase Order ( PO ) is an offer to purchase by Gyrus ACMI, Inc., or its direct or indirect subsidiary identified on the front of this PO ( Buyer

More information

VOLVO CONSTRUCTION EQUIPMENT. CARETRACK LICENCE (Version 3 April 2010)

VOLVO CONSTRUCTION EQUIPMENT. CARETRACK LICENCE (Version 3 April 2010) CARETRACK LICENCE () This licence is issued by VOLVO CONSTRUCTION EQUIPMENT DIVISION, VOLVO GROUP UK LTD incorporated and registered in England and Wales with company number 2190944, whose registered office

More information

SUBSCRIBER AGREEMENT Comodo LivePCSupport

SUBSCRIBER AGREEMENT Comodo LivePCSupport SUBSCRIBER AGREEMENT Comodo LivePCSupport THIS AGREEMENT CONTAINS A BINDING ARBITRATION CLAUSE. PLEASE READ THE AGREEMENT CAREFULLY BEFORE ACCEPTING THE TERMS AND CONDITIONS. IMPORTANT PLEASE READ THESE

More information

FUNDING AGREEMENT BETWEEN CALIFORNIA HIGHWAY PATROL AND SACRAMENTO TRANSPORTATION AUTHORITY

FUNDING AGREEMENT BETWEEN CALIFORNIA HIGHWAY PATROL AND SACRAMENTO TRANSPORTATION AUTHORITY Agreement No. 2 FUNDING AGREEMENT BETWEEN CALIFORNIA HIGHWAY PATROL AND SACRAMENTO TRANSPORTATION AUTHORITY THIS AGREEMENT, is made and entered into this day of, 2010, by and between the California Highway

More information

CONTRACTS & PROCUREMENT DEPARTMENT

CONTRACTS & PROCUREMENT DEPARTMENT CONTRACTS & PROCUREMENT DEPARTMENT AGREEMENT FOR PROFESSIONAL SERVICES BETWEEN NORTH SAN DIEGO COUNTY TRANSIT DEVELOPMENT BOARD AND Contractor Name RFP # This agreement is made and entered into as of,

More information

agrees to pay for all Services performed in accordance with the SOW. In the event that Services will materially exceed the estimate in the Sales

agrees to pay for all Services performed in accordance with the SOW. In the event that Services will materially exceed the estimate in the Sales Professional Services Terms and Conditions Avid Technology, Inc. 75 Network Drive Burlington, MA 01803, USA Avid Technology International B.V. Carmanhall Road Sandyford Industrial Estate Dublin 18, Ireland

More information