ADMINISTRATIVE REPORT
|
|
- Osborn Rafe Barker
- 8 years ago
- Views:
Transcription
1 ADMINISTRATIVE REPORT MEETING DATE: October 31, 2015 DEPARTMENT DIRECTOR AGENDA SECTION: Action Items ITEM: 12. A APPROVED BY GENERAL MANAGER TO: FROM: Honorable Members of the Board Kevin Kalman, General Manager DATE: August 27, 2015 SUBJECT: Joint Use Agreement No M between Coachella Valley Unified School District and Desert Recreation District RECOMMENDATION: Approve Joint Use Agreement No AD between Coachella Valley Unified School District and Desert Recreation District and authorize the General Manager to make any necessary changes in or additions to Exhibit D, renovations which will be financed by Coachella Valley Unified School District. BACKGROUND: Historically, Coachella Valley Unified School District (CVUSD) and Desert Recreation District (DRD) have pooled resources to meet ongoing youth and community demands for more developmental and recreational opportunities. CVUSD and DRD currently have active Administrative Report - Subject: Joint Use Agreement NO M Page 1
2 ADMINISTRATIVE REPORT agreements for DRD use of the Thermal Rummond Community Senior Center, Coachella Valley High School Track and Mecca Elementary School South Sport Field. In the past, other such cooperative agreements have included DRD operation of CVUSD ASES afterschool enrichment programs and joint use of La Familia and John Kelly baseball facilities. While the supply has never quite matched demand, the CVUSD/DRD partnership has effectively maximized the use of CVUSD facilities to meet community and student needs, beyond what either could do alone. In addition to creating more opportunities for their respective constituent groups, sharing facilities has led to greater efficiencies in cost and operations. DRD and CVUSD acknowledge the value of their collaboration and seek to extend their working relationship. It is a DRD and CVUSD objective to increase general community access to and use of Mecca Elementary School North Soccer Field. This agreement is not intended to amend any of the existing leases and other property agreements between the parties. In establishing this agreement, DRD and CVUSD seek to: 1. Enhance school and community services and amenities, 2. improve a local community s built environment and public health, 3. increase interaction between DRD and its CVUSD, and 4. address pressing concerns including childhood obesity and efficient use of developed space. Upon execution of this agreement, DRD will proceed to renovate the 5 acre joint use area to bring it to safe playable conditions. This renovation is estimated to cost between $110,000 and $130,000 to complete. However, local businesses and churches have committed to offset much of the cost with donated materials and labor. The DRD and CVUSD would split the balance of cost associated with the initial renovation. After the completion of the initial renovation ongoing responsibilities for the joint use facilities will be divided between DRD and CVUSD as follows: DRD Responsibilities 1. Ongoing maintenance and operation. 2. Programming and community use 4pm 9pm weekdays, 7am 9pm summer, weekends and school holidays. 3. Electric Utility bills. 4. Security during DRD designated use times. Administrative Report - Subject: Joint Use Agreement NO M Page 2
3 ADMINISTRATIVE REPORT CVUSD Responsibilities 1. Capital and major maintenance after initial renovation. 2. Programming and community use weekdays until 4pm 3. Water Utility bills. 4. Security during CVUSD designated use times. BOARD STRATEGIC GOALS OR KEY OBJECTIVES ADDRESSED: Provide District residents a comprehensive, well maintained system of parks and facilities. Participation in public/public partnerships. Promoting healthy and active lifestyles. PREVIOUS BOARD AND/OR STAFF ACTION: None FINANCIAL IMPACT The estimated initial renovation is $130,000 with DRD share between $25,000 and $65,000 dependent on donated materials and labor. This a onetime cost that will be funded from capital reserves. The ongoing maintenance and operations is estimated at $2,500 per month or an annual expense of $30,000 and will be funded through AD93-1. All adjustments to the budget will be incorporated in the mid-year budget adjustments. Administrative Report - Subject: Joint Use Agreement NO M Page 3
4 ATTACHMENT MEMORANDUM MEETING DATE: October 31, 2015 AGENDA SECTION: Action Item ITEM: 12. A TO: FROM: Honorable Members of the Board Kevin Kalman, General Manager DATE: August 27, 2015 Documents related to the Subject: Joint Use Agreement No M between Coachella Valley Unified School District and Desert Recreation District 1. Joint Use Agreement No M between Coachella Valley Unified School District and Desert Recreation District. Administrative Report - Subject: Funding, Support and Services Agreement NO AD Page 1
5 JOINT USE AGREEMENT for Soccer Fields This Joint Use Agreement Agreement (the Agreement ) is hereby entered into by and between the COACHELLA VALLEY UNIFIED SCHOOL DISTRICT, a school district organized and existing under the laws of the State of California (the CVUSD ), and DESERT RECREATION DISTRICT, a recreation and park district organized and existing under the laws of the State of California (the DRD ), as of this first day of September, RECITALS WHEREAS, the CVUSD is the owner of certain real property located in the unincorporated community of Mecca consisting of approximately XXX acres and more commonly known as the Mecca Elementary School ( Site ); and WHEREAS, the DRD desires to Agreement from the CVUSD, and the CVUSD desires to Agreement to the DRD, certain property located within the Site more particularly and legally described in Exhibit A, attached hereto and incorporated herein by this reference (the Premises ), which the DRD intends to utilize for recreation purposes; and WHEREAS, as a condition of the Agreement, the CVUSD has agreed to allow the DRD to utilize, subject to the restrictions and conditions set forth herein, a XXX acre portion of the Mecca Elementary School, which is depicted on the Site Map attached hereto as Exhibit B and incorporated herein by reference (the Mecca Elementary School Soccer Fields ); and WHEREAS, Mecca Elementary School Soccer Fields shall be referred to herein as the Joint Use Property ; and WHEREAS, this Agreement sets forth the terms and conditions for the DRD s use of the Joint Use Property, as well as the rights and obligations of the parties hereto with respect to construction and maintenance of improvements on the Joint Use Property. AGREEMENT NOW THEREFORE, in consideration of the recitals set forth above, the covenants and agreements set forth herein, and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the CVUSD and the DRD agree as follows: 1. Dates and Times of Use. 1.1 CVUSD Use. The CVUSD shall have the sole right to utilize the Joint Use Property Monday through Friday from 7 a.m. to 4 p.m., exclusive of CVUSD holidays (the Routine Use Schedule ). In addition, the CVUSD and the DRD agree to meet on an annual basis, during the first fiscal month of the CVUSD s fiscal year, at which time the CVUSD shall notify the DRD of the dates and times of certain CVUSD special events. The CVUSD shall have the sole right to use the Joint Use Property during such dates and times in addition to its Routine Use Schedule (the Special Event Schedule ). Said Special Event Schedule shall be annually attached to this Agreement as Exhibit C and shall be incorporated herein by this reference and expressly made a part of the Agreement. 1.2 DRD Use. Except during those times set forth in the Special Event Schedule established annually by the CVUSD, the DRD shall have the sole and exclusive right to utilize the Joint Use Property Monday through Friday from 4 p.m. to 9 p.m., and on Saturdays and Sundays and all CVUSD holidays from 7 a.m. to 9 p.m. The DRD shall use the Joint Use Property for public recreational uses.
6 2. Limitations on Use. 2.1 CVUSD Uses. The CVUSD shall have the right to use the Joint Use Property for any and all uses authorized under the California Education Code, so long as such use does not materially interfere with the DRD s rights to use of the Joint Use Property as set forth herein. Parking shall be permitted on only those portions of the Joint Use Property which have been set aside and paved for parking. 2.2 DRD Uses. The DRD may utilize the Joint Use Property during the times set forth in Section 1.2 for parking (but only those portions of the Joint Use Property which have been set aside and paved for parking), and DRD sponsored or affiliated recreational uses. 3. Mutual Indemnity and Release. DRD and the CVUSD each hereby agree to indemnify, defend, and hold harmless the other party and its officers, employees, agents, volunteers and independent contractors (collectively, Indemnitees ) from and against any and all of claims, causes of action, obligations, losses, liabilities, judgments, or damages, including reasonable attorneys fees and costs of litigation (collectively Claims ) arising out of and/or in any way relating to the indemnifying party s activities in the performance of this Agreement, or to the indemnifying party s acts and/or omissions in providing or administering the same, excepting only those claims, actions, obligations, losses, liabilities, judgments, or damages arising out of the sole negligence or willful misconduct of the Indemnitees. 4. Insurance. The Parties agree to provide insurance in accordance with the provisions of this Section DRD s Insurance Obligation. Without limiting the indemnification provisions provided herein, the DRD, at its sole expense, shall obtain and keep in force during the term of this Agreement and any extensions thereof, a policy or policies of general liability insurance covering all injuries to persons and damage to property occurring in, upon or about the Premises resulting from any actions or omissions of the DRD or any use of the Premises by the DRD or its invitees in accordance with the terms of this Agreement. The policy or policies evidencing such insurance shall name the CVUSD and its officials, officers, employees, and agents as additional insureds, shall provide that same may not be cancelled or amended without thirty (30) days prior written notice to the CVUSD, and shall provide for a combined single limit coverage of bodily injury and property damage in the amount of not less than One Million Dollars ($1,000,000). Such policy or policies shall be issued by an insurance company licensed to do business in the State of California and be rated A-/VIII or better by ambest.com. Prior to the Commencement Date of this Agreement, and upon renewal of such policies, the DRD shall submit to the CVUSD certificates of insurance and any applicable endorsements evidencing that the foregoing policy or policies are in effect. At the DRD s option, DRD shall be allowed to self-insure the insurance coverages as required above. 4.2 CVUSD s Insurance Obligation. Without limiting the indemnification provisions provided herein, the CVUSD, at its sole expense, shall obtain and keep in force during the term of this Agreement and any extensions thereof, a policy or policies of general liability insurance covering all injuries to persons and damage to property occurring in, upon or about the Premises resulting from any actions or omissions of the CVUSD or any use of the Premises by the CVUSD or its invitees. The policy or policies evidencing such insurance shall name the DRD and its officials, officers, employees, and agents, as additional insureds, shall provide that same may not be cancelled or amended without
7 thirty (30) days prior written notice to the DRD, and shall provide for a combined single limit coverage of bodily injury and property damage in the amount of not less than One Million Dollars ($1,000,000). Such policy or policies shall be issued by an insurance company licensed to do business in the State of California which is rated A-/VIII or better by ambest.com. Prior to the Commencement Date of this Agreement, and upon renewal of such policies, the CVUSD shall submit to the DRD certificates of insurance and any applicable endorsements evidencing that the foregoing policy or policies are in effect. At the CVUSD s option, CVUSD shall be allowed to self-insure the insurance coverages as required above. CVUSD also shall have in place workers compensation insurance as required by law. 5. Improvements to the Joint Use Property.5.1 Sports Fields. The parties shall renovate and improve Mecca Elementary School Soccer Fields on the Joint Use Property in accordance with DRD standards. CVUSD shall be responsible for the cost of 50% of renovations agreed upon with DRD up to $55,000, and DRD shall be responsible for the agreed-upon balance. DRD shall coordinate and manage the renovations. 6. Maintenance of Joint Use Property. The Joint Use Property shall be maintained (irrigation system and turf) by the DRD in accordance with the standards set forth in the DRD s Maintenance Standards for Parks and Sports fields. Major repair or renovation is and shall remain the responsibility of CVUSD except as set out in Section 5 above. 6.1 CVUSD Share of Water Costs. Water usage for the Joint Use Property will be billed to the CVUSD and the CVUSD shall promptly pay all such water bills. Is there a drought issue? 6.2 Other Utilities. The DRD shall be responsible for paying all electrical bills incurred with respect to the operation of the Joint Use Property. 6.3 Other Maintenance Costs. The DRD shall be responsible for contracting for the general maintenance and upkeep of the Joint Use Property. Such contract shall provide for the maintenance of the Joint Use Property consistent with the standards set forth in the DRD s approved landscape maintenance guidelines. 7. Term of Agreement. This Agreement shall become effective September 1, 2015, and shall remain in effect for a term of thirty (30) years, unless earlier terminated as provided hereafter. Either party may terminate this Agreement providing the other with six (6) months prior written notice of the termination date 8. Default. Failure or delay by either party to perform any covenant, condition or provision of this Agreement within the time provided herein constitutes a default under this Agreement. The injured party shall give written notice of default to the party in default, clearly detailing the default to be cured. The defaulting party shall immediately commence to cure such default and shall diligently complete such cure within thirty (30) days from the date of the notice or such longer period if the nature of the default is such that more than thirty (30) days is required to cure such default. Notwithstanding any other provision of this Agreement, the injured party shall have the right to immediately terminate this Agreement by written notice to the other party in the event of a default which is not cured within the time set forth in this section. 9. Attorneys Fees. In the event any declaratory or other legal or equitable action is instituted between DRD and CVUSD in connection with this Agreement, the prevailing party shall be entitled to recover from the losing party all of its costs and expenses, including court
8 costs and reasonable attorneys fees, and all fees, costs and expenses incurred on any appeal or in collection of any judgment. 10. Notices. Any notice, request, demand, consent, approval or other communication required or permitted hereunder or by law shall be validly given or made only if in writing and delivered in person to an officer or duly authorized representative of the other party, or deposited in the United States mail, duly certified or registered (return receipt requested), postage prepaid, or delivered through another commercially reasonable method, including facsimile transmission and addressed to the party for whom intended, as follows: If to DRD: If to CVUSD: Desert Recreation District Attn: General Manager Oasis Street Indio, CA Fax: (760) Coachella Valley Unified School District Attn: Superintendent Church Street Thermal, CA Fax: (760) Any party may from time to time, by written notice to the other, designate a different address which shall be substituted for that specified above. If any notice or other document is sent by mail as aforesaid, the same shall be deemed fully delivered and received forty-eight (48) hours after mailing as provided above. If any notice or document is sent by facsimile transmission, the same shall be deemed fully delivered and received upon the transmission to the sender of a facsimile confirmation sheet. 11. Gender and Number. In this Agreement (unless the context requires otherwise), the masculine, feminine and neuter genders and the singular and the plural shall be deemed to include one another, as appropriate. 12. Entire Agreement. This Agreement and its exhibits, each of which is incorporated herein by reference as though set forth in full, constitute the entire agreement between the parties hereto pertaining to the subject matter hereof, and the final, complete and exclusive expression of the terms and conditions thereof. All prior agreements, representations, negotiations and understanding of the parties hereto, oral or written, express or implied, are hereby superseded and merged herein. 13. Captions. The captions used herein are for convenience only and are not a part of this Agreement and do not in any way limit or amplify the terms and provisions hereof. 14. Governing Law. This Agreement and the exhibits attached hereto have been negotiated and executed in the State of California and shall be governed by and construed under the laws of the State of California. 15. Invalidity of Provision. If any provision of this Agreement as applied to any party or to any circumstance shall be adjudged by a court of competent jurisdiction to be void or unenforceable for any reason, the same shall in no way affect (to the maximum extent permissible by law) any other provision of this Agreement, the application of any such provision under circumstances different from those adjudicated by the court, or the validity or enforceability of this Agreement as a whole.
9 16. Amendments/Waiver. No addition to or modification of any provision contained in this Agreement shall be effective unless fully set forth in writing by CVUSD and DRD. No waiver of any term or condition of this Agreement shall be a continuing waiver thereof. 17. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which together shall constitute but one and the same instrument. 18. Binding Upon Successors. The terms and conditions, covenants, and agreements set forth herein shall apply to and bind the heirs, executors, administrators, assigns and successors of the parties hereof. 19. Fingerprinting. The DRD sanctioned Sports Associations shall require all board members and volunteer coaches be fingerprinted prior to participating within the leagues. Any additional Sports Association field use contracted through the DRD also will require fingerprinting of staff and volunteers as a requirement of this Agreement even when not otherwise required by law. -- SIGNATURES BEGIN ON NEXT PAGE --
10 IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year set forth herein above. ATTEST: CVUSD: COACHELLA VALLEY UNIFIED SCHOOL DISTRICT, a school district organized and existing under the laws of the State of California By: Its: School District Secretary APPROVED AS TO FORM: XXXXXXXXXX School District Special Counsel DRD: DESERT RECREATION DISTRICT, a recreation and park district organized and existing under the laws of the State of California Date Kevin Kalman, General Manager ATTEST: Delia Granados, District Clerk APPROVED AS TO FORM: Elizabeth Martin, DRD Attorney
11 EXHIBIT A LEGAL DESCRIPTION OF THE COLONEL PAIGE SPORTS FIELDS PROPERTY Mecca Elementary School Soccer Fields are located within Acres M/L in POR PAR 4 PM 184/087 PM Riverside, California.
12 EXHIBIT B MAP OF COLONEL PAIGE MIDDLE SCHOOL FIELDS
13 EXHIBIT C SPECIAL EVENT SCHEDULE DRD staff will meet with Desert Sands Unified School CVUSD staff on an annual basis to identify dates of special events.
ADMINISTRATIVE REPORT
ADMINISTRATIVE REPORT MEETING DATE: January 13, 2016 DEPARTMENT DIRECTOR AGENDA SECTION: Action Items ITEM: 10. G APPROVED BY GENERAL MANAGER TO: FROM: Honorable Members of the Board Kevin Kalman, General
More informationTHESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL ADVICE.
DISCLAIMER The forms provided on our site were drafted by lawyers with knowledge of equine and contractual matters. However, the forms are not State specific. THESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL
More informationCONSULTING SERVICES AGREEMENT
CONSULTING SERVICES AGREEMENT This CONSULTING SERVICES AGREEMENT (this Agreement ) is dated as of the latest date set forth on the signature page hereto (the Effective Date ) and is entered into by and
More informationAGREEMENT FOR FINANCIAL AND ACCOUNTING CONSULTATION SERVICES
AGREEMENT FOR FINANCIAL AND ACCOUNTING CONSULTATION SERVICES THIS AGREEMENT is made as of December 1, 2003, by and between the San Francisquito Creek Joint Powers Authority, a body corporate and politic
More informationINDEPENDENT CONTRACTOR AGREEMENT FOR SPECIAL SERVICES
INDEPENDENT CONTRACTOR AGREEMENT FOR SPECIAL SERVICES This Independent Contractor Agreement for Services ( Agreement ) is made as of, 2012, between the Culver City Unified School District ("District")
More informationAnesthesia Providers, Inc. CRNA GENERAL INFORMATION FORM. Name First Name M.I. Last Name. Address Street Address Apt. # City State Zip Code
Anesthesia Providers, Inc. CRNA GENERAL INFORMATION FORM *Please Print Name First Name M.I. Last Name Address Street Address Apt. # City State Zip Code Date of Birth / / Mo. Date Year Home Telephone -
More informationLTC ELITE, LLC MEMBERSHIP AGREEMENT
LTC ELITE, LLC MEMBERSHIP AGREEMENT This Membership Agreement (this Agreement ) is made and entered into effective, (the Effective Date ), by and between LTC Elite, LLC, a Texas limited liability company
More informationReal Estate Salesman Agreement (Independent Contractor)
Real Estate Salesman Agreement (Independent Contractor) This Packet Includes: 1. General Information 2. Instructions and Checklist 3. Real Estate Salesman Agreement (Independent Contractor ) 1 General
More informationPayroll Services Agreement
Payroll Services Agreement THIS PAYROLL SERVICES AGREEMENT (the Agreement ) is made and entered into this day of, 20, by and between Susan Arnoldussen, of Accounting Unlimited, LLC (the Payroll Service
More informationHow To Work With The City Of Riverhead
MEMORANDUM OF UNDERSTANDING BETWEEN RIVERSIDE COMMUNITY COLLEGE DISTRICT and CITY OF RIVERSIDE THIS MEMORANDUM OF UNDERSTANDING ( MOU ) is made and entered into this day of, 2012 ( Effective Date ), by
More informationCity of Scotts Valley INTEROFFICE MEMORANDUM
DATE: January 15, 2014 City of Scotts Valley INTEROFFICE MEMORANDUM Agenda Item Date: 1-15-2014 TO: FROM: SUBJECT: Honorable Mayor and City Council Corrie Kates, Community Development Director/Deputy City
More informationBUSINESS ASSOCIATE AGREEMENT
BUSINESS ASSOCIATE AGREEMENT THIS BUSINESS ASSOCIATE AGREEMENT (this Agreement ) is made effective as of the day of 2014 (the Effective Date ), by and between Sarasota County Public Hospital District,
More informationGOODS AND SERVICES AGREEMENT BETWEEN SOUTHERN CALIFORNIA PUBLIC POWER AUTHORITY AND COMPANY/CONTRACTOR NAME
GOODS AND SERVICES AGREEMENT BETWEEN SOUTHERN CALIFORNIA PUBLIC POWER AUTHORITY AND COMPANY/CONTRACTOR NAME This GOODS AND SERVICES AGREEMENT ("Agreement") is entered into and effective [DATE], by and
More informationAgent Agreement WITNESSETH
PATRIOT NATIONAL UNDERWRITERS, INC. Agent Agreement THIS AGENT AGREEMENT (the Agreement ) is made and entered into by and between Patriot National Underwriters, Inc., a Texas corporation ( Patriot ), and
More informationAttachment B Agreement No. D09-
PROPOSITION 42 CITY AID PROGRAM FUNDING AGREEMENT This CITY AID PROGRAM FUNDING AGREEMENT, Agreement No. D09- ( Agreement ) is made and entered into this day of, 2009, by and between County of Orange,
More informationCOMPUTER SERVICES AGREEMENT
COMPUTER SERVICES AGREEMENT This COMPUTER SERVICES AGREEMENT ( "Agreement") is made and entered into effective as of the 1 day of January, 2008 (the Effective Date ), by and between 3T Productions, Inc.,
More informationBROKER/AGENT INFORMATION PAGE RETS IDX
FRESNO ASSOCIATION OF REALTORS IDX / RETS Compliance 6720 N West Ave. Fresno, CA 93711 (559) 490-6400 ~ rets@fresnorealtors.com BROKER/AGENT INFORMATION PAGE RETS IDX IN WITNESS WHEREOF, the parties hereto
More informationSALES PARTNER AGREEMENT
SALES PARTNER AGREEMENT This Agreement is made this day of, 200_ between ACOM SOLUTIONS, INC. ( ACOM ) having offices at 2850 East 29th Street, Long Beach, California 90806-2313 and (Partner) having offices
More informationTHE UNIVERSITY OF UTAH INDEPENDENT CONTRACTOR SERVICES AGREEMENT INSTRUCTIONS
THE UNIVERSITY OF UTAH INDEPENDENT CONTRACTOR SERVICES AGREEMENT INSTRUCTIONS Contracting for Independent Contractor services with the University of Utah may require completion of the following: Employee/Independent
More informationHow To Perform A Contract With A Community College District
INDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES This Independent Consultant Agreement for Professional Services ( Agreement ) is made and entered into as of the 21 st day of January 2015 by
More informationMEMORANDUM OF AGREEMENT SUMMARY
MEMORANDUM OF AGREEMENT Project Name/Description: Owner(s): Owner s (Owners ) Address/Phone/Email: Owner Type: Private Property Address/Vicinity: SHF Project Number: # Grant Amount: Total Estimated Project
More informationCULVER CITY UNIFIED SCHOOL DISTRICT INDEPENDENT CONTRACTOR AGREEMENT FOR PROFESSIONAL SERVICES (SPECIAL SERVICES) CONSULTING SERVICES
CULVER CITY UNIFIED SCHOOL DISTRICT INDEPENDENT CONTRACTOR AGREEMENT FOR PROFESSIONAL SERVICES (SPECIAL SERVICES) CONSULTING SERVICES This Independent Contractor Agreement for Special Services ( Agreement
More informationFACILITIES USE AGREEMENT
FACILITIES USE AGREEMENT Effective Date: Sponsor: Sponsor Address: Facility: THIS FACILITIES USE AGREEMENT ( Agreement ) is effective as of the Effective Date set forth above, by and between Temple University
More informationNON EXCLUSIVE BROKER REFERRAL AGREEMENT
NON EXCLUSIVE BROKER REFERRAL AGREEMENT THIS NON-EXCLUSIVE BROKER REFERRAL AGREEMENT (this Broker Contract ) is made this day of, 2013 by and between [NAME] (herein after called the "IFPG FRANCHISE CONSULTANT/BROKER
More informationPROFESSIONAL ELECTRICAL ENGINEERING SERVICES CONSULTING AGREEMENT
PROFESSIONAL ELECTRICAL ENGINEERING SERVICES CONSULTING AGREEMENT This agreement is executed on, 20 by and between Paradise Recreation and Park District, a California recreation and park district (the
More informationLOCATION AGREEMENT RECITALS:
LOCATION AGREEMENT THIS LOCATION AGREEMENT (the Agreement ) is made this day of, 20 by and between Fremont Street Experience Limited Liability Company, a ( Producer ) (the foregoing parties are collectively
More informationSTANDARD AGREEMENT FOR CONSULTANT SERVICES. THIS AGREEMENT, made and entered into in the City of Modesto, State of
STANDARD AGREEMENT FOR CONSULTANT SERVICES THIS AGREEMENT, made and entered into in the City of Modesto, State of California, this day of, 20, ( Effective Date ) by and between the CITY OF MODESTO, a municipal
More informationCeres Unified School District INDEPENDENT CONTRACTOR AGREEMENT 2013-2014
Ceres Unified School District INDEPENDENT CONTRACTOR AGREEMENT 2013-2014 THIS CONTRACT is hereby entered into by the Ceres Unified School District, hereinafter referred to as DISTRICT, and CONTRACTOR MAILING
More informationPRODUCT SALES AGREEMENT
PRODUCT SALES AGREEMENT This Product Sales Agreement (this Agreement ) is made as of the day of, 201, by and between Georgia Tech Applied Research Corporation, a Georgia non-profit corporation ( Seller
More informationAGREEMENT BETWEEN THE CITY OF BEVERLY HILLS AND VENDOR TBD FOR PURCHASE AND INSTALLATION OF AUTOMATED LICENSE PLATE RECOGNITION SYSTEMS
AGREEMENT BETWEEN THE CITY OF BEVERLY HILLS AND VENDOR TBD FOR PURCHASE AND INSTALLATION OF AUTOMATED LICENSE PLATE RECOGNITION SYSTEMS NAME OF CONTRACTOR: RESPONSIBLE PRINCIPAL OF CONTRACTOR:, Vendor
More informationBID BOND CITY OF EAST POINT, GEORGIA
BID BOND CITY OF EAST POINT, GEORGIA BIDDER (Name and Address): SURETY (Name and Address of Principal Place of Business): OWNER (hereinafter referred to as the City (Name and Address): City of East Point
More informationIDA INSURANCE TRUST PARTICIPATION AGREEMENT
EXECUTED VERSION IDA INSURANCE TRUST PARTICIPATION AGREEMENT THIS PARTICIPATION AGREEMENT (the Agreement ), made and entered into as of, by and between (the Participating Employer ) and the IDA Insurance
More informationTHESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL ADVICE.
DISCLAIMER The forms provided on our site were drafted by lawyers with knowledge of equine and contractual matters. However, the forms are not State specific. THESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL
More informationServices Agreement Instruction Sheet
Delta-T Group POB 884 Bryn Mawr, PA 19010 Phone: 800-251-8501 FAX: 610-527-9547 www.delta-tgroup.com Services Agreement Instruction Sheet We thank you for your interest in Delta-T Group. Below please find
More informationSTOCK PURCHASE AGREEMENT
STOCK PURCHASE AGREEMENT THIS STOCK PURCHASE AGREEMENT ("Agreement") is made and entered into effective as of the day of, 2014, by and between Paula Ring Zerkle, an adult individual with an address of
More informationINSURANCE AGENT AGREEMENT
INSURANCE AGENT AGREEMENT THIS INSURANCE AGENT AGREEMENT is made, 200_ by and between Athens Area Health Plan Select, Inc. ( AAHPS or the Plan ), and ( Agent ). RECITALS: WHEREAS, AAHPS is licensed to
More informationHome Foundation Contractor Services Agreement
Home Foundation Contractor Services Agreement This Packet Includes: 1. General Information 2. Instructions and Checklist 3. Step-by-Step Instructions 4. Home Foundation Contractor Services Agreement General
More informationAGREEMENT FOR SERVICES BETWEEN THE CITY OF YREKA AND [CONTRACTOR] WHEREAS, Contractor has the necessary experience in providing the services; and
AGREEMENT FOR SERVICES BETWEEN THE CITY OF YREKA AND [CONTRACTOR] THIS AGREEMENT is made and entered into this day of, 2014, by and between the City of Yreka, a municipal corporation, hereinafter referred
More informationTHESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL ADVICE.
DISCLAIMER The forms provided on our site were drafted by lawyers with knowledge of equine and contractual matters. However, the forms are not State specific. THESE FORMS ARE NOT A SUBSTITUTE FOR LEGAL
More informationBRITISH SOCCER CAMP A G R E E M E N T
THE STATE OF TEXAS * COUNTY OF CORYELL * KNOW ALL MEN BY THESE PRESENTS: BRITISH SOCCER CAMP A G R E E M E N T This agreement is made and entered into this the 20th day of January, 2015 by and between
More informationPROVO CITY UTILITIES NET METERING LICENSE AGREEMENT
PROVO CITY UTILITIES NET METERING LICENSE AGREEMENT Customer-Owned Electric Generating Systems of 25kW or Less This NET METERING LICENSE AGREEMENT ( Agreement ) is between ( Customer ) and Provo City -
More informationRecitals. NOW, THEREFORE, the parties hereto agree as follows: Agreement
THIS INDEPENDENT CONTRACTOR SERVICES AGREEMENT (this Agreement ) is made this day of, 20 (the Effective Date ), regardless of the date of execution, by and between Sierra Field Services, Inc., a Nevada
More informationCOPYRIGHT LICENSE AGREEMENT
COPYRIGHT LICENSE AGREEMENT THIS LICENSE AGREEMENT (this Agreement ) is made and entered into effective as of the day of, 2002 (the Effective Date ), by and between HIRST ARTS FANTASY ARCHITECTURE and
More informationCLAIMS ADMINISTRATION SERVICES AGREEMENT
Attachment D.13 CLAIMS ADMINISTRATION SERVICES AGREEMENT This AGREEMENT is made and entered into by and between SANTA BARBARA SCHOOL DISTRICTS hereinafter referred to as "DISTRICT", and KEENAN & ASSOCIATES,
More informationWITNESSETH. That Contractor, for the consideration hereinafter fully set out, hereby agrees with the County as follows:
NORTH CAROLINA RANDOLPH COUNTY CONTRACT THIS CONTRACT, made and entered into this day of, 2015 by and between Randolph County, a political subdivision of the State of North Carolina, hereinafter referred
More informationBUSINESS ASSOCIATE AGREEMENT
BUSINESS ASSOCIATE AGREEMENT Please complete the following and return signed via Fax: 919-785-1205 via Mail: Aesthetic & Reconstructive Plastic Surgery, PLLC 2304 Wesvill Court Suite 360 Raleigh, NC 27607
More informationNPSA GENERAL PROVISIONS
NPSA GENERAL PROVISIONS 1. Independent Contractor. A. It is understood and agreed that CONTRACTOR (including CONTRACTOR s employees) is an independent contractor and that no relationship of employer-employee
More informationHIPAA BUSINESS ASSOCIATE AGREEMENT
HIPAA BUSINESS ASSOCIATE AGREEMENT This Agreement ( Agreement ) is entered into by and between Wittman Enterprises, LLC ( Business Associate ) and City of Coronado Fire Department ( Covered Entity ). RECITALS
More informationAgreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection)
Agreement for Net Metering and Interconnection Services (Level 1, 2 and 3 Interconnection) This Agreement for Net Metering and Interconnection Services ( Agreement ) is made and entered into this day of
More informationELECTRONIC TRANSMITTAL OF SIGNATURE AGREEMENT
ELECTRONIC TRANSMITTAL OF SIGNATURE AGREEMENT THIS ELECTRONIC TRANSMITTAL OF SIGNATURE AGREEMENT (the Agreement ) is entered into by and between General Agents Acceptance Corporation ( GAAC ) and ( PRODUCER
More information2 of 8 10/18/2012 1:12 PM
2 of 8 10/18/2012 1:12 PM Exhibit 10.11 EXECUTION COPY SALARIED EMPLOYEE LIABILITIES ASSUMPTION AGREEMENT This SALARIED EMPLOYEE LIABILITIES ASSUMPTION AGREEMENT ( Agreement ) is made on the 22nd day of
More informationREQUEST FOR QUOTES FOR. On-Call Plumbing Contractor
Department of Public Services REQUEST FOR QUOTES FOR On-Call Plumbing Contractor November 2013 One Detjen Drive Crestwood, Missouri 63126 314-729-4720 Fax 314-729-4729 http://www.ci.crestwood.mo.us 1 Request
More informationInsurance Producer Agreement
Insurance Producer Agreement Section 1 - Producer s Authority The Producer shall periodically submit risks to the Company for its consideration as authorized by the Company. These risks shall be located
More informationINDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES ARCHITECTURAL AND ENGINEERING SERVICES
INDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES ARCHITECTURAL AND ENGINEERING SERVICES This Independent Consultant Agreement for Professional Services ( Agreement ) is made and entered into
More informationCity of Piedmont COUNCIL AGENDA REPORT
City of Piedmont COUNCIL AGENDA REPORT DATE: February 17, 2015 TO: FROM: SUBJECT: Mayor and Council Paul Benoit, City Administrator Award of Agreement for Printing of Summer 2015 Recreation Activity Guide
More informationCONTRACT AGREEMENT THIS CONTRACT AGREEMENT IS BETWEEN ***************************************************************** FOR THE YUROK TRIBE
Contract # CONTRACT AGREEMENT THIS CONTRACT AGREEMENT IS BETWEEN (name of department) Yurok Tribe 190 Klamath Boulevard AND Klamath, California 95548 (707) 482-1350 *****************************************************************
More informationWEBSITE DEVELOPMENT STANDARD TERMS AND CONDITIONS
WEBSITE DEVELOPMENT STANDARD TERMS AND CONDITIONS A. Client commitment: Client agrees to allocate time and process information, as needed, during the duration of the project. Client agrees to review the
More informationBUSINESS ASSOCIATE AGREEMENT
BUSINESS ASSOCIATE AGREEMENT This Business Associate Agreement (the Agreement ), is made effective as of the sign up date on the login information page of the CarePICS.com website, by and between CarePICS,
More informationIndependent Contractor Agreement. Name of Contractor: Address: Social Security or Tax I.D. Number:
HOFSTRA UNIVERSITY Name of Contractor: Address: Social Security or Tax I.D. Number: Independent Contractor Agreement THIS INDEPENDENT CONTRACTOR AGREEMENT (together with any attachments referred to below,
More informationBROKER AGREEMENT. NOW THEREFORE, in consideration of promises, covenants and agreements hereinafter contain, the parties agree as follows:
THIS AGREEMENT is entered into in the State of California this day of 2006, between Crestline Funding Corporation, hereinafter referred to as Crestline Funding, and, hereinafter referred to as Broker.
More informationINDEPENDENT CONTRACTOR AGREEMENT
INDEPENDENT CONTRACTOR AGREEMENT This Agreement is hereby entered into between the ESCONDIDO UNION HIGH SCHOOL DISTRICT, hereinafter referred to as District, and hereinafter referred to as Contractor.
More informationRECITALS. WHEREAS, VENDOR is a company and a provider of technology services for business, government and education;
ATTACHMENT 9 AGREEMENT FOR CONSULTING SERVICES BETWEEN AND THE CLEVELAND PUBLIC LIBRARY This Agreement is made and entered by and between with a principal place of business at and the BOARD OF TRUSTEES
More informationINDEPENDENT CONTRACTOR AGREEMENT (On Call Real Estate Broker Services)
INDEPENDENT CONTRACTOR AGREEMENT (On Call Real Estate Broker Services) THIS AGREEMENT (Contract") is made this 14th day of December, 2010, between the Board of County Commissioners of Sumter County, Florida
More informationINDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES RETRO-COMMISSIONING PLAN AND ENGINEERING ANALYSIS FOR SCIENCE BUILDING
INDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES RETRO-COMMISSIONING PLAN AND ENGINEERING ANALYSIS FOR SCIENCE BUILDING Contract No. 13P014 This Independent Consultant Agreement for Professional
More informationAGREEMENT BETWEEN THE CITY OF BEVERLY HILLS AND FOR. Attention:
AGREEMENT BETWEEN THE CITY OF BEVERLY HILLS AND FOR NAME OF CONSULTANT: RESPONSIBLE PRINCIPAL OF CONSULTANT: CONSULTANT'S ADDRESS: Attention: CITY'S ADDRESS: City of Beverly Hills 455 N. Rexford Drive
More informationSUB-PRODUCER AGREEMENT
SUB-PRODUCER AGREEMENT THIS AGREEMENT is made and entered into on the day of, 2015 by and between SELECT INSURANCE MARKETS, LP., a Texas Company ( SIM ) and the following named individual or agency who/which
More informationHow To License A Patent From Ancient Recipe Cards
Option Agreement This Option Agreement (the "AGREEMENT") is made and entered into by and between EMORY UNIVERSITY, a nonprofit Georgia corporation with offices located at 1599 Clifton Road NE, 4 th Floor,
More informationAGREEMENT BETWEEN OWNER AND ARCHITECT/ENGINEER (Small Projects-Construction Costs Generally Under $100,000)
AISD PROJECT NO. PROJECT TITLE AND ADDRESS: AGREEMENT BETWEEN OWNER AND ARCHITECT/ENGINEER (Small Projects-Construction Costs Generally Under $100,000) This Agreement ( Agreement ) is made as of the day
More informationINDEPENDENT BROKER AGREEMENT October 1, 2011 edition
INDEPENDENT BROKER AGREEMENT October 1, 2011 edition This INDEPENDENT BROKER AGREEMENT made this day of 20 by and between Morstan General Agency of New Jersey, Inc. its affiliates and/or subsidiaries,
More informationFREELANCE PHOTOGRAPHY AGREEMENT
FREELANCE PHOTOGRAPHY AGREEMENT This Freelance Photography Agreement ( Agreement ) is made and entered into this day of, 201 ( Effective Date ) by and between Xavier University ( University ), an Ohio
More informationCOMPUTER AND INFORMATION TECHNOLOGY MANAGED SERVICES AGREEMENT
COMPUTER AND INFORMATION TECHNOLOGY MANAGED SERVICES AGREEMENT This Computer and Information Technology Services Agreement is made as of the day of, between Crown Networking Consultants, Inc. (CNC Inc.),
More informationHow To Work For A City Of Germany Project
CONSULTING SERVICES AGREEMENT This Consulting Services Agreement ( Agreement ) is made and entered into this day of, 2013, by and between the City of Clovis, a Municipal Corporation, hereinafter called
More informationCONSULTANT AGREEMENT WITNESSETH. Recitals:
CONSULTANT AGREEMENT THIS AGREEMENT, made and entered into this day of, 2000, by and between ( CONSULTANT ) and the City of Santa Ana, a municipal corporation of the State of California ( CITY ). WITNESSETH
More informationBROKERAGE AGREEMENT. WHEREAS Broker wishes to gain access to and offer Paragon s specialized insurance products and services to its clients; and
BROKERAGE AGREEMENT This Agreement, effective 2014 is between Paragon Insurance Holdings, LLC ( Paragon ), 45 Nod Road, Avon, Connecticut 06001 with underwriting office at 850 Fulton Street, Farmingdale,
More informationPay Per Click Services Agreement
Pay Per Click Services Agreement Pay per click service agreement made on the (date), between (Name of Client), a corporation organized and existing under the laws of the state of, with its principal office
More informationCity of Piedmont COUNCIL AGENDA REPORT
City of Piedmont COUNCIL AGENDA REPORT DATE: September 6, 2011 FROM: Edward W. Tubbs, Fire Chief SUBJECT: Emergency Medical Services Billing Contract RECOMMENDATION Authorize the Fire Chief to enter into
More informationCUSTOMER LIST PURCHASE AGREEMENT BY AND BETWEEN RICHARD PENNER SELLER. and S&W SEED COMPANY BUYER
EXHIBIT 10.1 CUSTOMER LIST PURCHASE AGREEMENT BY AND BETWEEN RICHARD PENNER as SELLER and S&W SEED COMPANY as BUYER CUSTOMER LIST PURCHASE AGREEMENT THIS CUSTOMER LIST PURCHASE AGREEMENT ( Agreement )
More informationMASTER ROAD REPAIR AGREEMENT STATE OF TEXAS KNOW ALL MEN BY THESE PRESENTS: COUNTY OF HOOD
SUP-20 - Date or PL-20 - Date GW-20 - Date MASTER ROAD REPAIR AGREEMENT STATE OF TEXAS KNOW ALL MEN BY THESE PRESENTS: COUNTY OF HOOD This Road Repair Agreement, ( Agreement ), is made and entered into
More informationMaster Software Purchase Agreement
Master Software Purchase Agreement This Master Software Purchase Agreement ( Agreement ) is entered into as of Wednesday, March 12, 2014 (the Effective Date ) by and between with principal offices at (
More informationINDEPENDENT CONTRACTOR AGREEMENT. Currituck (hereinafter County ) and, RECITALS
INDEPENDENT CONTRACTOR AGREEMENT THIS AGREEMENT is made the day December, 2015, between the County of Currituck (hereinafter County ) and, (hereinafter Contractor ). RECITALS County is a body corporate
More informationCONSULTANT SERVICES AGREEMENT
CONSULTANT SERVICES AGREEMENT This Consultant Services Agreement ( Agreement ) is dated [month] [day], [year] ( Effective Date ), and is between the City of Monrovia, a California municipal corporation
More informationALIEF INDEPENDENT SCHOOL DISTRICT
ALIEF INDEPENDENT SCHOOL DISTRICT MEMORANDUM OF UNDERSTANDING ALIEF INDEPENDENT SCHOOL DISTRICT AND HOUSTON COMMUNITY COLLEGE COLLEGE PREP MATHEMATICS AND ENGLISH LANGUAGE ARTS COURSES This Memorandum
More informationINDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES CONSULTING EDUCATION MASTER PLANNING SERVICES
INDEPENDENT CONSULTANT AGREEMENT FOR PROFESSIONAL SERVICES CONSULTING EDUCATION MASTER PLANNING SERVICES This Independent Consultant Agreement for Professional Services ( Agreement ) is made and entered
More informationConsulting Master Services Agreement
Consulting Master Services Agreement THIS CONSULTING AGREEMENT (this Agreement ), made and entered into this 21st day of June, 2002, by and between PrimeContractor, a StateName EntityType, its successors
More informationINDEPENDENT CONTRACTOR AGREEMENT
INDEPENDENT CONTRACTOR AGREEMENT This Independent Contractor Agreement ("Agreement") is made and effective this day of, 20. BETWEEN: (the "Independent Contractor"), a company organized and existing under
More informationEQUITY SHARING AGREEMENT
EQUITY SHARING AGREEMENT This Equity Sharing Agreement (the Agreement ) is entered into as of the date set forth below by and between a California nonprofit corporation (the Church ), and (the Occupant
More informationTRADEMARK AND DOMAIN NAME AGREEMENT
TRADEMARK AND DOMAIN NAME AGREEMENT This agreement (the Agreement ) is by and between _ ( Party ) and Eclipse Foundation, Inc. ( Eclipse ) and is effective as of [ ] [ ], 201[ ] (the Effective Date ).
More informationAGREEMENT WITH FOR PROFESSIONAL CONSULTANT SERVICES FOR
AGREEMENT WITH FOR PROFESSIONAL CONSULTANT SERVICES FOR This Agreement, made and entered into this day of,, by and between the CITY OF SAN MATEO, a municipal corporation existing under the laws of the
More informationLenders Axis LLC Working Capital Sales Agent Agreement Lenders Axis Sales Agent Agreement V 2.0
Lenders Axis LLC Working Capital Sales Agent Agreement Lenders Axis Sales Agent Agreement V 2.0 This Sales Agent Agreement (the Agreement ) is made and effective as of this the day of 13 by and between
More informationATLANTA COMMERCIAL BOARD OF REALTORS, INC. EXCLUSIVE LISTING AGREEMENT FOR SALE OF REAL PROPERTY
ATLANTA COMMERCIAL BOARD OF REALTORS, INC. EXCLUSIVE LISTING AGREEMENT FOR SALE OF REAL PROPERTY THIS EXCLUSIVE LISTING AGREEMENT (this Agreement ), dated, is made and entered into by and between as owner
More informationHow To Pay A Contract With Neustar
Neustar Referral Partnership Agreement This NEUSTAR REFERRAL AFFILIATE PARTNERSHIP AGREEMENT ( Agreement ) is made and entered into between Neustar, Inc. a Delaware Corporation, located at 46000 Center
More informationRECITALS. WHEREAS, TOP SEED possess specialized knowledge and expertise in tennis instruction and the management of tennis services; and
FACILITY USE AGREEMENT CALABASAS TENNIS AND SWIM CENTER This FACILITY USE AGREEMENT (AAgreement@) is entered into by and between the CITY OF CALABASAS, a California municipal corporation (ACity@) and TOP
More informationCONSULTING SERVICES AGREEMENT THE CORPORATION OF THE CITY OF GUELPH, an Ontario municipality. ( City ) and. an Ontario. ( Consultant").
Page 1 of 13 CONSULTING SERVICES AGREEMENT This consulting services agreement is between: THE CORPORATION OF THE CITY OF GUELPH, an Ontario municipality ( City ) and, an Ontario ( Consultant"). The parties
More informationCORD BLOOD FINANCIAL AND STORAGE AGREEMENT
CORD BLOOD FINANCIAL AND STORAGE AGREEMENT THIS CORD BLOOD FINANCIAL AND STORAGE AGREEMENT ( Agreement ) is made and entered into as of the Effective Date, by and between M.A.Z.E. Cord Blood Laboratories,
More informationCONTRACT FOR ACCESS TO TRAFFIC MANAGEMENT MONITORING SYSTEMS AND DATA
CONTRACT FOR ACCESS TO TRAFFIC MANAGEMENT MONITORING SYSTEMS AND DATA This Contract for Access to Traffic Management Monitoring Systems and Data ( Contract ) is entered into this 27 th day of January,
More informationDESERT RECREATION DISTRICT Located at 45-305 Oasis Street, Indio, CA 92201
DESERT RECREATION DISTRICT Located at 45-305 Oasis Street, Indio, CA 92201 NOTICE INVITING REQUESTS FOR QUALIFICATIONS For STRATEGIC PLAN RFQ #11-07-001-AD PUBLIC NOTICE IS HEREBY GIVEN that the Desert
More informationELECTRONIC DATA INTERCHANGE (EDI) TRADING PARTNER AGREEMENT THIS ELECTRONIC DATA INTERCHANGE TRADING PARTNER AGREEMENT
ELECTRONIC DATA INTERCHANGE (EDI) TRADING PARTNER AGREEMENT THIS ELECTRONIC DATA INTERCHANGE TRADING PARTNER AGREEMENT (the Agreement ) is made as of, by and between Potomac Electric Power Company (Pepco),
More informationNATIONAL CONTRACTORS INSURANCE COMPANY, INC., A RISK RETENTION GROUP SUBSCRIPTION AND SHAREHOLDERS AGREEMENT
1 NATIONAL CONTRACTORS INSURANCE COMPANY, INC., A RISK RETENTION GROUP NOTICE SUBSCRIPTION AND SHAREHOLDERS AGREEMENT This policy is issued by your risk retention group. Your risk retention group may not
More informationRetail Electric Supplier Tariff Service Agreement
Retail Electric Supplier Tariff Service Agreement This Agreement ( Agreement ) is made as of (date), entered into by and between Ameren Services Company ( Company ), a Missouri corporation, and (company
More informationAGREEMENT BETWEEN THE CITY OF CRESTWOOD, MO AND BIEG PLUMBING COMPANY FOR ON-CALL PLUMBING SERVICE FOR THE PERIOD
AGREEMENT BETWEEN THE CITY OF CRESTWOOD, MO AND BIEG PLUMBING COMPANY FOR ON-CALL PLUMBING SERVICE FOR THE PERIOD JANUARY 1, 2014 TO DECEMBER 31, 2015 AGREEMENT THIS AGREEMENT, is made and entered into
More information