DATED..DAY OF..201 KIKAMBALA HOUSING ESTATE LIMITED
|
|
- Melvin Parks
- 7 years ago
- Views:
Transcription
1 DATED..DAY OF..201 AGREEMENT FOR SALE KIKAMBALA HOUSING ESTATE LIMITED AND.. HOUSE NO :. KIKAMBALA HOUSING ESTATE TITLE NUMBER KILIFI / MTWAPA /867 Drawn by: Nabhan Swaleh Advocate Corporate Insurance House 1 st Floor Mvita Road Mombasa Kenya
2 This agreement is made the day of.201 Between : (1) Kikambala housing Estate limited P.O. box : Mombasa (hereinafter called Vendor which expression shall where the context so permits include its successors in title and assigns ) of the one part; AND (2).. P.O. box :.- Id. / passport number / pin number././ (hereinafter called The Purchaser which expression shall where the context so permits include his personal representatives and assigns ) of the other part. WHEREAS: A. The vendor is registered as proprietor of the property known as Kilifi/Mtwapa/867 ( hereinafter referred to as The Property ) B. The vendor is obtained planning permission to construct on the property and is in the process of constructing on the property the Development. C. The purchaser aware and accepts that the Development is under construction and not complete and notwithstanding the purchaser has agreed to purchase house (hereinafter defined) D. The vendor has granted or intends to grant leases of other houses in the development other than the House hereby agreed to be sold to the purchaser. E. In consideration of purchase price to be paid by the purchaser to the vendor in the manner set out in this agreement, the vendor has agreed to sell to the purchaser the house on the terms, conditions covenant and stipulations set out herein.
3 IT IS HEREBY AGREED as follows: 1. DEFINITIONS: House means the House number /.. on Kilifi / Mtwapa/ 867 and shall have the same meaning as defined in the lease. Development means 308 houses comprising of 84 type A houses, 82 type B houses, 62 C houses, 80 D houses together with ancillary facilities as swimming pool, shopping mall, dispensary and kinder garden the common parts and all other improvements or at any time during the term erected and constructed on the property. Board Board of director of the Management Company; Buildings Means the buildings and improvements constructed and erected by the vendor on the land in accordance with the building Plans; Buildings Plans means the building plans. Completion date when the vendor s Architects issues a certificate of practical completion, which ever will be change house to house and will be mentioned in the each contract; Date of Handover means immediately the full payment of the purchase price is effected or after registration of lease whichever is earlier. Disbursement Means the cost and expenses listed in the Schedule of this agreement to be paid by purchaser; Land the vendor is registered proprietor of ALL THAT piece or parcel of land situated in Mtwapa and as more particularly known as title
4 number KILIFI / MTWAPA / 867 measuring approximately 6.5 of a hectare or thereabouts (together with the building and improvements erected thereon ) ( hereinafter referred the Property ). Lease means the lease to be granted by the vendor to the purchaser for nine hundred and ninety nine (999) years from completion at the annual rent of a peppercorn (if demanded), plus the payment of the service Charge ( as defined in the lease ) Purchase price means the sum of Kenya Shillings one million eight hundred thousand ( 1,800,000/=); Vendor s Advocates Means Nabhan Swaleh Advocates, Corporate Insurance House 1 st Floor, Mvita Road, Off treasury Square road, Po box , Mombasa Purchaser s Advocates Means Nabhan Swaleh Advocates, Corporate Insurance House 1st Floor, Mvita Road, Off treasury Square road, Po box , Mombasa 1.2 All references in this agreement to a statutory provision shall be constructed as including references to All statutory instruments or orders made pursuant to a statutory provision and Any statutory provisions of which a statutory provision is a consolidation, re-enactment or modification. 1.3 Clause headings in this agreement are for ease of reference only and do not affect the construction of any provision herein.
5 2. PURCHASE PRICE 2.1 The purchase price shall be paid by the purchaser as follows: Kenya Shillings three hundred thousand (Kshs. 300,000/=) shall be paid on or before the execution of this Agreement. ( receipt whereof is hereby acknowledged) Balance The balance of the purchase price being the sum of Kenya Shillings one million five hundred thousand/=(kshs. 1,500,000/=) shall be paid to the Vendor s advocates by three equal monthly installments of Kenya Shillings five hundred thousand (Kshs. 500,000/=) starting on the and thereafter on the 30 th day of each succeeding month until payment in full In the event the purchaser shall seek financing, from the vendor ; Kenya Shillings five hundred thousand (Kshs. 500,000/=) shall be paid on or before the execution of this Agreement. (receipt whereof is hereby acknowledged) Balance- The balance will be paid Kenya shillings twenty five thousand ( Kshs. 25,000/=) every month during 90 months. All purchasers has to give a postdated cheques for the balance payments. 2.2 In the event that any moneys due as part of the purchase Price hereinabove reserved remains unpaid by the purchaser seven (7) days after the due date for payment of the same interest shall begin to accrue on such due amount at the rate of 3% per month from the due date until payment in full both days inclusive. 2.3 The vendor is hereby authorized to utilize the payments received in the completion of the development.
6 2.4 The purchaser understands that some aspects of the infrastructure for the overall project will be completed at the end of the practical completion. 3. SALE OF HOUSE: 3.1 The interest sold in the house is leasehold; 3.2 The sale of the house is subject to the Law Society Conditions of sale (1989 Edition) in so far as they are not inconsistent hereof; 3.3 The said house is sold with vacant possession on completion; and 3.4 The purchaser shall not be entitled to vacant possession of the House until he/she has paid the purchase price and all other outgoings including interest (if any) together with the costs as set out in Special Condition 1 below and schedule hereto having been paid in full by the purchaser or after the completion of the registration of the lease. 3.5 The House is sold subject to: The covenants, terms, conditions, stipulations, restrictions and rights as provided and reserved in the lease; All subsisting easements, quasi-easements and rights of way (if any); and Any provisional liability or assessment for road or sewerage charges. BUT Otherwise free from encumbrances. 3.6 The sale includes no movables.
7 3.7 The purchaser agrees and confirms that (save for the provision of clause 2.3 hereof ) Has inspected the sample house and plans of the Premises and purchases the Premises with full knowledge of its actual size and shall take the house as it appears on the plan; Has entered into this agreement solely as a result of his own survey and inspection as aforesaid and on the basis of the terms of this agreement and not in reliance upon any warranty representation or confirmation either written or oral or implied or made by or on behalf of the vendor Each of the parties hereby agrees confirms for the purposes of the Law of Contract Act ( Chapter 23, Laws of Kenya) that he or she ( as the case maybe ) has executed this agreement with the intention to bind himself or herself (as the case maybe) to the contents hereof This agreement constitutes the whole and any agreement between the parties hereto relating to the lease of the Premises and supersedes and extinguishing any prior agreements, undertakings, representations, warranties and arrangements of any nature whatsoever whether or not in writing relating to the lease of the Premises. 4. GRANT OF LEASE 4.1 The transfer of the house shall be by way of the grant of the lease from the vendor to the purchaser in consideration of the payment of the Purchase Price in full as provided herein.
8 4.2 The stamping and registration of the Lease and any discharge thereof shall be conducted by the Vendor s Advocates but at the Purchaser s cost and such stamping and registration shall only take place after the Purchaser has made all the payments required for purpose of stamping and registration of the Lease as provided for in clause 2 of the special conditions herein. 5. DEVELOPMENT BY VENDOR 5.1 The vendor will undertake the developments and constructions of the 308 Houses as more particularly detailed in the plans available at the site office at the development available for inspection by the Purchaser and the purchaser shall be deemed to have approved and accepted the same prior to the execution of this agreement. The vendor hereby covenants and undertakes to complete the works and finishes on the said House in accordance with good workmanship; and 5.2 The vendor shall not be liable for any damages, loss, costs or expenses, whatsoever or howsoever incurred or suffered by the Purchaser by reason of any defects or other faults which shall appear or occur in the house after six (6) months from the date of the Purchaser taking possession notwithstanding that the house and the buildings in the development are newly built by the vendor. Any defects or defaults arising and which have been notified in writing to the vendor within the period aforesaid shall be rectified by the vendor at no cost to the purchaser save if such defect or defaults is caused by any act or omission of the Purchaser. It is hereby agreed and understood that if the vendor shall not have, completed the rectification of the said defects or faults to the reasonable satisfaction of the Vendor s
9 architects within a reasonable time after receiving a schedule of defects certified by the said architect and delivered to the vendor then the purchaser shall be at liberty to rectify the defects himself using services of workman approved by the vendor, and vendor shall forthwith on demand reimburse to the purchaser all cost of rectifying aforesaid defects or faults. 6. MANAGEMENT COMPANY 6.1 The development shall be managed accordance with the rules and antmemorandum and articles of association of the management company. 6.2 The purchaser shall be entitled to shares pro-rata to the number of units purchased in the Management company upon registration of the lease in favor of the purchaser. 6.3 In the event the purchaser shall be more than one person, then the purchaser shall be entitled to nominate one of them to be appointed a director of the Management Company. 6.4 The purchaser hereby undertakes and covenants that in the event that the Purchaser shall hereafter sell the house such sale shall always be subject to the purchaser also transferring the Purchaser s shares in the Management Company to the new purchaser of the house. 7. RERVERSIONARY INTEREST 7.1 The parties agree that the vendor will sell and transfer the reversion expectant upon and the land to the management company for the sum of Kenya Shillings three hundred thousand ( Kshs.
10 300,000/=) with in ninty (90) days of the last leases being registered to the respective purchaser of the houses in the development. 7.2 The vendor hereby covenants with the purchaser that it shall do all things required and necessary to insure the reversionary interest in transferred to the Management Company within the said period subject to payment by the purchaser of his or her proportionate share of the cost and expenses thereof. 8. SERVICE CHARGE The purchaser hereby undertakes to be paying periodical service charges in respect of the House to the management company as will be determined by the Management Company time to time. The purchaser shall also before taking possessions of the House pay to the vendor and/or management company a sum of Kenya Shillings twelve thousands (Kshs. 12,000/=) to be held by the vendor and/ or Management Company to the credit of the purchaser on account of the said service charges. 9. ENTIRE UNDERSTANDING 9.1 This agreement embodies the entire understanding of the parties and there are no other agreements between the parties relating to the subject matter of this agreement. 9.2 No amendments or modification of this agreement shall be valid or binding on any party unless the same: a. is made in writing; b. refers expressly to this agreement; and
11 c. is signed by the party concerned or its or his duly authorize representatives 9.3 Upon registration of the lease if there shall be any inconsistency between the provisions of this agreement and the provisions of the lease, provisions of the lease shall prevail. 10. EXECUTORY AGREEMENT 10.1 This agreement is an executory agreement only and shall not operate nor be deemed to operate as a lease of the premises Purchaser shall not be entitled to occupation or possession of the premises until the entire purchase price has been paid lease registered. SPECIAL CONDITIONS 1. The purchaser shall execute the lease for the house and shall pay all costs related to the completion of the valuation for the house by the government Chief land valuer and the disbursements contained in the schedule hereto within seven (7) days of the Vendor s Advocates being ready to proceed with registration and the vendor s Advocates shall thereafter arrange for the stamping and registration of the same at the Lands office in accordance with the provisions herein. 2. The purchaser shall bear the following costs; a. Copying and binding charges; b. Postage and incidentals; c. 12% d. Provisional stamp duty on the lease; e. Registration fees f. Legal Fees for drawing and registering the lease
12 g. Purchaser s costs and/or Proportionate share of the cost for - Incorporation of the Management Company - Purchase of the Reversionary Interest - Deposit of the service charge - Deposit for water & electricity 3. Rents, rates and outgoing shall be apportioned as between the parties from the date of execution of the lease. 4. If for any cause whatsoever other than non-completion caused by the default of the Vendor the transaction shall not complete on the completion date: 4.1. The vendor shall be entitled to serve Notice in writing upon the purchaser to complete this transaction within twenty one (21) days from the date upon which such notice is served on the purchaser. If the purchaser shall fail to complete this transaction before the expiry of the said notice then the vendor shall be entitled at its sole discretion either: a. To extend to time for completion; or b. To rescind this agreement upon giving seven (7) days notice in writing in that behalf to the purchaser In the event the vendor shall extend the time for payment the Purchaser shall pay the vendor interest on any moneys due under this agreement remaining unpaid at the rate specified computed from the date such payment is due until the date of payment in full both days inclusive. For the avoidance of doubt the purchaser hereby agrees that such interest shall automatically start accruing immediately at the
13 rate of 3% per month on any payment which is due and is not paid on the due date In the event the vendor shall rescind this agreement due to the default of the Purchaser as aforesaid then 10% of the purchase price shall be forfeited by the purchaser to the vendor as agreed liquidated damages and the other payments (if any) paid by the purchaser to the vendor less a further amount Kenya Shillings Thirty Thousand (Kshs. 30,000/=) for the fees of the vendor s advocates which shall be payable by the purchaser for such failed transaction shall be returned to the purchaser without interest thereon and this agreement shall then absolutely determine. 5. In the event the vendor shall be in breach of its obligations under this agreement and the purchaser shall elect to rescind this agreement the vendor shall pay back monies received toward the purchase price including the deposit to be refunded to the purchaser within 90 days from the date of such rescission and this agreement shall henceforth become null and void and neither party shall have any further claims against the other of interest, profit, or any other compensatory head whatsoever. However, if the vendor shall delay the handover of the house on the completion date and if the purchaser shall opt to proceed with the transaction then the vendor shall pay the purchaser Kshs. 10,000 monthly being agreed liquidated damages for the delay until completion of the house. 6. The purchaser hereby acknowledges that the documents relating to this transaction prepared by the vendor s advocates are standard documents to be executed also by all purchasers of the
14 other units and purchaser accepts them as they are. The vendor confirms that such other documents relating to this transaction will not contravene the provisions of this agreement. 7. Time shall be deemed to be of the essence for all purposes of this agreement. 8. If any term or condition of this agreement shall to any extend be found or held to be invalid or enforceable, the parties shall negotiate in good faith to amend such term or condition of this agreement so as to be valid and enforceable. 9. If any term or condition of this agreement shall to any extend be invalid or unenforceable, the reminder of this agreement shall not be affected and each other term and condition shall be valid and enforceable to the fullest extend permitted by law. 10. Risk for the house shall pass to the Purchaser on the date of handover of the same to the purchaser by vendor. 11. If any dispute, difference or question shall arise whether during continuance of this agreement or upon or after its determination between parties hereto touching or concerning this agreement or as to any other matter in any way connected with or arising out of or in relation to the subject matter of this agreement such dispute, difference or question whatsoever shall be referred to an arbitrator under the rules of the arbitration act 1995 of Kenya or any statuary modification or re-enactment for the time being in force, such arbitrator to be appointed by agreement of both parties and in the absence of agreement within (14) fourteen days of the notification of the dispute by either party to the other then on the application of any one party to the Chairman of the Chartered Institute of Arbitrators (Kenya
15 Branch) he/she will appoint an arbitrator and the decision of such arbitrator shall be final and binding on the parties hereto. 12. This agreement shall be governed by the Laws of Kenya. THE SCHEDULE HEREINBEFORE REFERRED TO: The purchaser shall pay the Vendor s Advocates charges in connection with this transaction as follows, payable on the execution this agreement, The cost are as follows;- a. Incorporation Of Management Company Kshs 1,000 b. Transfer of reversionary Interest Kshs. 1,000 c. Stamp duty on agreement sale Kshs. 200 d. Legal Fees for preparing the Lease Kshs. 30,000 e. Issuance of share certificate Kshs. 2,000 f. Registration Fees and disbursement Kshs. 3,000 g. Stamp duty on lease (provisional) Kshs. %2 pct h. VAT on legal fees Kshs.. i. Water deposit Kshs. 5,000 j. Electricity deposit Kshs. 10,000 k. Service charge deposit Kshs. 12,000 IN THE WITNESS WHEREOF the parties hereto have hereunto set their respective hands the day and year first hereinbefore written: Signatures and stamps and seals..
(insert name and address)
Lease Agreement for Plant and Machinery LESSOR; LESSEE; DATE: (insert name and address) (insert name and address) 1. LEASE: The lessor hereby agrees to lease to Lessee and the Lessee hereby agrees to take
More informationCertificate of Entitlement (COE) Bidding Agreement. VENDOR S NAME (Addresses and details of Head Office and Branch Office)
Certificate of Entitlement (COE) Bidding Agreement VENDOR S NAME (Addresses and details of Head Office and Branch Office) THIS PURCHASER S REQUEST AND AUTHORISATION TO BID FOR A COE AGREEMENT ("the Agreement")
More informationSECTION 00900 PERFORMANCE BOND., hereinafter called PRINCIPAL, and
SECTION 00900 PERFORMANCE BOND KNOW ALL PERSONS BY THESE PRESENTS: THAT (Name or Contractor) a (Address of Contractor) (Corporation, Partnership, or Individual), hereinafter called PRINCIPAL, and (Name
More informationOFFER TO PURCHASE. SERVANT's ROOM
OFFER TO PURCHASE I, We, the Purchaser/s: [hereinafter referred to as the Purchaser] Address: HEREBY OFFER TO PURCHASE FROM: The Seller/s: [hereinafter referred to as the Seller] THE PROPERTY WHICH IS
More informationThe Vendor as described in Section 2 of the First Schedule herein; and The Purchaser as described in Section 2 of the First Schedule herein.
Page 1 Sale and Purchase Agreement Sample THIS AGREEMENT is made the day and year set out in Section 1 of the First Schedule hereto BETWEEN : The Vendor as described in Section 2 of the First Schedule
More informationDEED OF PRIORITIES. regulating priorities between two Debentures, to be used with factors/invoice discounters
When this form has been completed and signed by the Customer and the Alternate Lender, send it to the Customer s Relationship Manager together with the completed Authority to contact form DEED OF PRIORITIES
More informationBUY-SELL AGREEMENT. AGREEMENT, made this _(1)_ day of (2), 19_(3)_, by and between. (4), (5), (6), hereinafter separately referred to as
BUY-SELL AGREEMENT The sample buy-sell agreement below is for information purposes only. Neither MEG Financial, Inc. nor any of its representatives offers legal or tax advice. Please consult your tax and
More informationEscrow Agreement INSTRUCTIONS STOCKHOLM CHAMBER OF COMMERCE ESCROW MODEL AGREEMENT 2014
SCC Escrow Account No... (For SCC to fill in) Escrow Agreement INSTRUCTIONS STOCKHOLM CHAMBER OF COMMERCE ESCROW MODEL AGREEMENT 2014 This is a model agreement, which means that the parties should adapt
More informationMASTER EQUIPMENT LEASE AGREEMENT
MASTER EQUIPMENT LEASE AGREEMENT THIS LEASE AGREEMENT is made this.. day of 20 BETWEEN 1) Messrs....a limited liability company incorporated in the Republic of Kenya and Post Office Number in the said
More informationBUY-SELL AGREEMENT. WHEREAS, the Stockholders together own 100% of the outstanding shares of capital stock of the Corporation, and
BUY-SELL AGREEMENT AGREEMENT, made this (1) day of (2), (3), by and between (4), (5), (6), hereinafter separately referred to as "Stockholder", and jointly as "Stockholders", and (7), a (8) corporation,
More informationAL RAJHI SAVINGS ACCOUNT-i AGREEMENT - QARD
Original Bank Copy Duplicate Customer Copy BETWEEN AL RAJHI BANKING & INVESTMENT CORPORATION (MALAYSIA) BHD (719057-X) AND CUSTOMER S NAME: REGISTRATION NO./NRIC NO./PASSPORT NO.: DATE: 1 DATE: BETWEEN
More informationAGREEMENT OF PURCHASE AND SALE
AGREEMENT OF PURCHASE AND SALE This Agreement of Purchase and sale ( Agreement Buyer Agency Agreement ( Agreement ), dated as of,is made by and between: ( Buyer or Lessee ), whose address is, telephone
More informationAGREEMENT OF PURCHASE AND SALE *
AGREEMENT OF PURCHASE AND SALE * This Agreement dated this day of, 20. A. PARTIES PURCHASER(S): agrees to purchase from (full legal names of all Purchasers) VENDOR(S): the following: (full legal names
More informationSAMPLE ESCROW AGREEMENT APPLICATION SOFTWARE SOURCES CODE
Attachment F SAMPLE ESCROW AGREEMENT APPLICATION SOFTWARE SOURCES CODE This AGREEMENT between. (hereinafter ) located at, (hereinafter Escrow Agent ) whose main office is located at,, and,, (hereinafter
More informationSample. Rider Clauses to Contract of Sale Purchaser DEED DESCRIPTION DOWN PAYMENT ESCROW
Rider Clauses to Contract of Sale Purchaser DEED DESCRIPTION 1. The deed shall contain a metes and bounds description of the premises being conveyed thereby. The same shall be satisfactory to the title
More informationCONTRACT FOR SALE AND PURCHASE OF ASSET BETWEEN. PETRONAS Chemical Derivatives Sdn Bhd ( COMPANY ) AND BUYER
CONTRACT FOR SALE AND PURCHASE OF ASSET BETWEEN PETRONAS Chemical Derivatives Sdn Bhd ( COMPANY ) AND BUYER This CONTRACT FOR THE SALE AND PURCHASE OF ASSET (hereinafter referred to as Contract ) is made
More informationLAND CONTRACT. Parties. 1. THE SELLER AGREES AS FOLLOWS: (a) To sell and convey to the Purchaser the following described property:
LAND CONTRACT (WITH ALTERNATE TAX AND INSURANCE PROVISIONS) Parties Description Of Premises This Contract, made this day of, between, hereinafter referred to as the Seller, whose address is and, hereinafter
More informationRULES OF THE TENDER PROCESS
SALE OF LAND REFERENCE NUMBER 209/2683 NAIROBI RULES OF THE TENDER PROCESS N A M E A N D A D D R E S S O F T H E VEND O R The Embassy of the Republic of Poland in Kenya 58 Red Hill Road, off Limuru Road
More informationSTANDARD SUBLEASE AGREEMENT
STANDARD SUBLEASE AGREEMENT 1. Parties. This Sublease, dated, for reference purposes only, 20 is made by and between (herein called Sublessor ) and (herein called Sublessee ). 2. Premises. Sublessor hereby
More informationIRREVOCABLE LETTER OF CREDIT REIMBURSEMENT AGREEMENT
4/1/2015 IRREVOCABLE LETTER OF CREDIT REIMBURSEMENT AGREEMENT THIS AGREEMENT, dated as of, is between, an institution organized and existing under the laws of having its principal office at (the Customer
More informationTrading, Collaterised Accounts Terms & Conditions
Trading, Collaterised Accounts Terms & Conditions CB/ST/V1/2012 1. PURPOSE 1.1 You (i.e. the Applicant) shall use the Collaterised Trading Facility ( the Facility ) only to deal in securities ( Securities
More informationBUILDING CONTRACT MEMORANDUM OF AGREEMENT AND CONDITIONS OF CONTRACT
BUILDING CONTRACT MEMORANDUM OF AGREEMENT AND CONDITIONS OF CONTRACT MADE and entered into by and between: (hereinafter referred to as the OWNER); and (hereinafter referred to as the BUILDER) WHEREAS the
More informationMODEL TRIPARTITE AGREEMENT (FOR ROAD PROJECTS) BETWEEN PROJECT AUTHORITY, CONCESSIONAIRE AND INFRASTRUCTURE DEBT FUND
MODEL TRIPARTITE AGREEMENT (FOR ROAD PROJECTS) BETWEEN PROJECT AUTHORITY, CONCESSIONAIRE AND INFRASTRUCTURE DEBT FUND This Tripartite Agreement 1 is made at [New Delhi] on the ***** 2 day of *****, 201*
More informationSTANDARD LAND PURCHASE AND SALE AGREEMENT [#505] (With Contingencies)
STANDARD LAND PURCHASE AND SALE AGREEMENT [#505] (With Contingencies) The parties make this Agreement this day of,. This Agreement supersedes and replaces all obligations made in any prior Contract To
More informationHow To License A Patent From Ancient Recipe Cards
Option Agreement This Option Agreement (the "AGREEMENT") is made and entered into by and between EMORY UNIVERSITY, a nonprofit Georgia corporation with offices located at 1599 Clifton Road NE, 4 th Floor,
More informationBOOKING AGENT AGREEMENT AMERICAN FEDERATION OF MUSICIANS
BOOKING AGENT AGREEMENT AMERICAN FEDERATION OF MUSICIANS Agreement No. 1 AMERICAN FEDERATION OF MUSICIANS BOOKING AGENT AGREEMENT (A) Purpose: The American Federation of Musicians, hereinafter called Federation,
More informationMINNESOTA COMMERCIAL LEASE AGREEMENT. This lease is made between, herein called Lessor, and
MINNESOTA COMMERCIAL LEASE AGREEMENT This lease is made between, herein called Lessor, and, herein called Lessee, agree upon the following TERMS and CONDITIONS: 1) Property: Lessee hereby offers to lease
More informationMORTGAGE BROKER AGREEMENT
MORTGAGE BROKER AGREEMENT This Mortgage Broker Agreement (the "Agreement") is entered into by and between: ST. CLOUD MORTGAGE, a California Corporation (the "Lender"), and (the "Mortgage Broker") as of
More informationMODULAR HOME PURCHASE & CONSTRUCTION AGREEMENT
This document has been prepared as an aid to retailers selling a modular home for placement on the customer s land. We would like to remind you this is a general form and will need to be amended to fit
More informationTHE CORPORATION OF THE CITY OF BURLINGTON D1 - AGREEMENT
Agreement 2006 Page 1 THE CORPORATION OF THE CITY OF BURLINGTON D1 - AGREEMENT THIS AGREEMENT made in triplicate this day of 20 THE CORPORATION OF THE CITY OF BURLINGTON (hereinafter called "the City")
More informationIf you are in full agreement with the document, kindly return the signature page at the end of the documents
Introducing Broker Agreement If you are in full agreement with the document, kindly return the signature page at the end of the documents Brokersclub Limited is a limited liability company registered in
More informationOPTION AND LITERARY PURCHASE AGREEMENT
[There are many types of film and television option agreements, from one-page letters to multi-page documents complete with copyright assignment forms. Ideally, an option agreement should include two separate
More informationCONSTRUCTION AND PURCHASE CONTRACT (Fixed Price - Builder-owned Lot)
Home Builders Association of HBA Phone Contract No. CONSTRUCTION AND PURCHASE CONTRACT (Fixed Price - Builder-owned Lot) THIS CONTRACT, dated, 20, between (referred to as "Builder") and (referred to as
More informationTHE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE
THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE WHEREAS The Sustainable Energy Authority of Ireland (hereinafter called SEAI ) of Wilton Park House, Wilton Place,
More information(House and Land) Approved by the Nova Scotia Real Estate Commission for use by Industry Members under the Real Estate Trading Act.
AGREEMENT OF PURCHASE & SALE FOR TURN KEY NEW CONSTRUCTION (House and Land) Approved by the Nova Scotia Real Estate Commission for use by Industry Members under the Real Estate Trading Act The Buyer of
More informationSCHEDULE 14. Part 1 Performance Bond PERFORMANCE BOND NO.
SCHEDULE 14 BONDS Part 1 Performance Bond PERFORMANCE BOND NO. $ KNOW ALL PERSONS BY THESE PRESENTS, that Contractor s Name as Principal ( the Principal ) and Surety / Insurance Company name and address,
More informationUNITED BANK OF INDIA Head Office: Kolkata
UNITED BANK OF INDIA Head Office: Kolkata AGREEMENT FOR TERM LOAN AGAINST FUTURE RENT RECEIVABLES THIS AGREEMENT FOR TERM LOAN AGAINST FUTURE RENT RECEIVABLES is made this... Day of... two thousand...
More informationTT ELECTRONICS INTEGRATED MANUFACTURING SERVICES LIMITED CONDITIONS OF PURCHASE
TT ELECTRONICS INTEGRATED MANUFACTURING SERVICES LIMITED CONDITIONS OF PURCHASE DEFINITIONS In these conditions of purchase: the Buyer means TT electronics integrated manufacturing services Ltd., the Supplier
More informationPROPERTY MANAGEMENT AGREEMENT
Delaney Properties Ltd. 3107 29th Avenue Vernon, BC. V1T 1Z2 Bus: (250)550-2120 Fax: (250)549-2106 rentalsvernon@gmail.com PROPERTY MANAGEMENT AGREEMENT THIS AGREEMENT made this day of by and between Delaney
More informationBROKERAGE AGREEMENT. WHEREAS Broker wishes to gain access to and offer Paragon s specialized insurance products and services to its clients; and
BROKERAGE AGREEMENT This Agreement, effective 2014 is between Paragon Insurance Holdings, LLC ( Paragon ), 45 Nod Road, Avon, Connecticut 06001 with underwriting office at 850 Fulton Street, Farmingdale,
More informationAs used herein, capitalized terms have the following respective meanings:
RECEIVABU~S PURCHASE AND SALE AGREEMENT THIS AGREEMENT ("Agreement") is made as of August 22,2013, by NAME OF BUYER, ("Seller") and NAME OF SELLER ("Purchaser"). WHEREAS, Seller desires to sell certain
More informationLIBERTY REALTY L.L.C. BROKER-SALESPERSON INDEPENDENT CONTRACTOR AGREEMENT
LIBERTY REALTY L.L.C. BROKER-SALESPERSON INDEPENDENT CONTRACTOR AGREEMENT THIS AGREEMENT, is made and entered this day of by and between Liberty Realty, L.L.C., a New Jersey limited liability company with
More informationBelow is an overview of the Molex lease process as it applies to Molex Application Tooling equipment.
Dear Valued Customer, Below is an overview of the Molex lease process as it applies to Molex Application Tooling equipment. Lease process: Molex does not offer leases for all of the equipment that we promote.
More informationCORD BLOOD FINANCIAL AND STORAGE AGREEMENT
CORD BLOOD FINANCIAL AND STORAGE AGREEMENT THIS CORD BLOOD FINANCIAL AND STORAGE AGREEMENT ( Agreement ) is made and entered into as of the Effective Date, by and between M.A.Z.E. Cord Blood Laboratories,
More informationREAL ESTATE PURCHASE CONTRACT. OFFER TO PURCHASE the property municipally known as, Plan, Block, Lot, subject to the reservations and exceptions
REAL ESTATE PURCHASE CONTRACT (hereinafter referred to as "the Purchaser") HEREBY OFFER TO PURCHASE the property municipally known as,, Alberta (hereinafter referred to as "the Property") and legally described
More informationTHESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL ADVICE.
DISCLAIMER The forms provided on our site were drafted by lawyers with knowledge of equine and contractual matters. However, the forms are not State specific. THESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL
More informationLOAN AGREEMENT. (The City of Elk Grove Small Business Loan Program)
LOAN AGREEMENT (The City of Elk Grove Small Business Loan Program) THIS LOAN AGREEMENT (the "Loan Agreement") is made and entered into as of [date], by and between The City of Elk Grove, a California municipal
More informationPERFORMANCE BOND. That we, (operator name as established by Office of Conservation and address) (hereinafter called the Principal ), and
(Multiple Wells) Bond No. PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, (operator name as established by Office of Conservation and address) (hereinafter called the Principal ), and (bonding
More informationINDEPENDENT VIRTUAL ASSISTANT AGREEMENT (Company)
INDEPENDENT VIRTUAL ASSISTANT AGREEMENT (Company) This Independent Virtual Assistant Agreement ( Agreement ) is entered into as of,, by and between, with a principal place of business at ( Company ), and,
More informationInsurance Producer Agreement
Insurance Producer Agreement Section 1 - Producer s Authority The Producer shall periodically submit risks to the Company for its consideration as authorized by the Company. These risks shall be located
More information9. Unforeseen Delay 9.1 neither party shall be responsible for any losses resulting in the fulfilment of any of the terms of the
STANDARD TERMS AND CONDITIONS OF BUSINESS 1. Definitions 1.1 In the context of these standard terms and conditions of business:- 1.1.1 'the seller' means Entwistle and Joynt Limited of 62 Darlington Street
More informationLTC ELITE, LLC MEMBERSHIP AGREEMENT
LTC ELITE, LLC MEMBERSHIP AGREEMENT This Membership Agreement (this Agreement ) is made and entered into effective, (the Effective Date ), by and between LTC Elite, LLC, a Texas limited liability company
More informationAUCTION REAL ESTATE SALES CONTRACT
AUCTION REAL ESTATE SALES CONTRACT THIS AUCTION REAL ESTATE SALES CONTRACT (this "Contract"), by and between ("Seller") whose address is, and ("Buyer"), whose address is. The "Effective Date" of this Contact
More informationSALES PARTNER AGREEMENT
SALES PARTNER AGREEMENT This Agreement is made this day of, 200_ between ACOM SOLUTIONS, INC. ( ACOM ) having offices at 2850 East 29th Street, Long Beach, California 90806-2313 and (Partner) having offices
More informationCONSULTING SERVICES AGREEMENT
CONSULTING SERVICES AGREEMENT THIS AGREEMENT ("Agreement") is entered into on / /, between SCWOA ("Consultant"), a CA corporation with its principal place of business located at PO Box 1195, Pacifica,
More informationBUILDING AGREEMENT. between: ( the Owner ) and. ( the Builder )
BUILDING AGREEMENT between:. ( the Owner ) and. ( the Builder ) Of INTRODUCTION 1. The Owner is desirous of making alterations and additions ( the Works ) to the buildings situated on certain land being
More informationContract for Capital Purchase N [reference of the COMPANY]
Contract for Capital Purchase N [reference of the COMPANY] Between [ ].... represented by the duly authorized persons designated on the signature page of the present CONTRACT, hereinafter referred to in
More informationBID BOND CITY OF EAST POINT, GEORGIA
BID BOND CITY OF EAST POINT, GEORGIA BIDDER (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (hereinafter referred to as the City (Name and Address): City of East Point
More informationSURETY BOND - SAMPLE FORM
FORM-SI-BOND SURETY BOND - SAMPLE FORM OKLAHOMA WORKERS COMPENSATION COMMISSION 1915 N. STILES AVENUE OKLAHOMA CITY, OK 73105 SURETY BOND OF SELF-INSURER OF WORKERS COMPENSATION IN THE MATTER OF THE PERMIT
More information[Insert: Full Legal Name of the Company] (the Company ) (Collectively the Company and the Shareholder are the Parties ).
Summary Terms for a Shareholder s Agreement THIS AGREEMENT made as of the day of [], 200[]. A M O N G: [Insert: Investor], ( Shareholder ) - and - [Insert: Full Legal Name of the Company] (the Company
More informationINDEPENDENT BROKER AGREEMENT October 1, 2011 edition
INDEPENDENT BROKER AGREEMENT October 1, 2011 edition This INDEPENDENT BROKER AGREEMENT made this day of 20 by and between Morstan General Agency of New Jersey, Inc. its affiliates and/or subsidiaries,
More informationInnovative Technologies Group, LLC 3515 Sycamore School Rd. #125-301 Ft. Worth, Texas [76133] fax 206-888-6933 email marketing@innovativetech.
Innovative Technologies Group, LLC 3515 Sycamore School Rd. #125-301 Ft. Worth, Texas [76133] fax 206-888-6933 email marketing@innovativetech.us INDEPENDENT REPRESENTATIVE CONTRACT THIS CONTRACT is between
More informationBUYING AGENCY AGREEMENT
THIS AGREEMENT ( Agreement ) is made this day of, 20xx, by and between, with its principal place of business at referred to hereinafter as Buyer, and, with its principal office at, hereinafter referred
More informationElectronic Data Interchange (EDI) Trading Partner Agreement
Electronic Data Interchange (EDI) Trading Partner Agreement THIS ELECTRONIC DATA INTERCHANGE TRADING PARTNER AGREEMENT (the Agreement ) is made as of (date) by and between Ameren Services Company, for
More informationCOMPUTER AND INFORMATION TECHNOLOGY MANAGED SERVICES AGREEMENT
COMPUTER AND INFORMATION TECHNOLOGY MANAGED SERVICES AGREEMENT This Computer and Information Technology Services Agreement is made as of the day of, between Crown Networking Consultants, Inc. (CNC Inc.),
More informationPersonal Loan Agreement and Terms and Conditions
PARTIES Personal Loan Agreement and Terms and Conditions 1.SAMBA FINANCIAL GROUP, Dubai Branch, with offices located at Jumeirah Road, Umm Suqueim 2, P.O. Box 6038, Dubai, United Arab Emirates (the Samba
More informationTENANTS IN COMMON AGREEMENT
TENANTS IN COMMON AGREEMENT This Tenants in Common Agreement is entered into this day of, 20 by and between ( herein) and herein); collectively referred to as Owners and individually as Owner or or and,
More information1. Technical Offer Submission Sheet
8. Sample Forms SUMMARY Sample Form No. 1: 1. TECHNICAL OFFER SUBMISSION SHEET... 3 Sample Form No. 2: 2. PRICE OFFER SUBMISSION SHEET... 5 Sample Form No. 3: 3. BID SECURITY... 6 Sample Form No. 4: 4.
More informationTHESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL ADVICE.
DISCLAIMER The forms provided on our site were drafted by lawyers with knowledge of equine and contractual matters. However, the forms are not State specific. THESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL
More information2 of 8 10/18/2012 1:12 PM
2 of 8 10/18/2012 1:12 PM Exhibit 10.11 EXECUTION COPY SALARIED EMPLOYEE LIABILITIES ASSUMPTION AGREEMENT This SALARIED EMPLOYEE LIABILITIES ASSUMPTION AGREEMENT ( Agreement ) is made on the 22nd day of
More informationPersonal Loan Agreement
March 2014 HSBC Bank Middle East Limited - PERSONAL LOAN AGREEMENT HSBC Bank Middle East Limited Personal Loan Agreement Copyright. HSBC Bank Middle East Limited 2014 ALL RIGHTS RESERVED. No part of this
More informationStandard Conditions of Contract of VJ Engineering Limited (the Company)
1 DEFINITIONS AND GENERAL 1.1 The following expressions shall have the following meanings in these terms and conditions the Company means VJ Engineering Limited. the Customer means the person(s), corporation
More informationCSA CONSTRUCTION, INC. 2314 McAllister Road Houston, Texas 77092 SUBCONTRACTOR AGREEMENT
CSA CONSTRUCTION, INC. 2314 McAllister Road Houston, Texas 77092 SUBCONTRACTOR AGREEMENT THIS AGREEMENT made this day of Month, Year, by and between CSA CONSTRUCTION, INC., a Texas corporation whose principal
More informationForm 9.17. Hardware Purchase and Software License Agreement HARDWARE PURCHASE AND SOFTWARE LICENSE AGREEMENT
Form 9.17 Hardware Purchase and Software License Agreement HARDWARE PURCHASE AND SOFTWARE LICENSE AGREEMENT THIS HARDWARE PURCHASE AND SOFTWARE LICENSE AGREEMENT ("Agreement") is made this ^ day of ^,
More informationSTANDARD AGREEMENT FOR CONSULTANT SERVICES. THIS AGREEMENT, made and entered into in the City of Modesto, State of
STANDARD AGREEMENT FOR CONSULTANT SERVICES THIS AGREEMENT, made and entered into in the City of Modesto, State of California, this day of, 20, ( Effective Date ) by and between the CITY OF MODESTO, a municipal
More informationCONCIERGE SERVICE AGREEMENT. THIS AGREEMENT made this day of, 20, by and between QILIVING,
CONCIERGE SERVICE AGREEMENT THIS AGREEMENT made this day of, 20, by and between QILIVING, LLC., a New York Limited Liability Company with an address at 234 East 58 th Street, Suite 3 New York, New York
More informationWAGES PAYMENT SERVICES AGREEMENT
WAGES PAYMENT SERVICES AGREEMENT This Agreement is made on this the [ day of [, 2015 by and between: First Party: AND Second Party: Al Khaliji France S.A. P.O. Box 4207, Al Maktoum Street, Deira, Dubai,
More informationAgreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection)
Agreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection) This Agreement for Net Metering and Interconnection Services ( Agreement ) is made and entered into this day of
More informationMISSOURI HIGHWAYS AND TRANSPORTATION COMMISSION ELECTRONIC SIGNATURE AGREEMENT
CCO Form: DE06 Approved: 02/14 (AR) Revised: Modified: MISSOURI HIGHWAYS AND TRANSPORTATION COMMISSION ELECTRONIC SIGNATURE AGREEMENT THIS AGREEMENT is entered into by the Missouri Highways and Transportation
More informationDEED OF SALE MEMORANDUM OF AGREEMENT OF SALE ENTERED INTO BY AND BETWEEN:
DEED: erf 17 (G2 STANDS. 8/9/2014) TRUSTS,. PTY OR CC) DEED OF SALE MEMORANDUM OF AGREEMENT OF SALE ENTERED INTO BY AND BETWEEN: LEOPIET ONTWIKKELING EIENDOMS BEPERK REGISTRATION NUMBER: 1996 / 008369/
More informationINVESTMENT ADVISORY AGREEMENT
This CLIENT ADVISORY AGREEMENT (this Agreement ) dated is made between Liberty Partners Capital Management, LLC, a Wyoming-based limited liability company, hereinafter referred to as LPCM or Adviser and
More informationAgent Agreement WITNESSETH
PATRIOT NATIONAL UNDERWRITERS, INC. Agent Agreement THIS AGENT AGREEMENT (the Agreement ) is made and entered into by and between Patriot National Underwriters, Inc., a Texas corporation ( Patriot ), and
More informationONE MORTGAGE PROGRAM AGREEMENT
ONE MORTGAGE PROGRAM AGREEMENT This ONE MORTGAGE PROGRAM AGREEMENT (the Agreement ) is effective as of the day of, 201_, by and between the MASSACHUSETTS HOUSING PARTNERSHIP FUND BOARD, a Massachusetts
More informationCOMMONWEALTH OF VIRGINIA STANDARD PERFORMANCE BOND
(Rev 03/02) Page 1 of 6 COMMONWEALTH OF VIRGINIA STANDARD PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That, the Contractor ( Principal ) whose principal place of business is located at and ( Surety
More informationCREDIT APPLICATION CREDIT AGREEMENT
To the applicant(s): Please complete this Credit Application form in its entirety. After carefully reading and agreeing to the Credit Application and Terms and Conditions (all 5 pages), sign the last page
More informationServices Agreement Instruction Sheet
Delta-T Group POB 884 Bryn Mawr, PA 19010 Phone: 800-251-8501 FAX: 610-527-9547 www.delta-tgroup.com Services Agreement Instruction Sheet We thank you for your interest in Delta-T Group. Below please find
More informationBUSINESS SERVICE & MANAGEMENT AGREEMENT
BUSINESS SERVICE & MANAGEMENT AGREEMENT Company Pty Ltd ACN 111 222 333 BUSINESS SERVICE & MANAGEMENT AGREEMENT THIS AGREEMENT MADE THE DAY OF 20 BETWEEN: AND: Company Pty Ltd ACN 111 222 333 a company
More informationMUSIC RESOURCES TERMS AND CONDITIONS FOR SCHOOLS ( Conditions )
MUSIC RESOURCES TERMS AND CONDITIONS FOR SCHOOLS ( Conditions ) Please ensure all relevant staff have read and understood these Conditions before signing. Please complete, sign and return the Music Resources
More informationNON EXCLUSIVE BROKER REFERRAL AGREEMENT
NON EXCLUSIVE BROKER REFERRAL AGREEMENT THIS NON-EXCLUSIVE BROKER REFERRAL AGREEMENT (this Broker Contract ) is made this day of, 2013 by and between [NAME] (herein after called the "IFPG FRANCHISE CONSULTANT/BROKER
More informationCUSTOMER LIST PURCHASE AGREEMENT BY AND BETWEEN RICHARD PENNER SELLER. and S&W SEED COMPANY BUYER
EXHIBIT 10.1 CUSTOMER LIST PURCHASE AGREEMENT BY AND BETWEEN RICHARD PENNER as SELLER and S&W SEED COMPANY as BUYER CUSTOMER LIST PURCHASE AGREEMENT THIS CUSTOMER LIST PURCHASE AGREEMENT ( Agreement )
More informationSTATE OF OKLAHOMA WORKERS COMPENSATION COURT 1915 NORTH STILES OKLAHOMA CITY, OKLAHOMA 73105-4904 SURETY BOND OF SELF-INSURER OF WORKERS COMPENSATION
STATE OF OKLAHOMA WORKERS COMPENSATION COURT 1915 NORTH STILES OKLAHOMA CITY, OKLAHOMA 73105-4904 SURETY BOND OF SELF-INSURER OF WORKERS COMPENSATION IN THE MATTER OF THE PERMIT OF ) ) ) S U R E T Y B
More informationARTIST MANAGEMENT AGREEMENT
ARTIST MANAGEMENT AGREEMENT AGREEMENT made this day of, 20 by and between (Artist) whose address is (hereinafter referred to as Artist and (Manager) whose address is, (hereinafter referred to as Manager
More informationwww.sc.com/bw Copyright 2015 Standard Chartered Bank
Auto Loans Terms www.sc.com/bw Copyright 2015 Standard Chartered Bank V01-2015 Contents 1. Application 1 2. Pre-conditions to us 1 3. Limit 1 4 Grant of Credit Facilities 1 5 Funding 1 6 Interest, fees
More informationHow To Pay A Contract With Neustar
Neustar Referral Partnership Agreement This NEUSTAR REFERRAL AFFILIATE PARTNERSHIP AGREEMENT ( Agreement ) is made and entered into between Neustar, Inc. a Delaware Corporation, located at 46000 Center
More informationCARACOL LIMITED TIME HOME BUILDING INCENTIVE RIDER
CARACOL LIMITED TIME HOME BUILDING INCENTIVE RIDER Attached to and made a part of the Purchase Agreement dated, 2012 (the Agreement ) between Blackberry Island, LP ( Seller ) and ( Purchaser ) Purchaser
More informationEQUITY SHARING AGREEMENT
EQUITY SHARING AGREEMENT This Equity Sharing Agreement (the Agreement ) is entered into as of the date set forth below by and between a California nonprofit corporation (the Church ), and (the Occupant
More informationPENNSYLVANIA HOUSING FINANCE AGENCY ADDENDUM TO OWNER-ARCHITECT AGREEMENT FOR DESIGN SERVICES AND CONSTRUCTION CONTRACT ADMINISTRATION
PENNSYLVANIA HOUSING FINANCE AGENCY ADDENDUM TO OWNER-ARCHITECT AGREEMENT FOR DESIGN SERVICES AND CONSTRUCTION CONTRACT ADMINISTRATION THIS ADDENDUM shall amend the American Institute of Architects Document
More informationOrmond Beach Brokerage Commission Program Non-Exclusive Open Listing Agreement
Ormond Beach Brokerage Commission Program Non-Exclusive Open Listing Agreement This agreement is made and entered into this day of, 20 by and between the CITY OF ORMOND BEACH, Florida, a body corporate
More informationBuilders & Timber Merchants. Plumbing & Heating Supplies
Builders & Timber Merchants Plumbing & Heating Supplies Builders & Timber Merchants Plumbing & Heating Supplies # Please detach terms & conditions and retain for your records LBS BUILDERS MERCHANTS LIMITED
More informationSTAFF REPORT CONSIDERATION AND APPROVAL OF THIRD LEASE AMENDMENT WITH CROWN CASTLE GT COMPANY LLC FOR CELLULAR TOWER FACILITY ON HILLCREST AVENUE
STAFF REPORT TO: FROM: SUBJECT: HONORABLE MAYOR AND CITY COUNCIL MARTIN D. KOCZANOWICZ, CITY ATTORNEY CONSIDERATION AND APPROVAL OF THIRD LEASE AMENDMENT WITH CROWN CASTLE GT COMPANY LLC FOR CELLULAR TOWER
More information