DEPARTMENT OF NATURAL RESOURCES AND MINES

Size: px
Start display at page:

Download "DEPARTMENT OF NATURAL RESOURCES AND MINES"

Transcription

1 DEPARTMENT OF NATURAL RESOURCES AND MINES AGREEMENT FOR WORK TO BE CARRIED OUT UNDER THE GREAT ARTESIAN BASIN SUSTAINABILITY INTIATIVE CLIENT DOES - BORE REHABILITATION WORK ONLY Property Name Bore Name RN 1234 Natural Resources and Mines PO BOX 318, Toowoomba, QLD 4350 Australia

2 This Agreement is made between AND The State of Queensland acting through the Department of Natural Resources and Mines ABN: (DNRM) [Include Landholder s details and ABN] (Landholder) Background As part of the Great Artesian Basin Sustainability Initiative (GABSI) financial assistance (Subsidy) is A available for landholders who undertake bore rehabilitation work, and which results in a saving of flow from the Great Artesian Basin. B C D The Landholder has applied for financial assistance to do the works. DNRM has approved the Landholder s submission and has agreed to provide financial assistance to the Landholder to carry out the Bore Rehabilitation Work, subject to the terms and conditions of this Agreement. The Parties wish to record the terms and conditions of their agreement, which consists of: (a) Terms and Conditions; (b) Schedule 1 Party Details; (c) Schedule 2 Subsidy and Disbursement; (d) Annexure 1 Landholder s submission; and (e) Annexure 2 - Form GABSI-004. It is agreed: 1. Definitions and Interpretation 1.1 Definitions: Actual Bore Rehabilitation Subsidy Paid or Actual Subsidy means the subsidy paid to the Landholder by DNRM upon successful completion of the bore rehabilitation and is calculated in Item 2 of Schedule 2. The Actual Subsidy paid is the lesser of the actual cost and the proposed cost. Agreement means the clauses contained in this document and the attached Schedules and Annexures. Background IP means IP Rights which are made available by a party for the purpose of carrying out this Agreement and that are: (a) in existence at the Commencement Date; or (b) brought into existence after the Commencement Date other than as a result of the performance of the Works. Bore means the bore identified at Item 1 of Schedule 1. Bore Rehabilitation Work means the activities to be undertaken to bring the Bore into a controlled state whereby the flow from the aquifer can be regulated and shutdown with a valve, without leakage at the surface, resulting in a flow saving from the Great Artesian Basin. The Bore Rehabilitation Work is specified in the Landholder s Submission located in Annexure 1. Business Day means a day that is not a Saturday, Sunday or a public holiday in Brisbane. Class 3 Driller means a person who is accredited through the Australian Drilling Industry Association and carries a current Queensland water bore driller s licence. The details of the Class 3 Driller are shown in Item 6 of Schedule 1. Commencement Date means the date this Agreement is executed by the last Party to sign. Completion Date means the date by which the Bore Rehabilitation Work is to be completed as specified in Item 4 of Schedule 1. Disbursement means payment of an Actual Subsidy by DNRM. Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 2 of 15

3 DNRM means the State of Queensland as represented by the Department of Natural Resources and Mines. Expiry Date means the date by which: (a) the Bore Rehabilitation Work is completed; and (b) Form GABSI-004 has been provided to the Department. Form GABSI-004 means the form shown in Annexure 2 titled Completion of Works Compliance Certificate & Disbursement of Subsidy and includes: (a) Bore cementing report; (b) Bore completion report; (c) Materials invoices; (d) Drilling contractor invoices; (e) Geophysical logging invoice; (f) Pre-works bore flow testing invoice; and (g) Photographs of the old and new bores. GABSI means the Great Artesian Basin Sustainability Initiative, as a joint initiative between DNRM and the Commonwealth of Australia. GST means any tax imposed under GST Law and includes GST within the meaning of the GST Act. GST Act means the A New Tax System (Goods and Services Tax) Act 1999 (Cth) as amended. GST Law means the GST Law as defined in the GST Act and includes any act of Parliament of Australia that imposes or deals with GST. Landholder means the legal owner of the Property, or where there is a lease, the holder of the registered lease as described in Item 5 of Schedule 1. Landholder s Submission means the DNRM approved submission, located in Annexure 1. Ineligible Items means those items which the Landholder cannot claim as part of the Disbursement: (a) Costs associated with drilling, including materials, beyond the Total Depth of the Bore. (b) Costs associated with stand-down of the driller. (c) Costs associated with the transport, unloading, movement and storage of materials on the property. (d) Costs associated with the housing and feeding of drilling contractors; (e) Costs associated with the clearing of tracks and pads for drilling works; and (f) Costs associated with procurement and fitment of water meters. Material means any material including Intellectual Property Rights, created, written or otherwise brought into existence by or on behalf of the Landholder in the course of carrying out the Bore Rehabilitation Works, excluding reports. Parties means DNRM and the Landholder and Party means either of them, as the context requires. Property means the property identified at Item 2 of Schedule 1. Proposed Bore Rehabilitation Subsidy means the subsidy payable to the Landholder by DNRM as shown in Item 1.2 of Schedule 2. The proposed subsidy was calculated in the Landholder s submission. Representative means an employee, agent, officer, director, contractor, subcontractor or other authorised representative of a Party. Special Conditions means any terms and conditions that are agreed to by the Parties and specified in Item 7 of Schedule 1. Standards mean the Minimum standards for the construction and reconditioning of water bores that intersect the sediments of artesian basins in Queensland which are available at and as amended from time to time. State means the State of Queensland. Total Depth of the Bore means the depth of the Bore as described on DNRM s bore card for the Bore. This depth is specified in Item 3 of Schedule Interpretation: (a) In this Agreement unless a contrary intention appears, words importing a gender include any other gender and words in the singular include the plural and vice versa. (b) In this Agreement, unless a contrary intention appears, a reference to: (i) dollars or $ is a reference to the currency of Australia; (ii) any legislation shall include any Act of Parliament and any subordinate legislation, rule, regulation, order or instrument made under it and shall include any statutory modification, substitution or re-enactment of such legislation; Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 3 of 15

4 (iii) if under this Agreement, the day on which or by which any act is to be done is a Saturday, Sunday or public holiday in Queensland, the act may be done on the next business day in Queensland; (iv) an individual or person includes a corporation, partnership, joint venture, trust, association, governments, local government authorities and agencies; (v) a clause or schedule is a reference to a clause or schedule to this Agreement; and (vi) a party to this Agreement includes the executors, administrators, successors and permitted assigns of that party. (c) Clause headings in this Agreement are for convenience of reference only and have no effect in limiting or extending the language of the provisions to which they refer. (d) In this Agreement if a word is defined, cognate words and phrases have corresponding definitions. (e) If a Party to this Agreement consists of more than one person, those persons shall be jointly and severally bound under this Agreement. 2 Term This Agreement will start on the Commencement Date and finish on the Expiry Date, unless earlier terminated in accordance with its terms. 3. Precedence Where any inconsistency exists between: (a) the Special Conditions; (b) the terms and conditions; (c) Schedule 1 (except the Special Conditions); (d) Annexure 1; and (e) Annexure 2, the provisions will take precedence in that order to the extent necessary to resolve the inconsistency. 4. Bore Rehabilitation Work The Landholder warrants that: (a) The Bore Rehabilitation Work must be performed in accordance with this Agreement. (b) The Bore Rehabilitation Work must be carried out by a Class 3 Driller. (c) The Bore Rehabilitation Work will be as per the Landholder s Submission. (d) DNRM does not estimate or guarantee the flow and pressure to be expected from the rehabilitated bore and as such there is an element of financial risk associated with the Bore Rehabilitation Works. (d) The Landholder is liable for the full cost of the Bore Rehabilitation Work. (e) If the Landholder fails to complete the Bore Rehabilitation Work in accordance with the Landholder s Submission, the Landholder will not receive an Actual Subsidy. (f) The Bore Rehabilitation Work will meet the Standards. (g) The Landholder is responsible for all costs incurred where the bore depth is increased beyond the Total Depth of the Bore. These costs do not form part of the Disbursement. 5. Responsibilities of DNRM DNRM will: (a) administer the Subsidy for the Bore Rehabilitation Work; and (b) be responsible only for its own activities and that of its Representatives in accordance with clauses 5(a) and Responsibilities of the Landholder (a) The Landholder has obtained the approval of all neighbouring landholders who access a water supply from the bore of the intention to rehabilitate the bore. The approvals are shown in the Landholder s Submission. (b) The Landholder must complete the Bore Rehabilitation Work by or before the Completion Date. Failure to comply may result in forfeiture of an Actual Subsidy. (c) Unless otherwise provided for, the Landholder will be responsible for all additional costs not expressly mentioned in the Landholder s Submission, where such costs are necessary for the satisfactory completion of the work by or before the Completion Date. Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 4 of 15

5 (d) No part of a Disbursement will be paid for Ineligible Items. (e) The Landholder agrees to accept appointment as principal contractor for a construction workplace pursuant to the Work Health and Safety Act 2011 (the Act) and as such comply with the obligations of the principal contractor as specified in the Act. (f) It is the Landholder s responsibility to ensure that the Bore Rehabilitation Work meets the Standards. Failure to comply with the Standards may result in forfeiture of a Subsidy. (g) It is the Landholder s responsibility to ensure that the Bore Rehabilitation Work meets the requirements of the Landholder Submission shown in Annexure 1. Failure to comply with these requirements may result in forfeiture of a Subsidy. (h) The Landholder shall comply with the requirements of all relevant legislation and the lawful requirements of public or other authorities affecting the Works and shall unless otherwise specified pay all fees in connection therewith; and shall give all notices and obtain all necessary consents. For example but not limited to; crossing public roads, vegetation management, cultural heritage. (i) The Landholder must inform DNRM in writing of sale contracts of the Property on which the Bore Rehabilitation Work is being undertaken. Where the Property is sold, the Landholder will not be entitled to receive a partial Actual Subsidy. 7. Actual Subsidy Disbursement (a) The DNRM agrees to pay the Landholder the Disbursement value as calculated in Item 2 of Schedule 2, on receipt of: (i) a correctly certified and lodged Form GABSI-004, including all reports; and (ii) a correctly rendered tax invoice. (b) Upon receipt of the Form GABSI-004 and confirmation of satisfactory completion, the Department will request a correctly rendered tax invoice. (c) The DNRM may at its absolute discretion request further evidence, or undertake an inspection of the property in accordance with clause 8, before a Disbursement is made under sub-clause (a) of this clause 7. (e) All payments made by DNRM will be inclusive of GST. (f) The Department is released from obligation to pay any part of the Disbursement where the Bore Rehabilitation Works are not completed in accordance with the Landholder s Submission. 8. Security and access (a) The Landholder agrees to provide to DNRM and its Representatives access to the Property for the following periods: (i) during the Term of this Agreement; and (ii) for a period of five years after completion of the Bore Rehabilitation Works. (b) The Department will access the Property for the purposes of assessing the impact of the GABSI project and to assess the Bore Rehabilitation Work. (c) The DNRM will, when accessing the Property with respect to the Bore Rehabilitation Work, comply with all rules, directions and procedures including those relating to security and to workplace health and safety in effect at the Property. (d) The Department will provide 72 hours notice where it intends to access the Property. 9. Termination 9.1 Termination for convenience (a) DNRM may in its absolute discretion, at any time, by written notice, terminate this Agreement in whole or in part without prejudice to any other rights, including for: (i) a machinery of government change which results in monies no longer being made available for GABSI; or (ii) if no funding is provided by the Australian Government for the GABSI program. (b) The Landholder acknowledges that the Department relies upon an appropriation of funding from the Australian Government in order to pay the subsidy. The Department will use reasonable endeavours to ensure that Actual Subsidies are available, but the Department will not be in default or liable for any losses if it does not make a payment due to an absence or delay of funding. If the Department does not make a payment for this reason, the Department must notify the Landholder. Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 5 of 15

6 (c) On receipt of a notice of termination the Landholder must take all available steps to minimise loss resulting from that termination. 9.2 Termination for breach (a) Either Party may terminate this Agreement if the other Party: (i) breaches a material term of this Agreement which is not capable of being remedied; or (ii) breaches a material term of this Agreement which is capable of being remedied and fails to remedy that breach within thirty (30) days after receiving notice requiring it to do so. (b) On receipt of a notice of termination the Landholder must take all available steps to minimise loss resulting from that termination. 10. GST (a) Words defined in the GST Law have the same meaning in this clause. (b) If a Party is required under this Agreement to reimburse or pay to another Party an amount calculated by reference to a cost, expense, or an amount paid or incurred by that Party, the amount of the reimbursement or payment will be reduced by the amount of any input tax credits to which that Party (or an entity on whose behalf the Party is acting) is entitled in respect of any acquisition relating to that cost, expense or other amount. (c) If GST is payable by an entity ("Supplier") in relation to any supply that it makes under or in connection with this Agreement, the Parties agree that: (i) any consideration (including the value of any non-monetary consideration) provided for that supply under or in connection with this Agreement other than under this sub-clause (c) ("Agreed Amount") is exclusive of GST; (ii) an additional amount will be payable by the Party providing consideration for that supply ("Recipient") equal to the amount of GST payable by the Supplier on that supply; (iii) the additional amount is payable at the same time as any part of the Agreed Amount is to be first provided for that supply and the Supplier will provide a tax invoice to the Recipient in respect of that supply, no later than that time; and (iv)to the extent, if any, that any consideration (or part thereof) is specified in this Agreement to be inclusive of GST, that consideration (or the relevant part) shall be excluded from the Agreed Amount for the purposes of calculating the additional amount under subclause (c) (ii). 11. Good Faith and Dispute Resolution (a) The Parties agree to cooperate with each other in the performance of this Agreement and in the event of a dispute arising, to negotiate in good faith a resolution of the dispute. (b) A dispute about this Agreement arises when a Party gives written notice of the dispute to the other Party containing adequate details of the dispute. (c) The Parties agree that any dispute arising must be dealt with by a process of escalation through each Parties respective management hierarchy within 14 days of the notice of dispute. (d) The Landholder must continue to perform its obligations under this Agreement despite the existence of a dispute unless it obtains the State s prior written consent. (e) The Parties must comply with this clause 11 before seeking any relief in any court tribunal, except for urgent relief in the form of judgment from a court. 12. Liability and Indemnity 12.1 Release (a) The Landholder releases to the full extent permitted by law, the Department and its Representatives from all actions, claims, proceedings or demands and in respect of any loss, death, injury, illness or damage (whether personal or property, and whether special, direct, indirect or consequential, including consequential financial loss) arising from or in connection with the Services, the Project or this Agreement No liability for consequential or indirect loss (a) The Department and its Representatives will not in any circumstances (including for negligence) be liable for any loss of revenue, loss of profit, loss of anticipated savings or business, loss of opportunity (including opportunity to enter into or complete arrangements with third parties), loss of data or goodwill, loss of reputation, or any indirect or consequential loss, whether arising in contract, tort (including negligence) or otherwise, in connection with this Agreement. Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 6 of 15

7 12.3 Indemnity (a) The Landholder indemnifies the Department and its Representatives against all liability, loss, costs and expenses (including legal fees, costs and disbursements on a solicitor and own client basis) arising from or incurred in connection with: (i) any default by the Landholder or its Representatives under this Agreement; (ii) any unlawful, wilful or negligent act or omission of the Landholder, the Landholder s Representatives or any person for whose conduct the Landholder is liable; (iii) personal injury (including sickness and death) or property damage or loss in connection with the performance (or attempted or purported performance or non-performance) of this agreement or a breach of this agreement by the Landholder; or (iv) any infringement or alleged infringement of any IP Rights or Moral Rights. (b) The Landholder s liability to indemnify the Department and its Representatives under clause 12.3 will be reduced proportionally to the extent that any negligent act or omission or breach of this agreement by the Department caused the loss or liability. (c) The Department s liability will be limited to the amount of the Proposed Bore Rehabilitation Works Subsidy as set out in Schedule 2. (d) The indemnity granted in clause 12.3(a) is in addition to and not exclusive of any other remedies the Department may have against the Landholder at law No expense required (a) It is not necessary for the Department to incur expense or to make a payment before enforcing a right of indemnity conferred by this Agreement. 13. General matters (a) Variation - This Agreement may only be varied upon written agreement that is signed by both Parties provided that any variation does not exceed the original scope of the Agreement. (b) Governing Law - This Agreement is governed by and construed in accordance with the law of Queensland and the Parties hereby submit to the non-exclusive jurisdiction of the courts in Queensland. (c) Entire Agreement - This Agreement constitutes the entire Agreement of the Parties and supersedes all previous communications, negotiations, arrangements and agreements between the Parties. (d) Compliance with Laws - The Landholder must comply with all relevant laws in performing the Work including the Work Health and Safety Act (e) Severability - Any provision in this Agreement which is invalid or unenforceable is to be read down if possible, so as to be valid and enforceable. If that is not possible, the provision must, to the extent that it is capable, be severed to the extent of the invalidity or unenforceability without affecting the remaining provisions. (f) The Landholder will not assign, novate or subcontract the whole or any part of this Agreement without the prior written consent of DNRM. 14. Notices (a) Notices under this Agreement must be in writing and may be delivered by prepaid postage or certified mail, by hand, or by facsimile transmission to the Parties at the addresses specified in Item 5 of Schedule 1 or other address subsequently notified by one Party to the other. (b) Notices will be deemed to be given: (i) on the fifth day after the date of posting after deposit in the mail with postage prepaid; or (ii) immediately on delivery by hand; or (iii) if sent by facsimile transmission, at the time in the place to which it is sent equivalent to the time recorded on the transmitting machine from which it was sent. (c) The Parties agree that where notice is given by facsimile transmission the original document must be sent by post. (d) If the communication is taken to have been received on a day that is not a Business Day or later than 5.00pm on a Business Day, the communication is taken to have been received at 9.00am on the next Business Day. Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 7 of 15

8 15. Intellectual Property (a) Nothing in this deed affects ownership of Background IP. (b) All rights in and title to the Material and Reports will vest, upon creation, in the Landholder. (c) The Landholder grants to DNRM: (i) a non-exclusive, worldwide, perpetual, irrevocable, royalty-free licence (including a right to sublicense) to use, communicate, reproduce, publish, adapt and modify: (A) the Activity Material; (B) the Landholder s Background IP; and (C) the Reports for Department non-commercial purposes. (d) The Department grants to the Landholder a non-exclusive, non-transferable, royalty-free licence to use the Department s Background IP solely for the purposes of carrying out the Activity and exercising its rights in the Material (insofar as the Department s Background IP forms part of the Material). (e) The Landholder will do all things necessary (including obtaining consents) to ensure: (i) the vesting of the Material and Reports in accordance with clause 15(c); and (ii) the licensing of the Material and Reports in accordance with clause 15(d). 16. Survival (a) The following clauses survive termination of this Agreement: (i) Dispute resolution (clause 11); (ii) Liability and Indemnity (clause 12); (iii) General matters (clause 13); (iv) Intellectual property (clause 15); and (v) Survival (clause 16). Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 8 of 15

9 Signed as an Agreement Signed for and on behalf of the State of Queensland acting through the Department of Natural Resources and Mines ABN by, a person duly authorised to act in that behalf in the presence of: Signature of Witness Name of Witness in full Signature Position Date: Option 1: if the Recipient is an individual **Delete if inapplicable** OR Signed, sealed and delivered by the Recipient Signature Date: Signature of Witness Name of Witness in full Option 2: if the Recipient is a company **Delete if inapplicable** include ABN OR Executed by the Recipient in accordance with section 127 of the Corporations Act 2001 (Cth): Signature of Director/sole Director Name of Director/sole Director in full Date: Signature of Director/Secretary Name of Director/Secretary in full Date: Option 3: if the Recipient is another entity **Delete if inapplicable** include ABN Signed, sealed and delivered for and on behalf of the Recipient by a person Signature duly authorised to act in that behalf in the presence of: Date: Signature of Witness Name of Witness in full Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 9 of 15

10 Schedule 1 Party Details 1. The Registered Number of the Bore on which the Bore Rehabilitation Work is to be completed (taken from Section 1 of the approved Landholder Submission located in Annexure 1) [xx] 2. The Property/s on which the bore rehabilitation work is located (taken from Section 7.1 of the approved Landholder Submission located in Annexure 1) [xx] 3. The Total Depth of the Bore. Works beyond this depth are at the Landholders full expense. [xx] 4. Completion Date: 31 March 2016, for works to be completed in the 2015/2016 financial year 31 March 2017, for works to be completed in the 2016/2017 financial year 5. Contact Details DNRM: Department of Natural Resources and Mines Great Artesian Basin Sustainability Initiative PO Box 318, Toowoomba QLD 4350 Phone: (07) Fax: (07) Landholder: (taken from Section 7.0 of the approved Landholder Submission located in Annexure 1) [Name] [Position] [Address] Phone: [Phone] Fax: [Fax] [ ] 6. Class 3 Driller Details: [Name] Licence No.: [Licence No.] [Position] [Address] Phone: [Phone] [ ] 7. Special Conditions Should the Landholder nominate to undertake metering this is where this condition would be recorded - most other times Nil will be typed Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 10 of 15

11 Schedule 2 Subsidy and Disbursement All amounts in this schedule are inclusive of GST 1 Bore Rehabilitation Work (To the Total Depth of the Bore, Item 3 of Schedule 1) 1.1 ESTIMATED COST OF THE BORE REHABILITATION WORK (Incl GST) (from the DNRM approved Landholder Submission in Annexure 1) $ #### 1.2 PROPOSED BORE REHABILITATION SUBSIDY (Incl GST) (from the DNRM approved Landholder Submission in Annexure 1) $ #### 2 Disbursement Actual Bore Rehabilitation Subsidy Paid (to Total Depth only) the lesser of: (i) the value shown in item 1.2 above; and, (ii) {the sum of all bore rehabilitation expenses * 80%} Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 11 of 15

12 Annexure 1 Landholder s Submission [insert copy of submission] Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 12 of 15

13 Annexure 2 Form GABSI-004 Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 13 of 15

14 Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 14 of 15

15 Client Does - Works Agreement for Bore Rehabilitation work under GABSI Page 15 of 15

Vocational Education and Training (VET) Pre-qualified Supplier (PQS) Agreement

Vocational Education and Training (VET) Pre-qualified Supplier (PQS) Agreement Vocational Education and Training (VET) Pre-qualified Supplier (PQS) Agreement between STATE OF QUEENSLAND through the Department of Education and Training and [Supplier to Insert Legal Name] TABLE OF

More information

ASSET BUY/SELL AGREEMENT DATED. 6 July 2012 BETWEEN. Transport Trucks Pty Ltd AS SELLER AND. JP Investigations Pty Lttd AS BUYER

ASSET BUY/SELL AGREEMENT DATED. 6 July 2012 BETWEEN. Transport Trucks Pty Ltd AS SELLER AND. JP Investigations Pty Lttd AS BUYER ASSET BUY/SELL AGREEMENT DATED 6 July 2012 BETWEEN Transport Trucks Pty Ltd AS SELLER AND JP Investigations Pty Lttd AS BUYER This Agreement (the Agreement ) is entered into between: 1 Transport Trucks

More information

STATE OF QUEENSLAND Acting through Arts Queensland, Department of the Premier and Cabinet REGIONAL ARTS FUND [RAF]

STATE OF QUEENSLAND Acting through Arts Queensland, Department of the Premier and Cabinet REGIONAL ARTS FUND [RAF] STATE OF QUEENSLAND Acting through Arts Queensland, Department of the Premier and Cabinet [RAF] TERMS OF FUNDING Version 1 18 July 2016 These Terms of Funding together with the Letter of Offer and the

More information

PERSONAL ALERT SYSTEMS REBATE SCHEME PROVIDER PANER DEED

PERSONAL ALERT SYSTEMS REBATE SCHEME PROVIDER PANER DEED DATED DAY OF 2015 PERSONAL ALERT SYSTEMS REBATE SCHEME PROVIDER PANER DEED between MINISTER FOR COMMUNITIES AND SOCIAL INCLUSION - and - [INSERT PARTY NAME] ACN [INSERT] Page 1 of 1 TABLE OF CONTENTS BACKGROUND...

More information

CONSIGNMENT AGREEMENT DATED BETWEEN. Transit Holdings Pty Ltd AS CONSIGNOR AND. Independent Holdings Pty Ltd AS CONSIGNEE

CONSIGNMENT AGREEMENT DATED BETWEEN. Transit Holdings Pty Ltd AS CONSIGNOR AND. Independent Holdings Pty Ltd AS CONSIGNEE CONSIGNMENT AGREEMENT DATED BETWEEN Transit Holdings Pty Ltd AS CONSIGNOR AND Independent Holdings Pty Ltd AS CONSIGNEE This Agreement (the Agreement ) is entered into between: 1 Transit Holdings Pty Ltd

More information

PURCHASE ORDER TERMS & CONDITIONS FOR SUPPLY OF GOODS & MATERIALS

PURCHASE ORDER TERMS & CONDITIONS FOR SUPPLY OF GOODS & MATERIALS By accepting this Purchase Order, the Supplier named in the Schedule agrees to supply the Goods and/or Services subject to the conditions set out below. TERMS & CONDITIONS 1. Definitions 1.1 Code means

More information

Dispute Management Agreement. Approved Panel Member Terms of Appointment 3 APRIL 2014 FOUO: COMMERCIAL IN CONFIDENCE

Dispute Management Agreement. Approved Panel Member Terms of Appointment 3 APRIL 2014 FOUO: COMMERCIAL IN CONFIDENCE Dispute Management Agreement Approved Panel Member Terms of Appointment 3 APRIL 2014 FOUO: COMMERCIAL IN CONFIDENCE NBN Co Limited Approved Panel Member Terms of Appointment 03/04/14 Copyright This document

More information

SOFTWARE DEVELOPMENT AGREEMENT

SOFTWARE DEVELOPMENT AGREEMENT SOFTWARE DEVELOPMENT AGREEMENT THIS AGREEMENT dated the day of 20. BETWEEN: AND: ACN of (the Customer ; 1iT Pty Ltd ACN 092 074 247 of 41 Oxford Close West Leederville (the Contractor. BACKGROUND A. The

More information

Client Broker Agreement (Wholesale Broker)

Client Broker Agreement (Wholesale Broker) Client Broker Agreement (Wholesale Broker) Broker Name: and Parmia Pty Limited 1 PO Box 404, Beenleigh QLD 4207 Tel: 07 3387 1900 Fax: 07 3382 0676 Suite 7, Reece House 94 George Street, Beenleigh QLD

More information

Standard Terms and Conditions of Purchase

Standard Terms and Conditions of Purchase Standard Terms and Conditions of Purchase 1. INTERPRETATIONS AND GENERAL MATTERS 1.1 Definitions day means calendar day. FIS means, in relation to delivery of the Goods, free into store and includes the

More information

Training Contract Standard Terms and Conditions

Training Contract Standard Terms and Conditions Training Contract Standard Terms and Conditions 1. Consultant Training 2. Fee The Principal engages the Consultant as an independent consultant to provide the Training to the Principal on the terms and

More information

JRI S STANDARD TERMS OF PURCHASE. Business Day: a day (other than a Saturday, Sunday or public holiday) when banks in London are open for business.

JRI S STANDARD TERMS OF PURCHASE. Business Day: a day (other than a Saturday, Sunday or public holiday) when banks in London are open for business. JRI S STANDARD TERMS OF PURCHASE 1. INTERPRETATION 1.1 Definitions. In these Conditions, the following definitions apply: Business Day: a day (other than a Saturday, Sunday or public holiday) when banks

More information

BMT Tax Depreciation Pty Ltd - Terms of Engagement

BMT Tax Depreciation Pty Ltd - Terms of Engagement BMT Tax Depreciation Pty Ltd - Terms of Engagement 1.0 Definitions and Interpretation 1.1 In this document, unless the context indicates a contrary intention: Agreement means these Terms of Engagement

More information

Software Escrow & Copyright Agents Pty Ltd - Software Escrow Agreement

Software Escrow & Copyright Agents Pty Ltd - Software Escrow Agreement Schedule 1 General Details Agreement Date Customer Customer ABN Customer Address Commencement Date As per the date the Customer began paying the Escrow Service Fee product as defined in the Master Agreement.

More information

NEGOTIATED CONNECTION CONTRACT. between. The Distributor. and. The Customer

NEGOTIATED CONNECTION CONTRACT. between. The Distributor. and. The Customer NEGOTIATED CONNECTION CONTRACT between The Distributor and The Customer Negotiated Connection Contract (NSF No Tender) -1-1 July 2016 NEGOTIATED CONNECTION CONTRACT This Contract is made Between The Distributor

More information

Receivables Purchase Deed

Receivables Purchase Deed Deed Execution version Eastern Goldfields Regional Prison Redevelopment Project Receivables Purchase Deed The State of Western Australia represented by the Minister for Works, a body corporate constituted

More information

BUILDER AGREEMENT THIS BUILDER AGREEMENT DATED:... /... / 20...

BUILDER AGREEMENT THIS BUILDER AGREEMENT DATED:... /... / 20... Page 1 of 7 BUILDER AGREEMENT THIS BUILDER AGREEMENT DATED:... /... / 20... - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - -

More information

DEED OF ACCESS, INDEMNITY AND INSURANCE. The Named Officer (Officer) and. Grain Trade Australia Limited (Company)

DEED OF ACCESS, INDEMNITY AND INSURANCE. The Named Officer (Officer) and. Grain Trade Australia Limited (Company) The Named Officer (Officer) and Grain Trade Australia Limited (Company) DEED OF ACCESS, INDEMNITY AND INSURANCE Version 1-27 October 2015 Page 1 of 12 TABLE OF CONTENTS PAGE NO. 1. DEFINITIONS AND INTERPRETATION

More information

QBCC MAJOR WORKS SUBCONTRACT

QBCC MAJOR WORKS SUBCONTRACT Build better. QBCC MAJOR WORKS SUBCONTRACT The General Conditions of the QBCC Major Works Subcontract may not be suitable for all work and the QBCC does not make any representation as to the suitability

More information

Lodger (Name, address, & phone number)

Lodger (Name, address,  & phone number) QUEENSLAND LAND REGISTRY LEASE FORM 7 Version 6 Land Title Act 1994, Land Act 1994 and Water Act 2000 Page 1 of 17 Dealing Number OFFICE USE ONLY Privacy Statement Collection of this information is authorised

More information

Purchase Order Terms and Conditions

Purchase Order Terms and Conditions Purchase Order Terms and Conditions BGC Contracting Date As per Purchase Order 1. Definitions BGC means the BGC entity named in the Purchaser Order its authorised agents, employees, heirs and successors.

More information

(Short Form) Terms and Conditions. Version 1.2 dated 17 February 2015. Please note:

(Short Form) Terms and Conditions. Version 1.2 dated 17 February 2015. Please note: (Short Form) Terms and Conditions Version 1.2 dated 17 February 2015 Please note: The Agreement comprises two parts: Particulars Terms and Conditions (Short Form) Terms and Conditions Page 2 of 7 Terms

More information

Kbase Connect Terms of Business (Development and Licensing)

Kbase Connect Terms of Business (Development and Licensing) 1 Agreement 5.6.3 When the Client has used the Solution in a live environment. 1.1 By signing the Initial Requirements Document, the person doing so (the Client) is entering into an agreement - the Project

More information

Deed for Student Mobility Programmes

Deed for Student Mobility Programmes Deed for Student Mobility Programmes between the COMMONWEALTH OF AUSTRALIA as represented by the Australian Government Department of Education and Training and [Funding recipient name] regarding Student

More information

Purchase Order Terms and Conditions

Purchase Order Terms and Conditions Wilmar Sugar Pty Ltd (ABN 44 081 051 792) Wilmar BioEthanol (Australia) Pty Ltd (ABN 85 009 660 191) (each referred to as Wilmar in this document) 1. Electronically Transmitted Purchase Order Documents

More information

COMMERCIAL CREDIT ACCOUNT APPLICATION

COMMERCIAL CREDIT ACCOUNT APPLICATION COMMERCIAL CREDIT ACCOUNT APPLICATION *Mandatory field required to process application Please complete the below form in BLOCK LETTERS ONLY ensuring all information is entered with as much detail as possible.

More information

Funding Conditions. Parties. Agreed terms

Funding Conditions. Parties. Agreed terms Funding Conditions Parties The Commonwealth of Australia as represented by the Department of the Environment ABN 34 190 894 983 (Department) [Insert Recipient name and ABN] (Recipient) Agreed terms 1.

More information

Agreement to provide company secretarial and related services. Sample. Brooke Pendlebury Principal Lawyer, Pendlebury Workplace Law

Agreement to provide company secretarial and related services. Sample. Brooke Pendlebury Principal Lawyer, Pendlebury Workplace Law Agreement to provide company secretarial and related services Description: Author: This document is a precedent agreement to provide company secretarial and related services. Brooke Pendlebury Principal

More information

Entrepreneurs Programme: Research Connections Project Contract

Entrepreneurs Programme: Research Connections Project Contract Entrepreneurs Programme: Research Connections Project Contract Once completed, this document, together with each set of Project Details and the attached standard terms (Standard Terms), forms an Agreement

More information

Outdoor Advertising Rental Agreement - Terms & Conditions

Outdoor Advertising Rental Agreement - Terms & Conditions Outdoor Advertising Rental Agreement - Terms & Conditions M5 Limited ("Media5") STANDARD TERMS AND CONDITIONS OF BUSINESS The following terms and conditions apply to all advertising services provided by

More information

Commonwealth Grant Agreement

Commonwealth Grant Agreement between the Commonwealth represented by and [insert Grantee] [Insert reference number Business Research and Innovation Initiative - Pilot Page 1 of 16 Contents Commonwealth Grant Agreement... 1 Contents...2

More information

SourceIT. Licence Contract Commercial off-theshelf. Australian Government. Release version 2.2

SourceIT. Licence Contract Commercial off-theshelf. Australian Government. Release version 2.2 Australian Government SourceIT Licence Contract Commercial off-theshelf Software Release version 2.2 [Insert name of Customer] (Customer) [Insert name of Contractor] (Contractor) Licence Contract Commercial

More information

If you are in full agreement with the document, kindly return the signature page at the end of the documents

If you are in full agreement with the document, kindly return the signature page at the end of the documents Introducing Broker Agreement If you are in full agreement with the document, kindly return the signature page at the end of the documents Brokersclub Limited is a limited liability company registered in

More information

PROPERTY MANAGEMENT AGREEMENT

PROPERTY MANAGEMENT AGREEMENT PROPERTY MANAGEMENT AGREEMENT MASTER ADVOCATES REAL ESTATE SERVICES PTY LTD ABN 59 169 821 407 ( AGENT ) And [INSERT NAME OF CLIENT] ( CLIENT ) DATE: BETWEEN: MASTER ADVOCATES REAL ESTATE SERVICES PTY

More information

Terms and Conditions of Offer and Contract (Works & Services) Conditions of Offer

Terms and Conditions of Offer and Contract (Works & Services) Conditions of Offer Conditions of Offer A1 The offer documents comprise the offer form, letter of invitation to offer (if any), these Conditions of Offer and Conditions of Contract (Works & Services), the Working with Queensland

More information

THIS IS THE APPENDIX F REFERRED TO IN THE FOREGOING AGREEMENT BETWEEN FISHERIES INNOVATION SCOTLAND AND THE CONTRACTOR

THIS IS THE APPENDIX F REFERRED TO IN THE FOREGOING AGREEMENT BETWEEN FISHERIES INNOVATION SCOTLAND AND THE CONTRACTOR THIS IS THE APPENDIX F REFERRED TO IN THE FOREGOING AGREEMENT BETWEEN FISHERIES INNOVATION SCOTLAND AND THE CONTRACTOR APPENDIX F Terms and Conditions 1. Definitions 1.1. In these terms and conditions

More information

(This agreement is in rich text format and appears in a scrolling text box once you ve reached https://orgcert-renewal.equifax.com/orgcerts/...

(This agreement is in rich text format and appears in a scrolling text box once you ve reached https://orgcert-renewal.equifax.com/orgcerts/... (This agreement is in rich text format and appears in a scrolling text box once you ve reached https://orgcert-renewal.equifax.com/orgcerts/...) Equifax Subscriber Agreement This Agreement is between the

More information

New-Gen Electrical (ABN 11 514 699 805) Terms & Conditions

New-Gen Electrical (ABN 11 514 699 805) Terms & Conditions ACRS Lic No. A021974 Lic No. 192237C New-Gen Electrical (ABN 11 514 699 805) Terms & Conditions *Definitions are in clause 19 1. FORMATION OF AGREEMENT 1.1 Acceptance of Quotation The Customer must accept

More information

1.1 In these Terms the following expressions have the following meanings:

1.1 In these Terms the following expressions have the following meanings: General Terms and Conditions applying to all Booking Confirmations 1. Definitions and Interpretation 1.1 In these Terms the following expressions have the following meanings: Advertising Copy means any

More information

Conditions of Contract for Consultancy Services

Conditions of Contract for Consultancy Services Conditions of Contract for Consultancy Services INGENIUM PO Box 118, Thames; Ph 07 868 3930, Fax 07 868 3930 www.ingenium.org.nz NZ Transport Agency Private Bag 6995, Wellington 6441; Ph 04 894 5400, Fax:

More information

Breed Communications Limited - limited company consultancy agreement 230113

Breed Communications Limited - limited company consultancy agreement 230113 Limited Company Consultancy Master Agreement DATED BETWEEN:- (1) Breed Communications Limited (Company Number 4809384) whose registered office is c/o Hilton Consulting, 119 The Hub, 300 Kensal Rise, London

More information

TEXTURA AUSTRALASIA PTY LTD ACN 160 777 088 ( Textura ) CONSTRUCTION PAYMENT MANAGEMENT SYSTEM TERMS AND CONDITIONS OF USE

TEXTURA AUSTRALASIA PTY LTD ACN 160 777 088 ( Textura ) CONSTRUCTION PAYMENT MANAGEMENT SYSTEM TERMS AND CONDITIONS OF USE TEXTURA AUSTRALASIA PTY LTD ACN 160 777 088 ( Textura ) CONSTRUCTION PAYMENT MANAGEMENT SYSTEM TERMS AND CONDITIONS OF USE Welcome to the Textura Construction Payment Management ( CPM ) System. By clicking

More information

Inject Design General Terms & Conditions

Inject Design General Terms & Conditions Inject Design General Terms & Conditions Latest Revision: April 2015 www.injectdesign.co.nz Content No. Contents Page No. 00 01 03 04 05 06 07 08 09 10 11 12 13 14 15 16 17 18 General Terms & Conditions

More information

Software Development. Standard Terms and Conditions. V2.0 January 2013

Software Development. Standard Terms and Conditions. V2.0 January 2013 Software Development Standard Terms and Conditions V2.0 January 2013 Elysium Ltd Milton House Whitehill Road Crowborough East Sussex TN6 1LB Tel: 01892 667411 Fax: 01829667433 Email: sales@elysium.ltd.uk

More information

ARTWORK COMMISSION AGREEMENT

ARTWORK COMMISSION AGREEMENT ARTWORK COMMISSION AGREEMENT THIS AGREEMENT is made the day of in the year BETWEEN the Minister for Works of Level 6, 16 Parkland Road, Osborne Park, WA 6017 being the body corporate created under Section

More information

Custodian-Node data provision terms and conditions

Custodian-Node data provision terms and conditions Custodian-Node data provision terms and conditions Parties Node Operator Data Custodian Background A B C D E [Insert legal name of node][insert ACN/ABN/ARBN] of [Insert address]\ [Insert legal name of

More information

Purchase Order Terms and Conditions

Purchase Order Terms and Conditions Purchase Order Terms and Conditions "Avanade" means Avanade Asia Pte Ltd (Company Registration No.: 20005969E), a company incorporated in Singapore, having its offices at 238A Thomson Road, #25-01 Novena

More information

GENERAL CONDITIONS OF CONTRACT

GENERAL CONDITIONS OF CONTRACT GENERAL CONDITIONS OF CONTRACT 1 GENERAL 1.1 These General Conditions of Contract (General Conditions) apply to the contract created by Comcare when issuing the Purchase Order to the Contractor (the Contract).

More information

Services Agreement between Client and Provider

Services Agreement between Client and Provider Services Agreement between Client and Provider This Services Agreement is part of the Member Contract between Client and Provider, effective upon Client s award and Provider s acceptance of a Job on the

More information

TERMS AND CONDITIONS

TERMS AND CONDITIONS TERMS AND CONDITIONS 1. Definitions 1.1 "Booking" means the Tennis At The Palace booking form which is completed and signed by the Client and returned to The Capital Event Management LLC in connection

More information

VET (WA) Ministerial Corporation Purchase of Training Services Process Terms and Conditions

VET (WA) Ministerial Corporation Purchase of Training Services Process Terms and Conditions VET (WA) Ministerial Corporation Purchase of Training Services Process Terms and Conditions NOVEMBER 2013 EDITION TABLE OF CONTENTS 2. RESPONDENT S PARTICIPATION IN THE PROCUREMENT PROCESS 7 3. GENERAL...

More information

GENERAL CONDITIONS OF TENDER (Supply of Goods) ANNEX A. ANNEX A General Conditions of Tender (Supply of Goods)

GENERAL CONDITIONS OF TENDER (Supply of Goods) ANNEX A. ANNEX A General Conditions of Tender (Supply of Goods) ANNEX A General Conditions of Tender (Supply of Goods) Contents INTRODUCTORY PROVISIONS... 2 1. DEFINITIONS AND INTERPRETATION... 2 TENDERS... 4 2. REQUEST... 4 3. TENDERS... 5 4. HOW TO SUBMIT TENDERS...

More information

INTRODUCTION 1. Janet(UK) agrees to provide to the Customer the JVCRS subject to these Terms.

INTRODUCTION 1. Janet(UK) agrees to provide to the Customer the JVCRS subject to these Terms. Terms and Conditions for use of the Janet Videoconferencing Recording Service ( Terms ) Reference: CONREF/LA/xxxx INTRODUCTION 1. Janet(UK) agrees to provide to the Customer the JVCRS subject to these

More information

Macquarie Equity Lever online instructions terms and conditions 1 of 1

Macquarie Equity Lever online instructions terms and conditions 1 of 1 Macquarie Equity Lever online instructions terms and conditions 1 of 1 Important notice If you want to make investments under your Macquarie Equity Lever Facility online via GearUp, you need to read, understand,

More information

(INDIVIDUALS ONLY) IndContPkge Version: 1.7 Updated: 18 Jul. 03

(INDIVIDUALS ONLY) IndContPkge Version: 1.7 Updated: 18 Jul. 03 INDEPENDENT CONTRACTOR PACKAGE (INDIVIDUALS ONLY) IndContPkge Version: 1.7 Updated: 18 Jul. 03 Contents Preface 2 Checklist 3 Helpful Hints 4 Frequently Asked Questions 5 Agreement with an Independent

More information

Framework Terms and Conditions

Framework Terms and Conditions Introduction Framework Terms and Conditions These Framework Terms and Conditions form part of the contract to allow one or more Purchasing Agencies to purchase outcome-focussed services from the Provider.

More information

SUNCORP GROUP LIMITED

SUNCORP GROUP LIMITED SUNCORP GROUP LIMITED ABN 66 145 290 124 EXEMPT EMPLOYEE SHARE PLAN TRUST DEED 5709273/1 TABLE OF CONTENTS 1. PURPOSE... 1 2. DEFINITIONS... 1 3. OPERATION OF THE PLAN... 4 4. HOW THE PLAN WORKS... 4 5.

More information

[Insert Company address] GCU's SUPPLY OF RESEARCH SERVICES. Dear Sirs,

[Insert Company address] GCU's SUPPLY OF RESEARCH SERVICES. Dear Sirs, [Insert Company address] GCU's SUPPLY OF RESEARCH SERVICES Dear Sirs, The University Court of Glasgow Caledonian University, a charitable body registered in Scotland with registration number SCO21474 and

More information

Merchant Application. FAX BACK TO: 03 9413 1467 EMAIL TO: Merch.Support@UnitedCard.com.au POST To: PO Box 1028, Collingwood, Vic 3066 THE AGREEMENT

Merchant Application. FAX BACK TO: 03 9413 1467 EMAIL TO: Merch.Support@UnitedCard.com.au POST To: PO Box 1028, Collingwood, Vic 3066 THE AGREEMENT Merchant Application FAX BACK TO: 03 9413 1467 EMAIL TO: Merch.Support@UnitedCard.com.au POST To: PO Box 1028, Collingwood, Vic 3066 THE AGREEMENT 1. The Applicant acknowledges and agrees that this United

More information

ERM POWER RETAIL PTY LTD STANDARD LARGE CUSTOMER RETAIL CONTRACT

ERM POWER RETAIL PTY LTD STANDARD LARGE CUSTOMER RETAIL CONTRACT ERM POWER RETAIL PTY LTD STANDARD LARGE CUSTOMER RETAIL CONTRACT This standard large customer retail contract sets out the terms referred to in section 52(1) of the Act. It only applies between ERM Power

More information

TERMS AND CONDITIONS

TERMS AND CONDITIONS TERMS AND CONDITIONS 1. Definitions and Interpretation 1.1 In these Conditions: AGREEMENT means the Agreement for the provisions of the Services by the Company to the Client as contained in the Work Authorisation

More information

(2) name whose principal place of business is address (hereafter referred to as 'the Consultant').

(2) name whose principal place of business is address (hereafter referred to as 'the Consultant'). NB This is an example of the type of agreement we may require with a consultant. Individual circumstances and AACT s requirements may alter the format in particular instances. THIS AGREEMENT FOR CONSULTANCY

More information

MORRISON SECURITIES PTY LIMITED

MORRISON SECURITIES PTY LIMITED Morrison Securities Pty Limited Participant of ASX Group Participant of SFE ABN: 50 00 430 342 AFSL 24737 GPO BOX 5258, SYDNEY NSW 200 Ph: (02) 9033 8383 Fax: (02) 9033 8300 AGREEMENT dated CLIENT AGREEMENT

More information

End-User License Agreement

End-User License Agreement End-User License Agreement This End-User License Agreement ( EULA ) is a legal agreement between JGraph Limited ( JGraph ) and you. You agree that this EULA is enforceable like any written negotiated agreement

More information

Contractor Coach Agreement

Contractor Coach Agreement Contractor Coach Agreement Agreement between Sydney Uni Sport & Fitness, the Sydney Uni Club and (Insert club sport here) (Insert contractor s name here) Contact Details Contractor please complete all

More information

Street Lighting Procurement Pack Model Documentation

Street Lighting Procurement Pack Model Documentation Schedule 23 Sub-Contractor Direct Agreement Model Contract Schedule 23 Sub-Contractor Direct Agreement Dated 200[ ] [AUTHORITY] [SUB-CONTRACTOR] [SERVICE PROVIDER] [GUARANTOR] AUTHORITY SUB-CONTRACTOR

More information

Standard conditions of purchase

Standard conditions of purchase Standard conditions of purchase 1 OFFER AND ACCEPTANCE 2 PROPERTY, RISK & DELIVERY 3 PRICES & RATES The Supplier shall provide all Goods and Services in accordance with the terms and conditions set out

More information

PROPERHANDS CLEANING AGREEMENT

PROPERHANDS CLEANING AGREEMENT PROPERHANDS CLEANING AGREEMENT THIS AGREEMENT is made on the date that the Customer has Authorised Payment and Confirmed the Booking Request. BETWEEN: The Cleaning Service Provider And The Customer (each

More information

CONDITIONS OF CONTRACT

CONDITIONS OF CONTRACT CONDITIONS OF CONTRACT For the provision of Goods and/or Services Version 004 dated 1 July 2012 State of Queensland (Department of Housing and Public Works) 2012. All rights reserved. Introduction The

More information

TRANSFIELD SERVICES Australia

TRANSFIELD SERVICES Australia 1. INTERPRETATIONS AND GENERAL MATTERS 1.1 Definitions Customer means Transfield Services () Pty Limited (ABN 11 093 114 553). "day" means a calendar day. "FOT" means, in relation to delivery of the Goods,

More information

Youth Justice Board Purchase Order Form General Terms and Conditions

Youth Justice Board Purchase Order Form General Terms and Conditions Youth Justice Board Purchase Order Form General Terms and Conditions 1. Interpretation 1.1 In this Contract:- a) Authority means the Youth Justice Board for England and Wales acting through the authorized

More information

TCM RECRUITMENT LIMITED carries on the business of a recruitment agency. The following Terms and Conditions set out the relationship between

TCM RECRUITMENT LIMITED carries on the business of a recruitment agency. The following Terms and Conditions set out the relationship between TCM RECRUITMENT LIMITED carries on the business of a recruitment agency. The following Terms and Conditions set out the relationship between ourselves and our candidates for whom we are seeking introductions

More information

Hosting Service Agreement

Hosting Service Agreement tesseract-online.com Hosting Service Agreement Cranbox Limited T/A Tesseract Commencement Date: 1. Agreement 1.1. This Agreement is made between you (the 'Customer') and Cranbox Limited trading as Tesseract

More information

APPLICANT VERIFICATION SERVICES TERMS AND CONDITIONS OF USE

APPLICANT VERIFICATION SERVICES TERMS AND CONDITIONS OF USE APPLICANT VERIFICATION SERVICES TERMS AND CONDITIONS OF USE 1 P a g e Contents 1. Interpretation and Definitions 2. Commencement and Term 3. Recitals and Relationship 4. Services 5. Systems and Software

More information

Janison Terms and Conditions. Updated Jan 2013

Janison Terms and Conditions. Updated Jan 2013 Janison Terms and Conditions Updated Jan 2013 Terms and Conditions 1. Interpretation 1.1. In this Agreement, unless otherwise indicated by the context (a) (b) (c) (d) (e) (f) (g) (h) (i) words importing

More information

Payment Directions Deed

Payment Directions Deed Deed EXECUTION VERSION Eastern Goldfields Regional Prison Redevelopment Project Payment Directions Deed The State of Western Australia represented by the Minister for Works, a body corporate constituted

More information

Conditions of Contract. Quotation - Consultant Services. Effective Date: 1 July 2014 Version No. 5.0. Issued by Procurement Policy Unit

Conditions of Contract. Quotation - Consultant Services. Effective Date: 1 July 2014 Version No. 5.0. Issued by Procurement Policy Unit Quotation - Consultant Services Effective Date: 1 July 2014 Version No. 5.0 Issued by Procurement Policy Unit This page is left intentionally blank Table of Contents 1 Interpretation... 5 2 Formation of

More information

UNISCOPE COMMUNICATIONS PTY LTD. P a g e 1 ABN: 80 159 470 943. Unit 3/10, Advantage Way, Wangara, Western Australia, 6065.

UNISCOPE COMMUNICATIONS PTY LTD. P a g e 1 ABN: 80 159 470 943. Unit 3/10, Advantage Way, Wangara, Western Australia, 6065. UNISCOPE COMMUNICATIONS PTY LTD ABN: 80 159 470 943 Unit 3/10, Advantage Way, Wangara, Western Australia, 6065. T: (08) 6555 5850 E: info@uniscope.com.au W: www.uniscope.com.au P a g e 1 Table of Contents

More information

Order prevails to the extent of that inconsistency.

Order prevails to the extent of that inconsistency. TERMS AND CONDITIONS FOR PURCHASE OF GOODS AND/OR SERVICES 1. General 1. The Conditions of Contract include these conditions, the purchase order form, attached or dispatched separately, and any other documents

More information

SourceIT. Hardware Acquisition and Maintenance Contract. Australian Government. Release version 2.2

SourceIT. Hardware Acquisition and Maintenance Contract. Australian Government. Release version 2.2 Australian Government SourceIT Hardware Acquisition and Maintenance Contract Release version 2.2 [Insert name of Customer] (Customer) [Insert name of Contractor] (Contractor) Hardware Acquisition and Maintenance

More information

Agreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection)

Agreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection) Agreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection) This Agreement for Net Metering and Interconnection Services ( Agreement ) is made and entered into this day of

More information

Deed of Agreement for Lease

Deed of Agreement for Lease Deed of Agreement for Lease [in relation to Connection Contract Contestable ASP/1 Connection] Instructions for completion Ausgrid recommends you obtain legal advice before signing this document. Complete

More information

Managing Contractor. Design and Construction Management. Stage One with option for Stage Two. (Negotiated Guaranteed Construction Sum) July 2014

Managing Contractor. Design and Construction Management. Stage One with option for Stage Two. (Negotiated Guaranteed Construction Sum) July 2014 Managing Contractor Design and Construction Management Stage One with option for Stage Two (Negotiated Guaranteed Construction Sum) July 2014 Volume 2 of 4 Prepared by Contract Services Department of Housing

More information

South Australian One Library Management System

South Australian One Library Management System South Australian One Library Management System Service Agreement LGCS PTY LTD as Trustee of the LGCS Trust Number One ABN 90 602 350 622 and Town of Gawler ABN 29 861 749 581 Version: Final 273820\MWH01970313

More information

THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE

THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE THE SUSTAINABLE ENERGY AUTHORITY OF IRELAND PURCHASE ORDER TERMS AND CONDITIONS OF PURCHASE WHEREAS The Sustainable Energy Authority of Ireland (hereinafter called SEAI ) of Wilton Park House, Wilton Place,

More information

Request for Quotation

Request for Quotation Request for Quotation PROVISION OF GOODS FOR Food Services QUOTATION NO EF15/12346 You are invited to submit a quotation for provision of goods as detailed on the attached schedule. Your quotation is to

More information

Icetrak Fax to Email Contract Terms and Conditions

Icetrak Fax to Email Contract Terms and Conditions Section 1: General terms and conditions 1 Definitions Icetrak Fax to Email Contract Terms and Conditions 1.1 In these terms the words and expressions listed below shall have the following meanings: Act

More information

This is the Annexure A to Positive Covenant between and Woollahra Municipal Council

This is the Annexure A to Positive Covenant between and Woollahra Municipal Council This is the Annexure A to Positive Covenant between and Woollahra Municipal Council 1. Definitions and Interpretation 1.1. For the purpose of this covenant, the following definitions apply: Act means the

More information

MRA Agreement for Engagement of a Consultant/Contractor

MRA Agreement for Engagement of a Consultant/Contractor MRA Agreement for Engagement of a Consultant/Contractor 11/12/215 DOCID:207890 Table of Contents 1. DEFINITIONS AND INTERPRETATION... 1 2. FORMATION OF AGREEMENT... 3 3. TERM... 3 4. SCOPE OF WORK... 3

More information

FINANCIAL INCENTIVE AGREEMENT

FINANCIAL INCENTIVE AGREEMENT BETWEEN STATE OF QUEENSLAND through the Department of Science, Information Technology and Innovation (ABN 41 841 375 926) AND (ABN XX XXX XXX XXX) PROJECT: TABLE OF CONTENTS 1. DEFINITIONS AND INTERPRETATION...

More information

Network Support Service Contract Terms & Conditions. Business Terms describes this agreement for the provision of support services to the client;

Network Support Service Contract Terms & Conditions. Business Terms describes this agreement for the provision of support services to the client; Network Support Service Contract Terms & Conditions 1. Definitions In these Terms and Conditions: Business Terms describes this agreement for the provision of support services to the client; Service Manager

More information

Drain unblocking terms and conditions. Service@Happydrains.co.uk

Drain unblocking terms and conditions. Service@Happydrains.co.uk Drain unblocking terms and conditions Service@Happydrains.co.uk The Customer ( you ) can place an order with Happy Drains Limited, Unit 12 Manor Hall Road Chalex Industrial Estate, Southwick, Brighton,

More information

FUNDING AGREEMENT GENERAL TERMS

FUNDING AGREEMENT GENERAL TERMS 1. Appointment FUNDING AGREEMENT GENERAL TERMS 1.1. In consideration of the Foundation agreeing to make the Grant to the Recipient, the Recipient: 2. Term a) appoints the Foundation as [a/the] [major/exclusive]

More information

The Brand Consultants. 3men.co.uk. Client Agreement. we listen, we think, we design

The Brand Consultants. 3men.co.uk. Client Agreement. we listen, we think, we design 03 803 787 The Brand Consultants Client Agreement 3men.co.uk This Agreement shall set out the Terms and Conditions of Service between 3 Men & a Suit and the Client. Definitions 3 Company shall refer to

More information

PURCHASE ORDER IT HARDWARE CONDITIONS

PURCHASE ORDER IT HARDWARE CONDITIONS PURCHASE ORDER IT HARDWARE CONDITIONS 1 FORMATION OF CONTRACT The Principal has issued a Purchase Order for the supply of the Hardware and the Services (if any). The Purchase Order creates a contract between

More information

BLUETOOTH TRADEMARK LICENSE AGREEMENT This Bluetooth Trademark License Agreement (the License ) is made as of the date of acceptance by you as a

BLUETOOTH TRADEMARK LICENSE AGREEMENT This Bluetooth Trademark License Agreement (the License ) is made as of the date of acceptance by you as a BLUETOOTH TRADEMARK LICENSE AGREEMENT This Bluetooth Trademark License Agreement (the License ) is made as of the date of acceptance by you as a member of Bluetooth SIG, Inc., a Delaware corporation (

More information

STANDARD TERMS AND CONDITIONS FOR THE SUPPLY OF GOODS UNDER PURCHASE ORDER

STANDARD TERMS AND CONDITIONS FOR THE SUPPLY OF GOODS UNDER PURCHASE ORDER STANDARD TERMS AND CONDITIONS FOR THE SUPPLY OF GOODS UNDER PURCHASE ORDER THHNHSFT Standard Terms and Conditions of Contract for the Supply of Goods (PO version) Page 1 of 54 RECORD OF AMENDMENT VERSION

More information

PURCHASE ORDER TERMS AND CONDITIONS

PURCHASE ORDER TERMS AND CONDITIONS PURCHASE ORDER TERMS AND CONDITIONS 1 SUPPLY 1.1 The Supplier must supply and Deliver the Goods to Downer at the Place of Delivery or Place of Pick-up (as applicable) by the Delivery Date for the Price.

More information

If a Client and a Freelancer enter an independent contractor relationship, then this Freelancer Agreement ( Freelancer Agreement ) will apply.

If a Client and a Freelancer enter an independent contractor relationship, then this Freelancer Agreement ( Freelancer Agreement ) will apply. Freelancer Agreement If a Client and a Freelancer enter an independent contractor relationship, then this Freelancer Agreement ( Freelancer Agreement ) will apply. This Agreement is effective as of March

More information

These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES

These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES These Standard Terms and Conditions form a contract between the Company and the Supplier. SUPPLY OF GOODS / SERVICES 1. The Supplier shall supply and deliver to the Company all the goods/services set out

More information